Cost Estimate An estimate of the total project cost including but not limited to direct expenses, indirect expenses, land cost, and capital expenses.
Estimated Cost Estimated costs by construction phases for Specified Roads listed in A7 are stated by segments in the Schedule of Items. Such estimated costs are subject to adjustment under B3.3, B5.2, B5.21, B5.212, B5.25, and B5.26. Appropriately adjusted costs shall be made a part of a revised Schedule of Items and shown as adjustments to Timber Sale Account. The revised Schedule of Items shall supersede any prior Schedule of Items when it is dated and signed by Contracting Officer and a copy is furnished to Purchaser.
Cost Estimates If this Agreement pertains to the design of a public works project, CONSULTANT shall submit estimates of probable construction costs at each phase of design submittal. If the total estimated construction cost at any submittal exceeds ten percent (10%) of CITY’s stated construction budget, CONSULTANT shall make recommendations to CITY for aligning the PROJECT design with the budget, incorporate CITY approved recommendations, and revise the design to meet the Project budget, at no additional cost to CITY.
Estimated Costs The proposed GMP Change Order shall include separately identified dollar amounts, stated as fixed sums, for Actual Costs as estimated by the Design-Builder for the complete construction of the Project, which amount shall include the all Trade Contract and Subcontract Sums, costs of materials, and any Component Change Order Sums;
Project Cost a. The estimated cost of the Project is $ 97,740.00. This amount is based upon the Schedule of Financial Assistance in Exhibit "B", attached to and incorporated in this Agreement. Exhibit “B” may be modified by mutual execution of an amendment as provided for in paragraph 5.i.
Statement of Estimated Direct Expenses In addition, Landlord shall give Tenant a yearly expense estimate statement (the “Estimate Statement”) which shall set forth Landlord’s reasonable estimate (the “Estimate”) of what the total amount of Direct Expenses for the then-current Expense Year shall be and the estimated Tenant’s Share of Direct Expenses (the “Estimated Direct Expenses”). The failure of Landlord to timely furnish the Estimate Statement for any Expense Year shall not preclude Landlord from enforcing its rights to collect any Estimated Direct Expenses under this Article 4, nor shall Landlord be prohibited from revising any Estimate Statement or Estimated Direct Expenses theretofore delivered to the extent necessary. Thereafter, Tenant shall pay, with its next installment of Base Rent due that is at least thirty (30) days thereafter, a fraction of the Estimated Direct Expenses for the then-current Expense Year (reduced by any amounts paid pursuant to the last sentence of this Section 4.4.2). Such fraction shall have as its numerator the number of months which have elapsed in such current Expense Year, including the month of such payment, and twelve (12) as its denominator. Until a new Estimate Statement is furnished (which Landlord shall have the right to deliver to Tenant at any time), Tenant shall pay monthly, with the monthly Base Rent installments, an amount equal to one-twelfth (1/12) of the total Estimated Direct Expenses set forth in the previous Estimate Statement delivered by Landlord to Tenant.
Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shall submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the general conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over-Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (i), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease.
Estimate The Engineer shall independently develop and report quantities necessary to construct the contract in standard State bid format at the specified milestones and Final PS&E submittals. The Engineer shall prepare each construction cost estimates using Estimator or any approved method. The estimate shall be provided at each milestone submittal or in DCIS format at the 95% and Final PS&E submittals per State’s District requirement.
Total Project Cost The total cost of the Project is $36,378,683, of which (i) a match is being contributed in the amount of $21,000,000 shall be Matching Funds, and (ii) $15,378,683 shall be provided by the Grant. The total estimated cost of the Project is based upon the Budget. To the extent that the actual cost of the Project exceeds $36,378,683, Grantee shall be solely responsible for such excess. Grantee shall monitor the Budget and submit an amended Budget to Triumph in the event that (a) the total cost of the Project increases or decreases by greater than five percent (5%), (b) total the Budget increases or decreases by greater than five percent (5%), (c) the Budget increases or decreases by greater than five percent (5%) within a particular Budget category, and/or (d) Grantee’s portion of the Matching funds decreases by greater than five percent (5%). If Grantee proposes an increase or decrease by greater than five percent (5%) as described above as compared to the most recently approved Budget, such proposal shall be submitted to Triumph in writing along with a proposed amended Budget, and Triumph shall have the right to approve or disapprove both the proposed Budget category increase or decrease and the proposed amended Budget. If Grantee fails to obtain Triumph's approval, that failure shall be sufficient cause for nonpayment by Triumph as provided in Section 4.2(f). Using the Grant, its own funds, and funds from other sources (including, but not limited to, the Matching Funds), Grantee agrees to bear the entire cost and expense of the Project, including but not limited to, all costs and all expenses in excess of the total estimated cost of the Project, it being expressly understood and agreed that the Grant shall operate only to pay, on and subject to the terms and conditions set forth herein, a portion of the costs and expenses of the Project. Furthermore, Grantee agrees to spend all of the Matching Funds as contemplated in the Budget, and agrees that its failure to do so shall be deemed a material breach of this Agreement.
Construction Cost Budget The total cost to District of all elements of the Project designed or specified by the Architect, as adjusted during and at the end of the design phase in accordance with this Agreement and the Agreement for Architectural Services. The Construction Cost Budget does not include the compensation of the Project Design Team, the Program Manager (if any), the Construction Manager and any subconsultants, the cost of the land, rights-of-way, or financing which are the responsibility of the District.
