COMPENSATION TO TENANT FOR TEMPORARY USE Sample Clauses

COMPENSATION TO TENANT FOR TEMPORARY USE. If the temporary use or occupancy of all or any part of the Premises shall be taken by condemnation or in any other manner for any public or quasi-public use or purpose during the Term, Tenant shall be entitled, except as hereinafter set forth, to receive that portion of the award or payment for such taking which represents compensation for the use and occupancy of the Premises, for the taking of Tenant's Property and for moving expenses, and Landlord shall be entitled to receive that portion that represents reimbursement for the cost of restoration of the Premises. This Lease shall be and remain unaffected by such taking, and Tenant shall continue to be responsible for all of its obligations hereunder insofar as such obligations are not affected by such taking and shall continue to pay, in full, the Base Rent and Additional Rent when due. If the period of temporary use or occupancy shall extend beyond the Expiration Date, that part of the award that represents compensation for the use and occupancy of the Premises (or a part thereof) shall be prorated between Landlord and Tenant so that Tenant shall receive so much thereof as represents the period up to and including such Expiration Date and Landlord shall receive so much thereof as represents the period after such Expiration Date. All monies paid as, or as part of, an award for temporary use and occupancy for a period beyond the date to which the Base Rent and Additional Rent have been paid shall be received, held and applied by Landlord as a trust fund for payment of the Base Rent and Additional Rent becoming due.
Sample 1Sample 2See All (9)
AutoNDA by SimpleDocs

Related to COMPENSATION TO TENANT FOR TEMPORARY USE

  • Budget For Tenant Improvements A preliminary detailed breakdown by trade of the costs incurred or that will be incurred in connection with the design and construction of the Tenant Improvements is set forth on Schedule 3 attached hereto (the “Budget”). The Budget is based upon the TI Construction Drawings approved by Tenant and shall include a payment to Landlord of administrative rent (“Administrative Rent”) equal to 1.5% of the TI Costs, which Administrative Rent shall include, without limitation, all out-of-pocket costs, expenses and fees incurred by or on behalf of Landlord arising from, out of, or in connection with monitoring the construction of the Tenant Improvements and Changes, and shall be payable out of the TI Fund. Landlord shall provide Tenant with a final Budget promptly following approval of the TI Construction Drawings by Landlord and Tenant. The Budget shall be subject to Tenant’s review and approval which approval shall not be unreasonably withheld, conditioned or delayed by Tenant. Tenant shall have the right to approve any use of the contingency in the Budget by Landlord; provided, however, that, Tenant’s approval shall not be unreasonably withheld, conditioned or delayed, and the contingency shall not be available for use by Tenant for any Changes until all unforeseen conditions, changes to resulting from governmental agencies and the like have first been paid for out of the contingency.

  • Landlord’s General Conditions for Tenant’s Agents and Tenant Improvement Work Tenant’s and Tenant’s Agent’s construction of the Tenant Improvements shall comply with the following: (i) the Tenant Improvements shall be constructed in strict accordance with the Approved Working Drawings; (ii) Tenant’s Agents shall submit schedules of all work relating to the Tenant’s Improvements to Contractor and Contractor shall, within five (5) business days of receipt thereof, inform Tenant’s Agents of any changes which are necessary thereto, and Tenant’s Agents shall adhere to such corrected schedule; and (iii) Tenant shall abide by all rules made by Landlord’s Building manager with respect to the use of freight, loading dock and service elevators, storage of materials, coordination of work with the contractors of other tenants, and any other matter in connection with this Tenant Work Letter, including, without limitation, the construction of the Tenant Improvements.

  • Payment for Improvements If payment is made directly to contractors, Tenant shall (i) comply with Landlord's requirements for final lien releases and waivers in connection with Tenant's payment for work to contractors, and (ii) sign Landlord's standard contractor's rules and regulations. If Tenant orders any work directly from Landlord, Tenant shall pay to Landlord an amount equal to five percent of the cost of such work to compensate Landlord for all overhead, general conditions, fees and other costs and expenses arising from Landlord's involvement with such work. If Tenant does not order any work directly from Landlord, Tenant shall reimburse Landlord for Landlord's reasonable, actual, out-of-pocket costs and expenses actually incurred in connection with Landlord's review of such work.

  • Landlord’s Option to Repair Notwithstanding the terms of Section 11.1 of this Lease, Landlord may elect not to rebuild and/or restore the Premises, Building and/or Project, in which event this Lease shall terminate, by notifying Tenant in writing of such termination within sixty (60) days after the date of discovery of the damage, such notice will include a termination date giving Tenant sixty (60) days to vacate the Premises, but this Lease may be so terminated Landlord may so elect only if the Building or Project shall be damaged by fire or other casualty or cause, whether or not the Premises are affected, and one or more of the following conditions is present: (i) in Landlord’s reasonable judgment, repairs cannot reasonably be completed within one hundred eighty (180) days after the date of discovery of the damage (when such repairs are made without the payment of overtime or other premiums); (ii) the holder of any mortgage on the Building or Project or ground lessor with respect to the Building or Project shall require that the insurance proceeds or any portion thereof be used to retire the mortgage debt, or shall terminate the ground lease, as the case may be; (iii) the damage is not fully covered by Landlord’s insurance policies or that portion of the proceeds from Landlord’s insurance policies allocable to the Building or the Project, as the case may be; (iv) Landlord decides to rebuild the Building or Common Areas so that they will be substantially different structurally or architecturally; (v) the damage occurs during the last twelve (12) months of the Lease Term; or (vi) any owner of any other portion of the Project, other than Landlord, does not intend to repair the damage to such portion of the Project; provided, however, that if such fire or other casualty shall have damaged the Premises or a portion thereof or Common Areas necessary to Tenant’s occupancy and as a result of such damage the Premises are unfit for occupancy, and provided that Landlord does not elect to terminate this Lease pursuant to Landlord’s termination right as provided above, and either (a) the repairs cannot, in the reasonable opinion of Landlord’s contractor, be completed within two hundred seventy (270) days after being commenced, or (b) the damage occurs during the last twelve months of the Lease Term and will reasonably require in excess of ninety (90) days to repair, Tenant may elect, no earlier than sixty (60) days after the date of the damage and not later than ninety (90) days after the date of such damage, to terminate this Lease by written notice to Landlord effective as of the date specified in the notice, which date shall not be less than thirty (30) days nor more than sixty (60) days after the date such notice is given by Tenant.

  • Construction of Tenant Improvements by Tenants Agents Construction Contract; Cost Budget. Prior to Tenant's execution of ---------------------------------- the construction contract and general conditions with Contractor (the "Contract"), Tenant shall submit the Contract to Landlord for its approval, which approval shall not be unreasonably withheld or delayed. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, of the final costs to be incurred, or which have been incurred, as set forth more particularly in Sections 2.2.1.1 through ---------------- 2.2.1.8 above, in connection with the design and construction of the Tenant ------- Improvements to be performed by or at the direction of Tenant or the Contractor (which costs form a basis for the amount of the Contract, if any (the "Final Costs"). Prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with a completion bond in an amount equal to the Final Costs to ensure Landlord of the completion of the Tenant Improvements.

  • LANDLORD'S SERVICES Provided Tenant is not in default hereunder, Landlord shall, at Landlord's expense, except as provided to the contrary in this Lease, furnish to Tenant the following services:

  • Tenant's Responsibility Landlord shall not be liable to Tenant or to any other person for (i) damage to property or injury or death to persons due to the condition of the Leased Premises, the Building or the common areas, or (ii) the occurrence of any accident in or about the Leased Premises or the common areas, or (iii) any act or neglect of Tenant or any other tenant or occupant of the Building or of any other person, unless such damage, injury or death is directly and solely the result of Landlord's negligence; and Tenant hereby releases Landlord from any and all liability for the same. Tenant shall be liable for, and shall indemnify and defend Landlord from, any and all liability for (i) any act or neglect of Tenant and any person coming on the Leased Premises or common areas by the license of Tenant, express or implied, (ii) any damage to the Leased Premises, and (iii) any loss of or damage or injury to any person (including death resulting therefrom) or property occurring in, on or about the Leased Premises, regardless of cause, except for any loss or damage covered by Landlord's all risk coverage insurance as provided in Section 8.02 and except for that caused solely and directly by Landlord's negligence. This provision shall survive the expiration or earlier termination of this Lease.

  • Landlord's Responsibility During the term of this Lease, Landlord shall maintain in good condition and repair, and replace as necessary, the roof, exterior walls, foundation and structural frame of the Building and the parking and landscaped areas, the costs of which shall be included in Operating Expenses; provided, however, that to the extent any of the foregoing items require repair because of the negligence, misuse, or default of Tenant, its employees, agents, customers or invitees, Landlord shall make such repairs solely at Tenant's expense.

  • Landlord’s Retention of Contractor Landlord shall independently retain the Contractor to perform the Tenant Improvement Work in accordance with the Approved Construction Drawings.

  • Time of the Essence in This Tenant Work Letter Unless otherwise indicated, all references herein to a “number of days” shall mean and refer to calendar days. If any item requiring approval is timely disapproved by Landlord, the procedure for preparation of the document and approval thereof shall be repeated until the document is approved by Landlord.

Time is Money Join Law Insider Premium to draft better contracts faster.