Weather Days. A. Weather days are excusable delays. When weather conditions at the site prevent work from proceeding, immediately notify the Owner’s Project Manager for confirmation of the conditions. At the end of each calendar month, submit to the Owner’s Project Manager a list of Weather Days occurring in that month along with documentation of the impact on critical activities. Based on confirmation by the Owner’s Project Manager, any time extension granted will be issued by Change Order. If the Contractor and Owner cannot agree on the time extension, the Owner may issue a Unilateral Change Order for fair and reasonable time extension.
Weather Days i. No additional time will be granted for weather days associated with this Contract. All Work must be completed by the specified Contract dates, including the dates for each phase and milestone. However, weather events that are exceptionally irregular are excluded. An exceptional weather event shall be defined as an event that prevents work on one (1) or more critical path activities within the baseline schedule for ten (10) or more consecutive planned workdays. The eleventh (11th) consecutive planned workday prevented from occurring by an exceptional irregular weather event shall be grounds for requesting a time extension.
Weather Days. Adverse Weather conditions are those wherein the weather satisfies all of the following conditions: (1) unusually severe precipitation, sleet, snow, hail, heat, or cold conditions in excess of the norm for the location and time of year it occurred, (2) unanticipated, and (3) at the Project. Delays due to Adverse Weather will only be permitted in compliance with any applicable provisions in the Agreement and only if the number of days of Adverse Weather exceeds the following parameters and Contractor can verify that the excess days of Adverse Weather caused delays: January 6 July 0 February 7 August 0 March 5 September 1 April 3 October 2 May 2 November 2 June 1 December 4
Weather Days. Management retains sole discretion to define what is considered a weather day/emergency. If the Executive Director and/or their designee determine there is a weather emergency, employees unable to work their scheduled shift may be eligible to receive payment for that shift with the approval of their Director of Residential Services. Employees will not be denied coverage in an arbitrary, capricious or discriminatory manner. An employee working during a weather emergency, they will receive time and one half for hours worked over sixteen (16) hours. A weather day is a day where schools or other community programs may close, outings may be cancelled, driving may not be safe and NCYF may consider grounding agency vans. A weather emergency is when the state governor declares a “state of emergency” that affects the geographic area that encompasses our group homes. In a weather emergency issued by the governor, the Executive Director and/or their designee will ultimately determine a weather emergency for the agency. If a state of emergency is called and confirmed by the Ex Dir all vehicles will be grounded and only used if Ex Dir states that the transport is an emergency and necessary. If a client has a scheduled home visit during a weather day or a weather emergency, NCYF agrees to contact DCF (Department of Children and Families) and/or guardian, to consider adjustments to the visit schedules.
Weather Days. The Contractor shall submit a written request to the City Project Manager (email is the preferred method) for additional days for which work is suspended or delayed by weather. Weather days shall be reconciled with each monthly pay application for the time period in which the application is submitted and shall be final. Contractor performance and execution of work will be considered in the determination for granting additional days.
Weather Days. The EMP proposal shall include in its assumptions and clarifications the number of "weather days" that are included as an allowance in the proposed schedule and Amendment No. 1 shall specify the agreed number of weather days. Weather impacts will only constitute Excusable Delays to the extent they exceed the allowance in Amendment No. 1 and otherwise meet the criteria for an Excusable Delay.
Weather Days. Under extreme weather conditions or an unplanned emergency event, if Cornerstone elects to close a facility or department and employees are told not to report for work, such days shall be with pay but only for those who are scheduled to work on a date of closure. Payment for such days shall be limited to two days per calendar year. If it is possible for an employee to work from home on a weather day and if that employee was otherwise scheduled to work that day, then that employee will work their normal shift from home on that day.
Weather Days. When weather emergencies exist, the Executive Director shall make the decision as to whether or not the Authority offices will be closed. If the Authority offices are closed, critical personnel as designated by the Dept. Head may be called in. Decision shall be promulgated according to the phone method, as well as on the radio stations authorized. If the Executive Director or designee declares an emergency on a Saturday or Sunday, the Water Treatment Operator/SCADA Technician on duty shall be eligible for compensatory time for the shift covered by the weather emergency. Critical personnel who are called in and work will receive a full day's pay plus a compensatory day which may be used in conjunction with, or in lieu of, vacation, sick or personal days. If the Water Treatment Operator/SCADA Technician is scheduled to take over the shift at the time critical personnel are called in, he will also be eligible for compensatory time. Compensatory time may be taken during the period March 15 - November 15. Non-critical personnel will receive a full day's pay. Field personnel will be called by 6:00 a.m. to inform them of closing.
Weather Days. Contractor shall submit a written request to the City Project Manager (e-mail is the preferred method) for additional days for which work is suspended or delayed by weather. Contractor performance and execution of work will be considered in the determination for granting additional days. 3. Point repairs will be paid per stick 14LF of pipe. If 2’ of pipe is used, a full stick will be paid for. If 16’ of pipe is used, 2 sticks of pipe will be paid for. A - 1 Exhibit A – SCOPE OF WORK CONTRACT# CIP/220762
Weather Days. Contractor shall submit a written request to the City Project Manager (email is the preferred method) for additional days for which work is suspended or delayed by weather. Weather days shall be reconciled with each monthly pay application for the time period which the application is submitted and shall be final. Contractor performance and execution of work will be considered in the determination for granting additional days. Exhibit B - Price Proposal EnviroWaste Services Group, Inc Item # Description and Pipe Size Unit of Measure Unit Cost 1 Video Inspection of Pipes (12-30 inch) LF $0.49 2 Video Inspection of Pipes (36-48 inch) LF $0.49 3 Video Inspection of Pipes (54-72 inch) LF $0.99 Optional Items (will be ordered as needed by the City) Item # Description Unit of Measure Unit Cost 2 Medium Cleaning (15-18 inch) LF $5.00 3 Heavy Cleaning (15-18 inch) LF $7.00 4 Light Cleaning (24-42 inch) LF $7.50 5 Medium Cleaning (24-42 inch) LF $9.00 6 Heavy Cleaning (24-42 inch) LF $12.00 7 Light Cleaning (48-60 inch) LF $13.00 8 Medium Cleaning (48-60 inch) LF $18.00 9 Heavy Cleaning (48-60 inch) LF $22.00 10 Light Cleaning (66-72 inch) LF $21.00 11 Medium Cleaning (66-72 inch) LF $30.00 12 Heavy Cleaning (66-72 inch) LF $45.00 Grouting 13 4 joints or less (15 inch) Per Joint $100.00 14 5 joints or more (15 inch) Per Joint $95.00 15 4 joints or less (18 inch) Per Joint $115.00 16 5 joints or more (18 inch) Per Joint $110.00 17 4 joints or less (24 inch) Per Joint $150.00 18 5 joints or more (24 inch) Per Joint $145.00 Optional Items (will be ordered as needed by the City) Item # Description Unit of Measure Unit Cost
