Excusable Delay The Contractor is entitled to an equitable adjustment of time, issued via Change Order, for delays caused by the following:
Waiver or Delay No failure to exercise or delay by a party in exercising any right, power, or remedy under this License Agreement operates as a waiver of such right, power, or remedy. A single or partial exercise of any right, power, or remedy does not preclude any other or further exercise of that or any other right, power, or remedy. A waiver is not valid or binding on the party granting the waiver unless made in writing.
Six-Month Delay Notwithstanding anything to the contrary in this Agreement, no compensation or benefits, including without limitation any severance payments or benefits payable under this Section 4, shall be paid to the Executive during the six-month period following the Executive’s Separation from Service if the Company determines that paying such amounts at the time or times indicated in this Agreement would be a prohibited distribution under Section 409A(a)(2)(B)(i) of the Code. If the payment of any such amounts is delayed as a result of the previous sentence, then on the first day of the seventh month following the date of Separation from Service (or such earlier date upon which such amount can be paid under Section 409A without resulting in a prohibited distribution, including as a result of the Executive’s death), the Company shall pay the Executive a lump-sum amount equal to the cumulative amount that would have otherwise been payable to the Executive during such period.
Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Unavoidable Delay When construction is impeded as a result of strikes, lockouts, acts of God or other factors beyond the control, and ability to remedy, of the Developer.
Tenant Delay If substantial completion of the Tenant Improvements, Warm Shell Improvements or Base Building is delayed due to any of the following (collectively, "Tenant Delays"), then the Delivery Date and/or Commencement Date, as applicable, shall be adjusted to reflect what the substantial completion date would have been if there had been no delay: (i) Tenant's failure to timely submit any items required by this Work Letter, including, without limitation, Tenant's Plans; (ii) Tenant Modifications; (iii) Tenant's failure to comply with Landlord's contractor's schedule; (iv) Tenant's or Tenant's Contractor's failure to comply with Paragraph 8, (v) Tenant's requested changes to the Tenant's Plans after they are approved by Landlord; (vi) Tenant's request for materials, finishes or installations which require longer than thirty (30) days to complete; (vii) delays caused by Tenant in construction of the Warm Shell Improvements or the Tenant Improvements; or (viii) any other event expressly constituting "Tenant Delay" pursuant to any provision of this Work Letter. Landlord shall give Tenant at least five (5) days prior notice if Landlord becomes aware that Tenant is in danger of causing a Tenant Delay, and if Tenant takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Delivery Date or Commencement Date shall be made on account of such Tenant Delay; provided, however, that if such delay was not reasonably foreseeable by Landlord, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Landlord becomes aware of such delay or potential delay; and provided further, that no such notice shall be required if Tenant Delay results from Tenant's failure to perform any obligation within a specific date or time period (including, without limitation, any delay in delivery of Tenant's space plan or Working Drawings or non-compliance with Landlord's contractor's schedule), or from schedule changes resulting from Tenant Modifications of which Tenant is advised by Landlord's architect or contractor as provided in Paragraph 4, or from causes that, due to the parties' relative positions with respect to the construction process, are more likely to be foreseeable by Tenant than by Landlord.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion First Tier Participants:
Payment Delay Notwithstanding any other terms of this Agreement, no payments will be made to CONTRACTOR until COUNTY is satisfied that work of such value has been rendered pursuant to this Agreement. However, COUNTY will not unreasonably withhold payment and, if a dispute exists, the withheld payment shall be proportional only to the item in dispute.