Rate Redetermination for Environmental Modification In the event of a contract modification under B8.33 or partial termination under B8.34, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber remaining immediately prior to the revision and the appraised unit value of Included Timber to be cut under the modification. The appraisal shall consider the estimated cost of any construction work listed in the Schedule of Items that was performed and abandoned. Tentative Rates and Flat Rates in effect at the time of the revision will be adjusted by said differences to become Current Contract Rates. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essential reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. However, existing Base Indices shall not be changed under this Subsection. Redetermined rates, or differences for rates subject to B3.2, and Required Deposits shall be considered established under B3.1 for timber Scaled subsequent to the contract revision.
Rate Redetermination for Market Change In the event of delay or interruption, exceeding 90 days, under B8.33, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber immediately prior to the delay or interruption and the appraised unit value of Included Timber immediately after the delay or interruption. The appraisal shall be done after any rate redetermination done pursuant to B3.31, using remaining volumes. Tentative Rates and Flat Rates in effect at the time of delay or interruption or established pursuant to B3.31 will be reduced, if appraised rates declined during the delay or interruption, to become Current Contract Rates. Increases in rates will not be considered. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essential reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. However, existing Base Indices shall not be changed under this Subsection. Redetermined rates shall be considered established under B3.1 for timber Scaled subsequent to the delay or interruption.
Rate Redetermination Rates may be redetermined as set forth in this Section. Bid Premium Rates shall be added to all redetermined rates, except as provided in B3.31, B3.32, and B3.33. Rate redeterminations shall be made in accordance with the standard Forest Service methods in effect 45 days prior to rate redetermination. Such methods shall take into consideration factors that may affect timber value at rate redetermination date. Redetermined rates shall not be less than Base Rates listed in A4, except for reduction under B3.31, B3.32, or B3.33. Required Deposits shall be redetermined. Redetermined Specified Road construction cost is subject to the limitations of B5.26.
ORDER PROCESSING CHARGE H-GAC will apply an Order Processing Charge for each sale done through the H-GAC contract, with the exception of orders for motor vehicles. Any pricing submitted must include this charge amount per the most current H-GAC schedule. For motor vehicle orders, the Processing Charge is paid by the Customer.
SALES AND ORDER PROCESSING CHARGE Contractor shall sell its products to END USERS based on the pricing and terms of this Agreement. H-GAC will invoice Contractor for the applicable order processing charge when H-GAC receives notification of an END USER order. Contractor shall remit to H-GAC the full amount of the applicable order processing charge, after delivery of any product or service and subsequent END USER acceptance. Payment of the Order Processing Charge shall be remitted from Contractor to H-GAC, within thirty (30) calendar days or ten (10) business days after receipt of an END USER’s payment, whichever comes first, notwithstanding Contractor’s receipt of invoice. For sales made by Contractor based on this Agreement, including sales to entities without Interlocal Agreements, Contractor shall pay the applicable order processing charges to H-GAC. Further, Contractor agrees to encourage entities who are not members of H-GAC’s Cooperative Purchasing Program to execute an H-GAC Interlocal Agreement. H-GAC reserves the right to take appropriate actions including, but not limited to, Agreement termination if Contractor fails to promptly remit the appropriate order processing charge to H-GAC. In no event shall H-GAC have any liability to Contractor for any goods or services an END USER procures from Contractor. At all times, Contractor shall remain liable to pay to H-GAC any order processing charges on any portion of the Agreement actually performed, and for which compensation was received by Contractor.
Additional Costs Capital Adequacy (a) If any new law, rule or regulation, or any change after the date hereof in the interpretation or administration of any applicable law, rule or regulation by any governmental authority, central bank or comparable agency charged with the interpretation or administration thereof, or compliance by the Bank (or its applicable lending office) with any request or directive (whether or not having the force of law) of any such authority, central bank or comparable agency in connection therewith issued, promulgated or enacted after the date hereof shall:
Calculation of Borrowing Base For purposes of this Agreement, the “Borrowing Base” shall be determined, as at any date of determination, as the sum of the products obtained by multiplying (x) the Value of each Eligible Portfolio Investment by (y) the applicable Advance Rate; provided that:
Scheduled and Interim Redetermination Procedure (i) Each Scheduled Redetermination and each Interim Redetermination shall be effectuated as follows: Upon receipt by the Administrative Agent of (A) the Reserve Report and the certificate required to be delivered by the Borrower to the Administrative Agent, in the case of a Scheduled Redetermination, pursuant to Section 8.12(a) and (c), and, in the case of an Interim Redetermination, pursuant to Section 8.12(b) and (c), and (B) such other reports, data and supplemental information, including, without limitation, the information provided pursuant to Section 8.12(c), as may, from time to time, be reasonably requested by the Majority Lenders (the Reserve Report, such certificate and such other reports, data and supplemental information being the “Engineering Reports”), the Administrative Agent shall evaluate the information contained in the Engineering Reports and shall, in good faith, propose a new Borrowing Base (the “Proposed Borrowing Base”) based upon such information and such other information (including, without limitation, the status of title information with respect to the Oil and Gas Properties as described in the Engineering Reports and the existence of any other Debt) as the Administrative Agent deems appropriate in its sole discretion and consistent with its normal oil and gas lending criteria as it exists at the particular time. In no event shall the Proposed Borrowing Base exceed the Aggregate Maximum Credit Amounts.
Increased Cost and Reduced Return; Capital Adequacy; Reserves on Eurodollar Rate Loans (a) If any Lender determines that as a result of the introduction of or any change in or in the interpretation of any Law, or such Lender’s compliance therewith, there shall be any increase in the cost to such Lender of agreeing to make or making, funding or maintaining Eurodollar Rate Loans or (as the case may be) issuing or participating in Letters of Credit, or a reduction in the amount received or receivable by such Lender in connection with any of the foregoing (excluding for purposes of this subsection (a) any such increased costs or reduction in amount resulting from (i) Taxes or Other Taxes (as to which Section 3.01 shall govern), (ii) changes in the basis of taxation of overall net income or overall gross income by the United States or any foreign jurisdiction or any political subdivision of either thereof under the Laws of which such Lender is organized or has its Lending Office, and (iii) reserve requirements contemplated by Section 3.04(c)), then from time to time upon demand of such Lender (with a copy of such demand to the Administrative Agent), the Borrower shall pay to such Lender such additional amounts as will compensate such Lender for such increased cost or reduction.
Cost of Living Adjustments Effective December 1, 2021, Compensation Plan salary rates shall be increased by two and five tenths percent (2.5%) but not less than eighty-five dollars ($85) per month (prorated for part-time employees). Effective December 1, 2022, Compensation Plan salary rates shall be increased by three and one tenth percent (3.1%) but not less than one hundred dollars ($100) per month (prorated for part-time employees). (See Appendix C & E.)
