NOTICE OF POTENTIAL VENDOR BREACH Sample Clauses

NOTICE OF POTENTIAL VENDOR BREACH. If Vendor breaches the contract or anticipates, breaching the contract the Vendor shall immediately give written notice to the State. The notice shall explain the breach or potential breach, and may include a request for a waiver of the breach if so desired. The State may, at its discretion, temporarily or permanently waive the breach. By granting a temporary waiver, the State does not forfeit any rights or remedies to which the State is entitled by law or equity, or pursuant to the provisions of the contract. Failure to give immediate notice, however, may be grounds for denial of any request for a waiver of a breach.
Sample 1Sample 2See All (4)
AutoNDA by SimpleDocs
NOTICE OF POTENTIAL VENDOR BREACH. Accept (Initial) Reject (Initial) Reject & Provide Alternative Response (Initial) NOTES/COMMENTS: If Vendor breaches the contract or anticipates breaching the contract, the Vendor shall immediately give written notice to the State. The notice shall explain the breach or potential breach, a proposed cure, and may include a request for a waiver of the breach if so desired. The State may, in its discretion, temporarily or permanently waive the breach. By granting a waiver, the State does not forfeit any rights or remedies to which the State is entitled by law or equity, or pursuant to the provisions of the contract. Failure to give immediate notice, however, may be grounds for denial of any request for a waiver of a breach.
Sample 1
NOTICE OF POTENTIAL VENDOR BREACH. Accept (Initial) Reject (Initial) Reject & Provide Alternative Response (Initial) NOTES/COMMENTS: If Vendor breaches the contract or anticipates, breaching the contract the Vendor shall immediately give written notice to the State. The notice shall explain the breach or potential breach, and may include a request for a waiver of the breach if so desired. The State may, at its discretion, temporarily or permanently waive the breach. By granting a temporary waiver, the State does not forfeit any rights or remedies to which the State is entitled by law or equity, or pursuant to the provisions of the contract. Failure to give immediate notice, however, may be grounds for denial of any request for a waiver of a breach.
Sample 1

Related to NOTICE OF POTENTIAL VENDOR BREACH

  • Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.

  • Termination for Breach of Contract 1. Except as provided in PSC-6, if CONTRACTOR fails to perform any of the provisions of this Contract or so fails to make progress as to endanger timely performance of this Contract, CITY may give CONTRACTOR written notice of the default. CITY’S default notice will indicate whether the default may be cured and the time period to cure the default to the sole satisfaction of CITY. Additionally, CITY’S default notice may offer CONTRACTOR an opportunity to provide CITY with a plan to cure the default, which shall be submitted to CITY within the time period allowed by CITY. At CITY’S sole discretion, CITY may accept or reject CONTRACTOR’S plan. If the default cannot be cured or if CONTRACTOR fails to cure within the period allowed by CITY, then CITY may terminate this Contract due to CONTRACTOR’S breach of this Contract.

  • Termination for Breach or Default If the County terminates the Contract for default or breach of any Contract provision or condition, then the termination will be immediate after notice of termination to the Contractor (unless the County provides for an opportunity to cure), and the Contractor will not be permitted to seek termination costs. Upon any termination pursuant to this section, the Contractor will be liable to the County for costs that the County must expend to complete the Work, including costs resulting from any related delays and from unsatisfactory or non-compliant work performed by the Contractor or its subcontractors. The County will deduct such costs from any amount due to the Contractor; or if the County does not owe the Contractor, the Contractor must promptly pay the costs within 15 days of a demand by the County. This section does not limit the County’s recovery of any other damages to which it is entitled by law. Except as otherwise directed by the County, the Contractor must stop work on the date of receipt the notice of the termination.

  • Termination for Breach Either party may terminate this Agreement (including the Statement of Work) if the other party breaches any material term of this Agreement and fails to cure such breach within thirty (30) days following written notice thereof from the non-breaching party.

  • Material Breach of Contract In the event Contractor fails to deliver the product and services as contracted for herein, to the satisfaction of the City of Sparks or otherwise fails to perform any provisions of this Contract, the City, after providing five (5) days written notice and Contractor’s failure to cure such breach within the time specified in the notice, may without waiving any other remedy, make good the deficiencies and deduct the actual cost of providing alternative products and/or services from payment due the Contractor. Non-performance after the first notice of non-performance shall be considered a material breach of contract.

  • FALSE STATEMENTS; BREACH OF REPRESENTATIONS The Parties acknowledge that this Agreement has been negotiated, and is being executed, in reliance upon the information contained in the Application, and any supplements or amendments thereto, without which the Comptroller would not have approved this Agreement and the District would not have executed this Agreement. By signature to this Agreement, the Applicant:

  • Damages for Failure to Cut or Termination for Breach (a) In event of Purchaser’s failure to cut designated timber on portions of Sale Area by Termination Date or termination for breach under B9.31, Forest Service shall appraise remaining Included Timber, unless termination is under B8.22 or B8.34. Such appraisal shall be made with the standard Forest Service method in use at time of termination.

  • Material Breach or Early Termination Section 9.1. EVENTS CONSTITUTING MATERIAL BREACH OF AGREEMENT. Applicant shall be in Material Breach of this Agreement if it commits one or more of the following acts or omissions:

  • Defendant’s Breach of Plea Agreement If the defendant commits any crimes, violates any conditions of release, or violates any term of this plea agreement between the signing of this plea agreement and the date of sentencing, or fails to appear for sentencing, or if the defendant provides information to the Probation Office or the Court that is intentionally misleading, incomplete, or untruthful, or otherwise breaches this plea agreement, the United States will be released from its obligations under this agreement. The defendant, however, will remain bound by the terms of the agreement, and will not be allowed to withdraw his plea of guilty. The defendant also understands and agrees that in the event he violates this plea agreement, all statements made by him to law enforcement agents subsequent to the execution of this plea agreement, any testimony given by him before a grand jury or any tribunal or any leads from such statements or testimony shall be admissible against him in any and all criminal proceedings. The defendant waives any rights that he might assert under the United States Constitution, any statute, Rule 11(f) of the Federal Rules of Criminal Procedure, Rule 410 of the Federal Rules of Evidence, or any other federal rule that pertains to the admissibility of any statements made by him subsequent to this plea agreement.

  • Termination for a Material Breach Either party may terminate this Agreement for a material breach by the other party. The breaching party will have thirty (30) days from the date of written notice to cure any material breach.

Time is Money Join Law Insider Premium to draft better contracts faster.