Direct Damages Each of the Parties shall be liable to the other for any direct damages arising out of or relating to its performance or failure to perform under this Agreement.
Delay Damages If the Commercial Operation Date is not achieved by the date set forth therefor in Section 3.1(a) (as extended pursuant to Section 3.1(c)), Seller shall pay to Buyer damages for each month from and after such date until the Commercial Operation Date at the rate of $1.50 per kwh of Contract Maximum Amount up to a maximum of twelve (12) months of delay, pro rated for partial months (“Delay Damages”). Delay Damages shall be due under this Section 3.2(a) without regard to whether Buyer exercises its right to terminate this Agreement pursuant to Section 9.3; provided, however, that if Buyer exercises its right to terminate this Agreement under Section 9.3, Delay Damages shall be due and owing to the extent that such Delay Damages were due and owing at the date of such termination. If the Facility has not achieved the Commercial Operation by the date set forth therefor in Section 3.1(a) (as the same may be extended in accordance with Section 3.1(c)), for any reason, Seller shall have the right to terminate this Agreement at any time after that deadline date (as so extended) until either the Facility achieves the Commercial Operation Date or Buyer terminates this Agreement under Section 9.3 (regardless of whether or not Seller elected to continue to construct the Project). In the event Seller so terminates this Agreement, Seller shall be liable to Buyer on the date of such termination for (x) the entire amount of Delay Damages that would otherwise accrue (or have accrued) by such date plus (y) the undrawn amount of any Development Period Security provided to Buyer by Seller; provided, however, that if Seller terminates this Agreement on the deadline set forth for the Commercial Operation Date in Section 3.1(a) (as the same may be extended in accordance with Section 3.1(c)), Seller shall not be required to pay any Delay Damages hereunder but shall forfeit the Development Period Security. Subject to the foregoing sentence, neither Party shall have any liability to the other Party with respect to a termination of this Agreement by Seller under this Section 3.2(b). Each Party agrees and acknowledges that (i) the damages that Buyer would incur due to Seller’s delay in achieving the Commercial Operation Date would be difficult or impossible to predict with certainty, and (ii) it is impractical and difficult to assess actual damages in the circumstances stated, and therefore the Delay Damages and other damages as agreed to by the Parties and set forth herein are a fair and reasonable calculation of such damages. Notwithstanding the foregoing, this Article shall not limit the amount of damages payable to Buyer if this Agreement is terminated by Buyer as a result of Seller’s failure to achieve the Commercial Operation Date. Any such termination damages shall be determined in accordance with Article 9. By the tenth (10th) day following the end of the calendar month in which Delay Damages first become due and continuing by the tenth (10th) day of each calendar month during the period in which Delay Damages accrue (and the following months if applicable), Buyer shall deliver to Seller an invoice showing Buyer’s computation of such damages and any amount due Buyer in respect thereof for the preceding calendar month. No later than ten (10) days after receiving such an invoice, Seller shall pay to Buyer, by wire transfer of immediately available funds to an account specified in writing by Buyer or by any other means agreed to by the Parties in writing from time to time, the amount set forth as due in such invoice. If Seller fails to pay such amounts when due, Buyer may draw upon the Development Period Security for payment of such Delay Damages, and Buyer may exercise any other remedies available for Seller’s default hereunder.
Monetary Damages In the event that the Partnership breaches its obligations set forth in Article 2, Article 3, or Article 6 with respect to a Protected Partner the Protected Partner’s sole right shall be to receive from the Partnership, and the Partnership shall pay to such Protected Partner as damages, an amount equal to:
Exclusion of Consequential Damages Notwithstanding anything contained herein to the contrary, neither Party will be liable under this Agreement or under any cause of action relating to the subject matter of this Agreement for any special, indirect, incidental, punitive, exemplary or consequential damages, including loss of profits, loss of use of any property or claims of customers or contractors of the Parties for any such damages.
Waiver of Punitive Damages Notwithstanding anything to the contrary contained in this Agreement, the Borrower hereby agrees that it shall not seek from the Lenders or the Administrative Agent punitive, consequential, or indirect damages relating to any such matters under any theory of liability.
Punitive Damages The Administrative Agent, the Lenders and the Borrower hereby agree that no such Person shall have a remedy of punitive or exemplary damages against any other party to a Loan Document and each such Person hereby waives any right or claim to punitive or exemplary damages that they may now have or may arise in the future in connection with any Dispute, whether such Dispute is resolved through arbitration or judicially.
Waiver of Consequential Damages To the fullest extent permitted by applicable Law, the Borrower shall not assert, and hereby waives, any claim against any Indemnitee, on any theory of liability, for special, indirect, consequential or punitive damages (as opposed to direct or actual damages) arising out of, in connection with, or as a result of, this Agreement, any other Loan Document, the Related Documents or any agreement or instrument contemplated hereby or thereby, the transactions contemplated hereby or thereby, any Term Loan or the use of the proceeds thereof. No Indemnitee referred to in subsection (b) above shall be liable for any damages arising from the use by unintended recipients of any information or other materials distributed by it through telecommunications, electronic or other information transmission systems in connection with this Agreement or the other Loan Documents, the Related Documents or the transactions contemplated hereby or thereby other than for direct or actual damages resulting from the gross negligence or willful misconduct of such Indemnitee as determined by a final and nonappealable judgment of a court of competent jurisdiction.
Incidental and Consequential Damages Contractor shall be responsible for incidental and consequential damages resulting in whole or in part from Contractor’s acts or omissions. Nothing in this Agreement shall constitute a waiver or limitation of any rights that City may have under applicable law.
Limitation on Consequential Damages NEITHER PARTY WILL HAVE ANY OBLIGATION OR LIABILITY (WHETHER IN CONTRACT, WARRANTY, TORT (INCLUDING NEGLIGENCE) OR OTHERWISE, AND NOTWITHSTANDING ANY FAULT, NEGLIGENCE (WHETHER ACTIVE, PASSIVE OR IMPUTED), REPRESENTATION, STRICT LIABILITY OR PRODUCT LIABILITY), FOR COVER OR FOR ANY INCIDENTAL, INDIRECT, CONSEQUENTIAL, MULTIPLIED, PUNITIVE, SPECIAL, OR EXEMPLARY DAMAGES OR LOSS OF REVENUE, PROFIT, SAVINGS OR BUSINESS ARISING FROM OR OTHERWISE RELATED TO THIS AGREEMENT, EVEN IF A PARTY OR ITS REPRESENTATIVES HAVE BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES. THE PARTIES ACKNOWLEDGE THAT THESE EXCLUSIONS OF POTENTIAL DAMAGES WERE AN ESSENTIAL ELEMENT IN SETTING CONSIDERATION UNDER THIS AGREEMENT.
Indirect Damages To the maximum extent permitted by Law, the Stripe Parties will not be liable to you or your Affiliates in relation to this Agreement or the Services during and after the Term (whether in contract, negligence, strict liability or tort, or on other legal or equitable grounds) for any lost profits, personal injury, property damage, loss of data, business interruption, indirect, incidental, consequential, exemplary, special, reliance, or punitive damages, even if these losses, damages, or costs are foreseeable, and whether or not you or the Stripe Parties have been advised of their possibility.
