Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Quality- and Cost-Based Selection Except as ADB may otherwise agree, the Borrower shall apply quality- and cost-based selection for selecting and engaging consulting services.
Quality-based Selection Services for assignments which the Bank agrees meet the requirements set forth in paragraph 3.2 of the Consultant Guidelines may be procured under contracts awarded on the basis of Quality-based Selection in accordance with the provisions of paragraphs 3.1 through 3.4 of the Consultant Guidelines.
DEVELOPMENT OR ASSISTANCE IN DEVELOPMENT OF SPECIFICATIONS REQUIREMENTS/ STATEMENTS OF WORK Firms and/or individuals that assisted in the development or drafting of the specifications, requirements, statements of work, or solicitation documents contained herein are excluded from competing for this solicitation. This shall not be applicable to firms and/or individuals providing responses to a publicly posted Request for Information (RFI) associated with a solicitation.
Reportable Events Involving the Xxxxx Law Notwithstanding the reporting requirements outlined above, any Reportable Event that involves solely a probable violation of section 1877 of the Social Security Act, 42 U.S.C. §1395nn (the Xxxxx Law) should be submitted by Practitioner to CMS through the self-referral disclosure protocol (SRDP), with a copy to the OIG. If Practitioner identifies a probable violation of the Xxxxx Law and repays the applicable Overpayment directly to the CMS contractor, then Practitioner is not required by this Section III.G to submit the Reportable Event to CMS through the SRDP.
Presentation of Potential Target Businesses The Company shall cause each of the Initial Shareholders to agree that, in order to minimize potential conflicts of interest which may arise from multiple affiliations, the Initial Shareholders will present to the Company for its consideration, prior to presentation to any other person or company, any suitable opportunity to acquire an operating business, until the earlier of the consummation by the Company of a Business Combination or the liquidation of the Company, subject to any pre-existing fiduciary obligations the Initial Shareholders might have.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
PRICING for Markup of Non-Prepriced Items in RS Means Unit Price Book What is your proposed Markup Percentage on materials not found in the RS Means Price Book? If any materials being utilized for a project cannot be found in the RS Means Price Book, this question is what is the markup percentage on those materials? When answering this question please insert the number that represents your percentage of proposed markup. Example: if you are proposing a 30 percent markup, please insert the number "30". Remember that this is a ceiling markup. You may markup a lesser percentage to the TIPS Member customer when pricing the project, but not a greater percentage. EXAMPLE: You need special materials that are not in the RS Means Unit Price Book for a project. You would buy the materials and mark them up to the TIPS Member customer by the percentage you propose in this question. If the materials cost you, the contractor, $100 and you proposed a markup on this question for the material of 30 percent, then you would charge the TIPS Member customer $130 for the materials.
Tests and Preclinical and Clinical Trials The preclinical studies and clinical trials conducted by or, to the Company’s knowledge, on behalf of the Company, that are described in the Registration Statement, the Pricing Disclosure Package and the Prospectus, as applicable, and are intended to be submitted to FDA or other comparable government entities, were and, if still ongoing, are being conducted in all material respects in accordance with experimental protocols, procedures and controls pursuant to accepted professional scientific standards and all Authorizations and Applicable Laws, including, without limitation, the Federal Food, Drug and Cosmetic Act and the rules and regulations promulgated thereunder and for studies submitted to regulatory authorities for approval, current Good Clinical Practices and Good Laboratory Practices and any applicable rules and regulations of the jurisdiction in which such trials and studies are being conducted; the descriptions of the results of such studies and trials contained in the Registration Statement, the Pricing Disclosure Package and the Prospectus are, to the Company’s knowledge, accurate and complete in all material respects and fairly present the data derived from such studies and trials; except to the extent disclosed in the Registration Statement, the Pricing Disclosure Package and the Prospectus, the Company is not aware of any studies or trials, the results of which the Company believes reasonably call into question the study or trial results described or referred to in the Registration Statement, the Pricing Disclosure Package and the Prospectus when viewed in the context in which such results are described and the clinical stage of development; and, except to the extent disclosed in the Registration Statement, the Pricing Disclosure Package or the Prospectus, the Company has not received any written notices or written correspondence from the FDA or any governmental entity requiring the termination or suspension of any preclinical studies or clinical trials conducted by or on behalf of the Company, other than ordinary course communications with respect to modifications in connection with the design and implementation of such trials, copies of which communications have been made available to you.
