Payment of Liquidated Damages With respect to any Liquidated Damages that accrue, Owner shall invoice Contractor for such Liquidated Damages. Contractor shall pay such Liquidated Damages within ten (10) Days after Contractor’s receipt of such invoice. To the extent Contractor does not pay such Liquidated Damages within such ten (10) Day period, Owner may, at its option, do one or more of the following: (i) withhold from Contractor amounts that are otherwise due and payable to Contractor in the amount of such Liquidated Damages and/or (ii) collect on the Letter of Credit in the amount of such Liquidated Damages. For the avoidance of doubt, prior to exercising such right to withhold or collect on the Letter of Credit, Owner shall not be required to provide the notice as set forth in Section 7.8. As used in this Agreement, Liquidated Damages are “paid” if and to the extent Owner exercises option (i) or (ii) above for the collection of Liquidated Damages.
Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.
Seller Default If a Seller, prior to the Closing, defaults in its representations, warranties, covenants, or obligations under this Agreement, including to sell its Property as required by this Agreement and such default continues for more than ten (10) days after written notice from Purchaser, then, at Purchaser’s election, Purchaser may either (i) if Purchaser has closed on the remaining Properties for which there has been no default alleged, seek specific performance of the defaulting Seller’s obligations pursuant to this Agreement (but not damages); or (ii) give a Termination Notice to Sellers’ Representative of Purchaser’s decision to terminate this Agreement for the Properties for which there was such a default, proceed to Closing on the remaining Properties, and the applicable Seller shall pay to Purchaser an amount equal to the Applicable Share of the Deposit for the terminated Properties, Return on Deposit on the Applicable Share amount (or credit the same to Purchaser against the Base Purchase Price for the other Properties for which this Agreement has not been terminated), an amount equal to the actual third party costs incurred by Purchaser relating to breaking Purchaser’s rate lock with respect to the terminated Properties (provided Sellers’ liability for such costs to Purchaser related to breaking the rate lock shall not exceed $2,000,000 in the aggregate regardless of the number of terminated Properties), and, if Sellers’ default under this Agreement resulted from an intentional action or inaction of Sellers taken in bad faith (excluding any action or inaction a Seller reasonably takes or refuses to take in response to a request or requirement of any Lender) that causes one (1) or more of the Closings not to occur solely as a result of such action or inaction, a termination fee of $8,000,000 (the “Termination Fee”) (provided Purchaser has otherwise performed it obligations under this Agreement with respect to the other remaining Properties, including delivery of the Purchase Price therefor, and Sellers have been afforded notice and an opportunity to cure as provided above but have failed to so cure). The amount of the Termination Fee that may be collected by Purchaser shall be limited to $8,000,000, regardless of the number of Sellers alleged to have defaulted hereunder. Purchaser shall be entitled to execute on the Guaranty for any of the Applicable Share of the Deposit, Return on Deposit, and Termination Fee if the same are not returned within one (1) day after termination of the Agreement with respect to the Property or Properties in question.
Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Hxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.
Buyer Default If Buyer defaults under this Contract after the Review Period, and such default continues for thirty (30) days following written notice from Seller (provided no notice shall extend the time for Closing), then at Seller’s election by written notice to Buyer, this Contract shall be terminated and of no effect, in which event the Xxxxxxx Money Deposit, including any interest thereon, shall be paid to and retained by the Seller as Seller’s sole and exclusive remedy hereunder, and as liquidated damages for Buyer’s default or failure to close, and both Buyer and Seller shall thereupon be released from all obligations hereunder.
Seller’s Default Should the Sellers fail to give Notice of Readiness in accordance with Clause 5 a) or fail to be ready to validly complete a legal transfer by the date stipulated in line 61 the Buyers shall have the option of cancelling this Agreement provided always that the Sellers shall be granted a maximum of 3 banking days after Notice of Readiness has been given to make arrangements for the documentation set out in Clause 8. If after Notice of Readiness has been given but before the Buyers have taken delivery, the Vessel ceases to be physically ready for delivery and is not made physically ready again in every respect by the date stipulated in line 61 and new Notice of Readiness given, the Buyers shall retain their option to cancel. In the event that the Buyers elect to cancel this Agreement the deposit together with interest earned shall be released to them immediately. Should the Sellers fail to give Notice of Readiness by the date stipulated in line 61 or fail to be ready to validly complete a legal transfer as aforesaid they shall make due compensation to the Buyers for their loss and for all expenses together with interest if their failure is due to proven negligence and whether or not the Buyers cancel this Agreement.
Purchaser Default If Purchaser defaults in its obligations hereunder to (a) deliver the Deposit, or (b) deliver the Purchase Price for each Property at the time required by Section 2.2.4 and, as a result, does not close on the purchase of the Properties on the Closing Date, then, immediately and without notice or cure, Purchaser shall forfeit the Deposit and neither party shall be obligated to proceed with the purchase and sale of the Properties. If Purchaser defaults in any of its other representations, warranties or obligations under this Agreement (including, without limitation, the failure to deliver to Escrow Agent the deliveries specified under Section 6.4 on the date required thereunder), and such default continues for more than ten (10) days after written notice from Sellers’ Representative, then Purchaser shall forfeit the Deposit and neither party shall be obligated to proceed with the purchase and sale of the Property. The Deposit constitutes liquidated damages and recourse to the Deposit is, except for Purchaser’s indemnity and confidentiality obligations hereunder, Sellers’ sole and exclusive remedy for Purchaser’s failure to perform its obligation to purchase the Properties or any breach of a representation or warranty by Purchaser hereunder. Sellers expressly waive the remedies of specific performance and additional damages for any default by Purchaser hereunder. SELLERS AND PURCHASER ACKNOWLEDGE THAT SELLERS’ DAMAGES WOULD BE DIFFICULT TO DETERMINE, AND THAT THE DEPOSIT IS A REASONABLE ESTIMATE OF SELLERS’ DAMAGES RESULTING FROM A DEFAULT BY PURCHASER IN ITS OBLIGATION TO PURCHASE THE PROPERTY. SELLERS AND PURCHASER FURTHER AGREE THAT THIS SECTION 11.1 IS INTENDED TO AND DOES LIQUIDATE THE AMOUNT OF DAMAGES DUE SELLERS, AND SHALL BE SELLERS’ EXCLUSIVE REMEDY AGAINST PURCHASER, BOTH AT LAW AND IN EQUITY, ARISING FROM OR RELATED TO A BREACH BY PURCHASER OF ITS OBLIGATION TO CONSUMMATE THE TRANSACTIONS CONTEMPLATED BY THIS AGREEMENT, OTHER THAN WITH RESPECT TO PURCHASER’S INDEMNITY AND CONFIDENTIALITY OBLIGATIONS HEREUNDER.
Waiver of Liquidated Damages If the Partnership is unable to cause a Registration Statement to become effective on or before the Target Effective Date, then the Partnership may request a waiver of the Liquidated Damages, which may be granted by the consent of the Holders of at least the Registrable Securities Required Voting Percentage, in their sole discretion, and which such waiver shall apply to all the Holders of Registrable Securities included on such Registration Statement.
Buyer’s Default Should the deposit not be paid in accordance with Clause 2, the Sellers have the right to cancel this Agreement, and they shall be entitled to claim compensation for their losses and for all expenses incurred together with interest. Should the Purchase Price not be paid in accordance with Clause 3, the Sellers have the right to cancel the Agreement, in which case the deposit together with interest earned shall be released to the Sellers. If the deposit does not cover their loss, the Sellers shall be entitled to claim further compensation for their losses and for all expenses incurred together with interest.
Default Payment Following the occurrence and during the continuance of an Event of Default, the Holder, at its option, may demand repayment in full of all obligations and liabilities owing by Company to the Holder under this Note, the Purchase Agreement and/or any other Related Agreement and/or may elect, in addition to all rights and remedies of the Holder under the Purchase Agreement and the other Related Agreements and all obligations and liabilities of the Company under the Purchase Agreement and the other Related Agreements, to require the Company to make a Default Payment (“Default Payment”). The Default Payment shall be 130% of the outstanding principal amount of the Note, plus accrued but unpaid interest, all other fees then remaining unpaid, and all other amounts payable hereunder. The Default Payment shall be applied first to any fees due and payable to the Holder pursuant to this Note, the Purchase Agreement, and/or the other Related Agreements, then to accrued and unpaid interest due on this Note and then to the outstanding principal balance of this Note. The Default Payment shall be due and payable immediately on the date that the Holder has exercised its rights pursuant to this Section 2.3.
