Post-Commercial Operation Date Testing and Modifications Each Party shall at its own expense perform routine inspection and testing of its facilities and equipment in accordance with Good Utility Practice as may be necessary to ensure the continued interconnection of the Large Generating Facility with the Participating TO’s Transmission System in a safe and reliable manner. Each Party shall have the right, upon advance written notice, to require reasonable additional testing of the other Party’s facilities, at the requesting Party’s expense, as may be in accordance with Good Utility Practice.
Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
Construction Period During the construction period, Redeveloper agrees to keep the construction area, including completed operations insured against loss or damage by fire, and such other risks, casualties, and hazards as are customarily covered by builders’ risk or extended coverage policies in an amount not less than the replacement value but allowing for reasonable coinsurance clauses and deductibles. In the event of any insured damage or destruction, Redeveloper agrees to use its good faith efforts to commence restoration of the Private Improvements to its prior condition within nine (9) months from the date of the damage or destruction, and shall diligently pursue the same to completion.
Unbundled Loop Modifications (Line Conditioning 2.5.1 Line Conditioning is defined as routine network modification that BellSouth regularly undertakes to provide xDSL services to its own customers. This may include the removal of any device, from a copper Loop or copper Sub-loop that may diminish the capability of the Loop or Sub-loop to deliver high-speed switched wireline telecommunications capability, including xDSL service. Such devices include, but are not limited to, load coils, excessive bridged taps, low pass filters, and range extenders. Excessive bridged taps are bridged taps that serves no network design purpose and that are beyond the limits set according to industry standards and/or the XxxxXxxxx XX 00000.
Non-Paid Status During Treatment After Positive Test The employee will be in a non-pay status during any absence for evaluation or treatment, while participating in a rehabilitation program.
Project Completion Date It is agreed between the Parties that the Project Completion Date is <END DATE, YEAR>. If the Project is not completed by such date then, subject to an amendment agreed to between the Parties, Alberta Innovates may elect to terminate this Investment Agreement. In such event, Alberta Innovates will notify the Applicant of its decision to terminate as soon as reasonably practical and shall advise the Applicant of the effective date of termination. Alberta Innovates will have no liability or obligation to reimburse the Applicant for any Project Costs incurred after the effective date of termination and may require the Applicant to return any portions of the Investment which were spent on Ineligible Expenses. Additionally, any portion of the Investment not used and accounted for in accordance with this Agreement as of the Project Completion Date or earlier termination is repayable by the Applicant to AI at AI’s request.
Commercial Operation Date Testing and Modifications Prior to the Commercial Operation Date, the Connecting Transmission Owner shall test the Connecting Transmission Owner’s Attachment Facilities and System Upgrade Facilities and System Deliverability Upgrades and Developer shall test the Large Generating Facility and the Developer Attachment Facilities to ensure their safe and reliable operation. Similar testing may be required after initial operation. Developer and Connecting Transmission Owner shall each make any modifications to its facilities that are found to be necessary as a result of such testing. Developer shall bear the cost of all such testing and modifications. Developer shall generate test energy at the Large Generating Facility only if it has arranged for the injection of such test energy in accordance with NYISO procedures.
Construction Preparation Period 2.1.3 Construction Management Plan
PREVAILING WAGE RATES - PUBLIC WORKS AND BUILDING SERVICES CONTRACTS If any portion of work being Bid is subject to the prevailing wage rate provisions of the Labor Law, the following shall apply:
WORKING TEST PERIOD Section One. The Working Test Period shall be deemed an extension of the examination process. Therefore, a determination of unsatisfactory performance during a Working Test Period shall be tantamount to a failure of the competitive exam.
