Proposed New or Expanded Facility; Partial Performance Sample Clauses

Proposed New or Expanded Facility; Partial Performance. If the Expansion Project results in a completed Facility that is only partially operational, or is material different than the Expansion Project agreed to in Schedule B (as measured by such factors as size, capital investment expenditures, capital improvements, employment levels, estimated energy demand and/or other criteria determined by the Authority to be relevant), the Authority may, in its discretion, on its own initiative or at the Customer’s request, make a permanent reduction to the Allocation and Contract Demand to an amount that the Authority determines to fairly correspond to the completed Facility.
Sample 1Sample 2Sample 3See All (18)
AutoNDA by SimpleDocs

Related to Proposed New or Expanded Facility; Partial Performance

  • Discontinued Facility Any facility, element, arrangement or the like that the Federal Unbundling Rules do not require Frontier to provide on an unbundled basis to Onvoy, whether because the facility was never subject to an unbundling requirement under the Federal Unbundling Rules, because the facility by operation of law has ceased or ceases to be subject to an unbundling requirement under the Federal Unbundling Rules, or otherwise.

  • EXTENSION OF USE COMMITMENT The Contractor agrees to honor all orders from State Agencies, political subdivisions and others authorized by law (see Section 25 Extension of Use) which are in compliance with the pricing, terms, and conditions set forth in the Contract. Any unilateral limitations/restrictions imposed by the Contractor on eligible Authorized Users will be grounds for cancellation of the Contract.

  • FACILITY OPERATIONS FACILITY OPERATION MON TUES WED THURS FRI SAT SUN A. Regular hours facility is open to public and employees 10A -9P 10A -9P 10A -9P 10A -9P 10A -5P 10A -5P Closed B. Hours facility is open to public and employees

  • Facility Use The Employer shall allow individuals the use of gender- segregated facilities, such as restrooms, locker rooms, and dressing rooms that are consistent with that individual's gender expression or gender identity. In such facilities where undressing in the presence of others occurs, the Employer shall allow access to and use of a facility consistent with that individual's gender expression or gender identity.

  • Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.

  • Loss of a Facility Hub In the event that BellSouth loses a facility hub, the recovery process is much the same as above. Once the NMC has observed the problem and administered the appropriate controls, the ECC will assume authority for the repairs. The recovery effort will include

  • Commitment of Current Revenues Only In the event that, during any term hereof, the Commissioners Court does not appropriate sufficient funds to meet the obligations of County under this Agreement, County may terminate this Agreement upon ninety (90) days written notice to Company. County agrees, however, to use reasonable efforts to secure funds necessary for the continued performance of this Agreement. The parties intend this provision to be a continuing right to terminate this Agreement at the expiration of each budget period of County. Agreements for the acquisition, including lease of real or personal property under Tex. Loc. Govt. Code §271.903: In the event that, during any term hereof, the Commissioner’s Court does not appropriate sufficient funds to meet the obligations of County under this Agreement, County may terminate this Agreement upon ninety (90) days written notice to Company, County agrees, however, to use a best efforts attempt to obtain and appropriate funds for payment of the Agreement. The parties intend this provision, if applicable, to be a continuing right to terminate this at the expiration of each budget period of County in accordance with Tex. Loc. Govt. Code §271.903 (Xxxxxx Supp. 1996).

  • Refinancing Preparation Advance; Capitalizing Front-end Fee and Interest (a) If the Loan Agreement provides for the repayment out of the proceeds of the Loan of an advance made by the Bank or the Association (“Preparation Advance”), the Bank shall, on behalf of such Loan Party, withdraw from the Loan Account on or after the Effective Date the amount required to repay the withdrawn and outstanding balance of the advance as at the date of such withdrawal from the Loan Account and to pay all accrued and unpaid charges, if any, on the advance as at such date. The Bank shall pay the amount so withdrawn to itself or the Association, as the case may be, and shall cancel the remaining unwithdrawn amount of the advance.”

  • Service Commitment Newly hired nurses and currently employed nurses who voluntarily choose to relocate and receive a relocation allowance may be required to serve for a minimum of two years at their base before they will be considered for transfer to another base. This commitment will not apply when the employer and nurse mutually agree to waive it and when relocation occurs as a result of layoff/rehire.

  • Credit for Project Work In order to compensate PURCHASER for project work that PURCHASER agrees to complete under the section titled, “Project Work,” of this contract, STATE agrees to credit PURCHASER’s timber account in the sum of $46,657 upon completion of and STATE’s acceptance of all work, unless otherwise approved in writing by STATE. PURCHASER may request partial credit for project work when PURCHASER has completed and STATE has accepted project work, in accordance with the following credit schedule: Partial credit amount of $24,999 (Project No. 1 completion) Partial credit amount of $ 545 (Project No. 2 completion) Partial credit amount of $ 2,721 (Project No. 3 completion) Partial credit amount of $ 1,753 (Project No. 4 completion) Partial credit amount of $16,639 (Project No. 5 completion)

Time is Money Join Law Insider Premium to draft better contracts faster.