Aircraft The Airframe to be sold by AVSA to the Owner Trustee as provided in the Participation Agreement and to be leased under the Lease (or any permitted substitute airframe thereunder) together with two Engines (whether either is an initial Engine or a Replacement Engine) whether or not any of such initial or Replacement Engines may from time to time be installed on such Airframe or may be installed on any other airframe or on any other aircraft, including any aircraft substituted pursuant to Section 11.03
Lease of Aircraft Lessor agrees to lease the Aircraft to Lessee pursuant to the provisions of FAR Section 91.501(b)(6) and Section 91.501(c)(1) and this Agreement, and to provide a fully-qualified and credentialed flight crew for all flights to be conducted hereunder during the Term (as defined in Section 13) hereof. The parties acknowledge and agree that this Agreement did not result in any way from any direct or indirect advertising, holding out or soliciting on the part of Lessor or any person purportedly acting on behalf of Lessor. Lessor and Lessee intend that the lease of the Aircraft effected by this Agreement shall be treated as a “wet lease” pursuant to which Lessor provides transportation services to Lessee in accordance with FAR Section 91.501(b)(6) and Section 91.501(c)(1).
Condition of Aircraft The Aircraft at the time of its return to Lessor shall have been maintained and repaired in accordance with the Approved Maintenance Program and this Lease with the same care and consideration for the technical condition of the Aircraft as if it were to have been kept in continued regular service by the Lessee, and shall meet the following requirements:
Return of Aircraft 64 23.1 Date of Return................................................64 23.2
Return of Aircraft, Etc (a) If an Event of Default shall have occurred and be continuing and the Equipment Notes have been accelerated, subject to Section 4.03 hereof and unless the Owner Trustee or the Owner Participant shall have elected to purchase the Equipment Notes, at the request of the Mortgagee, the Owner Trustee shall promptly execute and deliver to the Mortgagee such instruments of title and other documents as the Mortgagee may deem necessary or advisable to enable the Mortgagee or an agent or representative designated by the Mortgagee, at such time or times and place or places as the Mortgagee may specify, to obtain possession of all or any part of the Mortgaged Property included in the Trust Indenture Estate to which the Mortgagee shall at the time be entitled hereunder. If the Owner Trustee shall for any reason fail to execute and deliver such instruments and documents after such request by the Mortgagee, the Mortgagee may (i) obtain a judgment conferring on the Mortgagee the right to immediate possession and requiring the Owner Trustee to execute and deliver such instruments and documents to the Mortgagee, to the entry of which judgment the Owner Trustee hereby specifically consents to the fullest extent permitted by Law, and (ii) pursue all or part of such Mortgaged Property wherever it may be found and, in the event that a Lease Event of Default has occurred and is continuing, may enter any of the premises of Lessee wherever such Mortgaged Property may be or be supposed to be and search for such Mortgaged Property and take possession of and remove such Mortgaged Property. All expenses of obtaining such judgment or of pursuing, searching for and taking such property shall, until paid, be secured by the Lien of this Trust Indenture.
Delivery; Acceptance of Premises; Commencement Date Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date, with Landlord’s Work Substantially Completed (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 90 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Landlord or Tenant by written notice to the other, and if so terminated by either: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms “Landlord’s Work,” “Tenants’ Work,” and “Force Majeure Delays” shall have the meanings set forth for such terms in the Work Letter. If neither Landlord nor Tenant elects to void this Lease within 10 business days of the lapse of such 90 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect; provided, however, that if Landlord does not Deliver the Premises within 150 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Tenant by written notice to Landlord, in which case subsections (a) and (b) of this paragraph shall apply. If Tenant does not elected to void this Lease within 10 business days of the lapse of such 150 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect.
Scheduled Maintenance No later than March 1, 2001, Seller shall submit to Buyer a proposed schedule of Scheduled Maintenance Outages scheduled by Seller for the following Contract Year for the Units, which schedule shall be updated by Seller by each March 31 and September 30 thereafter to cover the twelve month period following each such update; provided, however, that no Scheduled Maintenance Outage may be scheduled to cover the period from May 15 to September 15. Parameters within which Scheduled Maintenance Outages must be planned are included as Appendix I. If the OEM issues recommendations for changes to the parameters in Appendix I, the parties shall negotiate in good faith to revise Appendix I accordingly. Such schedule, and each supplement thereto, shall indicate the planned start and completion dates for each Scheduled Maintenance Outage during the period covered thereby and the amount of the Net Dependable Capacity of a Unit that will be affected. Within thirty (30) days of receipt of such schedule or any supplement thereto, Buyer may request reasonable modifications in the Scheduled Maintenance Outage schedule contained therein. Both parties agree to use reasonable efforts to develop a mutually acceptable final schedule for such Scheduled Maintenance Outages. If within six months prior to the scheduled start of a Scheduled Maintenance Outage, Buyer desires to change the scheduled start or duration of such Scheduled Maintenance Outage, Buyer shall notify Seller of Buyer's requested change and Seller shall use reasonable efforts to accommodate Buyer's requested change. Seller may propose compensation from Buyer to Seller for such change. Buyer shall then have the right to either direct such change and pay Seller such compensation, or withdraw the request for such change. At least one week prior to any Scheduled Maintenance Outage, Seller shall orally notify Buyer of the expected start date of such Scheduled Maintenance Outage, the amount of Capacity at the Units that will not be available to Buyer during such Scheduled Maintenance Outage, and the expected completion date of such Scheduled Maintenance Outage. Seller shall orally notify Buyer of any subsequent changes in such Capacity not available or any subsequent changes in the Scheduled Maintenance Outage completion date. As soon as practicable, all such oral notifications shall be confirmed in writing. Scheduled Maintenance Outages may be taken in any number of non-contiguous periods, subject to Buyer's approval, which shall not be unreasonably withheld or delayed. Subject to the foregoing, the duration, frequency and timing of Scheduled Maintenance Outages shall be based on OEM recommendations and the age and operation of the Units generally plus up to five (5) days per Unit on a semi-annual basis for Non-Summer Period balance of plant maintenance.
Maintenance of Aircraft Lessor shall be solely responsible for securing maintenance, preventive maintenance and inspections of the Aircraft (utilizing an inspection program listed in FAR Section 91.409(f)), and shall take such requirements into account in scheduling the Aircraft hereunder.
Aircraft Basic Price The Aircraft Basic Price is listed in Table 1 and is subject to escalation in accordance with the terms of this Purchase Agreement.
Airframe The Airbus A300F4-605R aircraft (excluding the Engines or engines from time to time installed thereon) to be leased by the Lessor to the Lessee pursuant to the Lease and the initial Lease Supplement and having the United States FAA Registration Number initially and manufacturer's serial number specified in the initial Lease Supplement, including (i) all Parts in respect thereof and (ii) any Replacement Airframe which may be substituted pursuant to Section 11.03
