Where the Academy Trust acquires assets for a nil consideration or at an under value it shall be treated for the purpose of this Agreement as having incurred expenditure equal to the market value of those assets at the time that they were acquired. This provision shall not apply to assets transferred to the Academy Trust at nil or nominal consideration and which were previously used for the purposes of an Academy and/or were transferred from an LA, the value of which assets shall be disregarded.
POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
POSSESSION OF THE APARTMENT 7.1 Schedule for possession of the said Apartment - The Promoter agrees and understands that timely delivery of possession of the Apartment to the allottee’s and the common areas to the association of allottee’s or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the Apartment along with ready and complete common areas with all specifications, amenities and facilities of the project in place on (Date) unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee’s agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, provided that such Force Majeure conditions are not of a nature, which make it impossible for the contract to be implemented. The Allottee’s agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee’s the entire amount received by the Promoter from the allotment within 45 days from that date. The promoter shall intimate the allottee’s about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee’s, the Allottee’s agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
GENERAL COMPLIANCE WITH RESPECT TO THE APARTMENT Subject to Clause 12 above, the Allottee shall, after taking possession, be solely responsible to maintain the [Apartment/Plot] at his/her own cost, in good repair and condition and shall not do or suffer to be done anything in or to the Building, or the [Apartment/Plot], or the staircases, lifts, common passages, corridors, circulation areas, atrium or the compound which may be in violation of any laws or rules of any authority or change or alter or make additions to the [Apartment/Plot] and keep the [Apartment/Plot], its walls and partitions, sewers, drains, pipe and appurtenances thereto or belonging thereto, in good and tenantable repair and maintain the same in a fit and proper condition and ensure that the support, shelter etc. of the Building is not in any way damaged or jeopardized. The Allottee further undertakes, assures and guarantees that he/she would not put any sign-board / name-plate, neon light, publicity material or advertisement material etc. on the face / facade of the Building or anywhere on the exterior of the Project, buildings therein or Common Areas. The Allottees shall also not change the colour scheme of the outer walls or painting of the exterior side of the windows or carry out any change in the exterior elevation or design. Further the Allottee shall not store any hazardous or combustible goods in the [Apartment/Plot] or place any heavy material in the common passages or staircase of the Building. The Allottee shall also not remove any wall, including the outer and load bearing wall of the [Apartment/Plot]. The Allottee shall plan and distribute its electrical load in conformity with the electrical systems installed by the Promoter and thereafter the association of allottees and/or maintenance agency appointed by association of allottees. The Allottee shall be responsible for any loss or damages arising out of breach of any of the aforesaid conditions.
COMPLIANCE WITH RESPECT TO THE APARTMENT 15.1 Subject to para 12 above, the Allottee shall, after taking possession, be solely responsible to maintain the Apartment at his/her own cost, in good repair and condition and shall not do or suffer to be done anything in or to the Building, or the Apartment, or the staircases, lifts, common passages, corridors, circulation areas, atrium or the compound which may be in violation of any laws or rules of any authority or change or alter or make additions to the Apartment and keep the Apartment, its walls and partitions, sewers, drains, pipe and appurtenances thereto or belonging thereto, in good and tenantable repair and maintain the same in a fit and proper condition and ensure that the support, shelter etc. of the Building is not in any way damaged or jeopardized.
Pursuant to the Act The Company has filed with the Commission a registration statement and any amendment thereto, on Form S-1 (File No. 333-[●]), including any related preliminary prospectus (the “Preliminary Prospectus”, including any prospectus that is included in the registration statement immediately prior to the effectiveness of the registration statement), for the registration of the Units under the Act, which registration statement and amendment or amendments have been prepared by the Company in conformity with the requirements of the Act, and the rules and regulations (the “Regulations”) of the Commission under the Act. The conditions for use of Form S-1 to register the Offering under the Act, as set forth in the General Instructions to such Form, have been satisfied. Except as the context may otherwise require, such registration statement, as amended, on file with the Commission at the time the registration statement became effective, including the prospectus, financial statements, schedules, exhibits and all other documents filed as a part thereof or incorporated therein and all information deemed to be a part thereof as of such time pursuant to Rule 430A of the Regulations, together with the registration statement filed by the Company pursuant to Rule 462(b) under the Act registering additional Public Securities (the “Rule 462(b) Registration Statement”), is hereinafter called the “Registration Statement,” and the form of the final prospectus dated the Effective Date included in the Registration Statement (or, if applicable, the form of final prospectus containing information permitted to be omitted at the time of effectiveness by Rule 430A of the Regulations, filed by the Company with the Commission pursuant to Rule 424 of the Regulations), is hereinafter called the “Prospectus.” For purposes of this Agreement, “Applicable Time,” as used in the Act, means 5:00 p.m. New York City time, on the date of this Agreement. Prior to the Applicable Time, the Company prepared a Preliminary Prospectus, which was included in the Registration Statement filed on [●], 2021, for distribution by the Underwriters (such Preliminary Prospectus used most recently prior to the Applicable Time, the “Statutory Prospectus”). Other than the Registration Statement, together with any correspondence letters between the Company and/or counsel for the Company and the Commission, no other document with respect to the Registration Statement has been filed under the Act with the Commission. All of the Public Securities have been or will be registered for public sale under the Act pursuant to the Registration Statement. The Registration Statement has been declared effective by the Commission on the date hereof. If, subsequent to the date of this Agreement, the Company or the Representative determines that, at the Applicable Time, the Statutory Prospectus included an untrue statement of a material fact or omitted a statement of material fact necessary to make the statements therein, in light of the circumstances under which they were made, not misleading and the Company and the Representative agree to provide an opportunity to purchasers of the Units to terminate their old purchase contracts and enter into new purchase contracts, then the Statutory Prospectus will be deemed to include any additional information available to purchasers at the time of entry into the first such new purchase contract.
Purchase and Sale of the Assets (a) Purchase and Sale of the Assets. Subject to the terms and conditions of this Agreement and on the basis of the representations, warranties, covenants and agreements herein contained:
Possession by the Allottee After obtaining the occupancy certificate* and handing over physical possession of the [Apartment/Plot] to the Allottees, it shall be the responsibility of the Promoter to hand over the necessary documents and plans, including common areas, to the association of Allottees or the competent authority, as the case may be, as per the local laws. [Provided that, in the absence of any local law, the promoter shall handover the necessary documents and plans, including common areas, to the association of allottees or the competent authority, as the case may be, within thirty days after obtaining the completion certificate].
Construction of the Agreement The Agreement sets forth the entire understanding between two sophisticated business entities with legal counsel as to its subject and supersedes all prior agreements, conditions, warranties, representations, arrangements and communications, including purchase orders issued by Client, whether oral or written, and whether with or by Accenture, any of its affiliates, or any of their employees, officers, directors, agents or shareholders. Each party acknowledges that it entered into the Agreement solely based on the agreements and representations contained herein, and has not relied upon any representations, warranties, promises, or inducements of any kind, whether oral or written, and from any source. If a court of competent jurisdiction finds any term of the Agreement to be invalid, illegal or otherwise unenforceable, such term or provision will not affect the other terms of this Agreement and will be deemed modified to the extent necessary, in the court’s opinion, to render such term enforceable while preserving to the fullest extent permissible the intent and agreements of the parties set forth in this Agreement. No waiver or modification of any provision of the Agreement will be effective unless it is in writing and signed by the party against which it is sought to be enforced. The delay or failure by either party to exercise or enforce any of its rights under this Agreement is not a waiver of that party’s right to later enforce those rights, nor will any single or partial exercise of any such right preclude any other or further exercise of these rights or any other right. There are no third-party beneficiaries to the Agreement. In the event of a conflict between these GTC and an Order Form, the Order Form controls for purposes of that Order Form only.
SUBJECT MATTER OF THE AGREEMENT 1.1 The institution shall provide support to the participant for undertaking a mobility activity for [teaching/ training/ teaching and training] under the Erasmus+ Programme.
