Protocol No action to coerce or censor or penalize any negotiation participant shall be made or implied by any other member as a result of participation in the negotiation process.
Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.
Tests and Preclinical and Clinical Trials The studies, tests and preclinical and clinical trials conducted by or, to the Company’s knowledge, on behalf of the Company were and, if still ongoing, are being conducted in all material respects in accordance with experimental protocols, procedures and controls pursuant to accepted professional scientific standards and all Authorizations and Applicable Laws, including, without limitation, the Federal Food, Drug and Cosmetic Act and the rules and regulations promulgated thereunder (collectively, “FFDCA”); the descriptions of the results of such studies, tests and trials contained in the Registration Statement, the General Disclosure Package and the Prospectus are, to the Company’s knowledge, accurate in all material respects and fairly present the data derived from such studies, tests and trials; except to the extent disclosed in the Registration Statement, the General Disclosure Package and the Prospectus, the Company is not aware of any studies, tests or trials, the results of which the Company believes reasonably call into question the study, test, or trial results described or referred to in the Registration Statement, the General Disclosure Package and the Prospectus when viewed in the context in which such results are described and the clinical state of development; and, except to the extent disclosed in the Registration Statement, the General Disclosure Package or the Prospectus, neither the Company nor any Subsidiary has received any notices or correspondence from the FDA or any Governmental Entity requiring the termination or suspension of any studies, tests or preclinical or clinical trials conducted by or on behalf of the Company, other than ordinary course communications with respect to modifications in connection with the design and implementation of such trials, copies of which communications have been made available to you.
Clinical Trials The studies, tests and preclinical and clinical trials conducted by or on behalf of, or sponsored by, the Company, or in which the Company has participated, that are described in the Registration Statement, the Time of Sale Disclosure Package or the Prospectus, or the results of which are referred to in the Registration Statement, the Time of Sale Disclosure Package or the Prospectus, were and, if still pending, are being conducted in all material respects in accordance with protocols, procedures and controls pursuant to, where applicable, accepted professional and scientific standards for products or product candidates comparable to those being developed by the Company and all applicable statutes, rules and regulations of the FDA, the EMEA, Health Canada and other comparable drug and medical device (including diagnostic product) regulatory agencies outside of the United States to which they are subject; the descriptions of the results of such studies, tests and trials contained in the Registration Statement, the Time of Sale Disclosure Package or the Prospectus do not contain any misstatement of a material fact or omit a material fact necessary to make such statements not misleading; the Company has no knowledge of any studies, tests or trials not described in the Disclosure Package and the Prospectus the results of which reasonably call into question in any material respect the results of the studies, tests and trials described in the Registration Statement, the Time of Sale Disclosure Package or Prospectus; and the Company has not received any notices or other correspondence from the FDA, EMEA, Health Canada or any other foreign, state or local governmental body exercising comparable authority or any Institutional Review Board or comparable authority requiring or threatening the termination, suspension or material modification of any studies, tests or preclinical or clinical trials conducted by or on behalf of, or sponsored by, the Company or in which the Company has participated, and, to the Company’s knowledge, there are no reasonable grounds for the same. Except as disclosed in the Registration Statement, the Time of Sale Disclosure Package and the Prospectus, there has not been any violation of law or regulation by the Company in its respective product development efforts, submissions or reports to any regulatory authority that could reasonably be expected to require investigation, corrective action or enforcement action.
Compatibility 1. Any unresolved issue arising from a mutual agreement procedure case otherwise within the scope of the arbitration process provided for in this Article and Articles 25A to 25G shall not be submitted to arbitration if the issue falls within the scope of a case with respect to which an arbitration panel or similar body has previously been set up in accordance with a bilateral or multilateral convention that provides for mandatory binding arbitration of unresolved issues arising from a mutual agreement procedure case.
Validation To validate the notice requirements outlined in Section 5.3, the Assuming Institution shall provide the Receiver (i) an Affidavit of Publication to meet the publication requirements outlined in Section 5.3(a) and (ii) the Assuming Institution will prepare an Affidavit of Mailing in a form substantially similar to Exhibit 2.3B after mailing the seven (7) day Notice to Depositors as required under Section 5.3(b).
Clinical Data and Regulatory Compliance The preclinical tests and clinical trials, and other studies (collectively, “studies”) that are described in, or the results of which are referred to in, Registration Statement, the Pricing Disclosure Package or the Prospectus were and, if still pending, are being conducted in all material respects in accordance with applicable laws, rules, regulations and policies of the Food and Drug Administration of the U.S. Department of Health and Human Services (the “FDA”) or any committee thereof or of any other U.S. or foreign government or drug or medical device regulatory agency, or health care facility Institutional Review Board; each description of the results of such studies is accurate and complete in all material respects and fairly presents the data derived from such studies, and the Company and its subsidiaries have no knowledge of any other studies the results of which are materially inconsistent with, or otherwise call into question, the results described or referred to in the Registration Statement, the Pricing Disclosure Package or the Prospectus; for such studies that have been or are being conducted, the Company and its subsidiaries have made all such filings and obtained all such approvals as may be required by foreign government or drug or medical device regulatory agencies, or foreign health care facility Institutional Review Boards; and no investigational new drug application filed by or on behalf of the Company or any of its subsidiaries with the FDA has been terminated or suspended by the FDA, and neither the FDA nor any applicable foreign regulatory agency has commenced, or, to the knowledge of the Company, threatened to initiate, any action to place a clinical hold order on, or otherwise terminate, delay or suspend, any proposed or ongoing studies conducted or proposed to be conducted by or on behalf of the Company or any of its subsidiaries.
Labeling Upon request, Lessee will xxxx the Equipment indicating Lessor's interest with labels provided by Lessor. Lessee will keep all Equipment free from any other marking or labeling which might be interpreted as a claim of ownership.
