Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
EDD Independent Subrecipient Reporting Requirements Effective January 1, 2001, the County of Orange is required to file in accordance with subdivision (a) of Section 6041A of the Internal Revenue Code for services received from a “service provider” to whom the County pays $600 or more or with whom the County enters into a contract for $600 or more within a single calendar year. The purpose of this reporting requirement is to increase child support collection by helping to locate parents who are delinquent in their child support obligations. The term “service provider” is defined in California Unemployment Insurance Code Section 1088.8, Subparagraph B.2 as “an individual who is not an employee of the service recipient for California purposes and who received compensation or executes a contract for services performed for that service recipient within or without the State.” The term is further defined by the California Employment Development Department to refer specifically to independent Subrecipients. An independent Subrecipient is defined as “an individual who is not an employee of the ... government entity for California purposes and who receives compensation or executes a contract for services performed for that ... government entity either in or outside of California.” The reporting requirement does not apply to corporations, general partnerships, limited liability partnerships, and limited liability companies. Additional information on this reporting requirement can be found at the California Employment Development Department web site located at xxxx://xxx.xxx.xx.xxx/Employer_Services.htm
Child Abuse Reporting Requirements A. Grantees shall comply with child abuse and neglect reporting requirements in Texas Family Code Chapter 261. This section is in addition to and does not supersede any other legal obligation of the Grantee to report child abuse.
Training Requirements Grantee shall:
Certain State Law Requirements for Contracts The contents of this Section are required by Texas Law and are included by County regardless of content.
Additional Reporting Requirements Contractor agrees to submit written quarterly reports to H-GAC detailing all transactions during the previous three (3) month period. Reports must include, but are not limited, to the following information:
EDD Independent Contractor Reporting Requirements Effective January 1, 2001, the County of Orange is required to file in accordance with subdivision (a) of Section 6041A of the Internal Revenue Code for services received from a “service provider” to whom the County pays $600 or more or with whom the County enters into a contract for $600 or more within a single calendar year. The purpose of this reporting requirement is to increase child support collection by helping to locate parents who are delinquent in their child support obligations. The term “service provider” is defined in California Unemployment Insurance Code Section 1088.8, subparagraph B.2 as “an individual who is not an employee of the service recipient for California purposes and who received compensation or executes a contract for services performed for that service recipient within or without the state.” The term is further defined by the California Employment Development Department to refer specifically to independent Contractors. An independent Contractor is defined as “an individual who is not an employee of the ... government entity for California purposes and who receives compensation or executes a contract for services performed for that ... government entity either in or outside of California.” The reporting requirement does not apply to corporations, general partnerships, limited liability partnerships, and limited liability companies. Additional information on this reporting requirement can be found at the California Employment Development Department web site located at xxxx://xxx.xxx.xx.xxx/Employer_Services.htm
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Credentialing Requirements Registry Operator, through the facilitation of the CZDA Provider, will request each user to provide it with information sufficient to correctly identify and locate the user. Such user information will include, without limitation, company name, contact name, address, telephone number, facsimile number, email address and IP address.
Reporting Requirements The Company, during the period when the Prospectus is required to be delivered under the 1933 Act or the 1934 Act, will file all documents required to be filed with the Commission pursuant to the 1934 Act within the time periods required by the 1934 Act and the 1934 Act Regulations.
