Computation of Period of Days, Deadline In computing a period of days, when the ending date is not 54 specified, the first day is excluded and the last day is included, e.g., three days after MEC. If any deadline falls on a Saturday, 55 Sunday or federal or Colorado state holiday (Holiday), such deadline Will Will Not be extended to the next day that is not
QUANTITY CHANGES PRIOR TO AWARD The Commissioner reserves the right, at any time prior to the award of a specific quantity Contract, to alter in good faith the quantities listed in the Bid Specifications. In the event such right is exercised, the lowest responsible Bidder meeting Bid Specifications will be advised of the revised quantities and afforded an opportunity to extend or reduce its Bid price in relation to the changed quantities. Refusal by the low Bidder to so extend or reduce its Bid price may result in the rejection of its Bid and the award of such Contract to the lowest responsible Bidder who accepts the revised qualifications.
Puts Prior to the Settlement Date During the period from the Bank Closing Date to and including the Business Day immediately preceding the Settlement Date, the Assuming Bank shall be entitled to require the Receiver to purchase any Asset which the Assuming Bank can establish is evidenced by forged or stolen instruments as of the Bank Closing Date; provided, that, the Assuming Bank shall not have the right to require the Receiver to purchase any such Asset with respect to which the Assuming Bank has taken any action referred to in Section 3.4(a)(ii) with respect to such Asset. The Assuming Bank shall transfer all such Assets to the Receiver without recourse, and shall indemnify the Receiver against any and all claims of any Person claiming by, through or under the Assuming Bank with respect to any such Asset, as provided in Section 12.4.
Holiday Falling on a Scheduled Workday A team member who works on a designated holiday which is a scheduled workday shall be compensated at the rate of double-time for hours worked, plus a day off in lieu of the holiday; except for Christmas and New Year's when the compensation shall be at the rate of double-time and one-half for hours worked, plus a day off in lieu of the holiday. The scheduling of the lieu day shall be in accordance with Appendix 4.
Holiday Falling on Saturday or Sunday For an employee whose normal workweek is from Monday to Friday and when any of the above-noted holidays falls on a Saturday and is not proclaimed as being observed on another day, the following Monday will be deemed to be the holiday. When a holiday falls on a Sunday and it is not proclaimed as being observed on another day, the following Monday (or Tuesday, where the preceding section already applies), will be deemed to be the holiday for the purpose of this agreement.
Holiday Falling on a Scheduled Workday An employee who works on a designated holiday which is a scheduled workday shall be compensated at the rate of double-time for hours worked, plus a day off in lieu of the holiday; except for Christmas and New Year's when the compensation shall be at the rate of double-time and one-half for hours worked, plus a day off in lieu of the holiday.
Recovery of Schedule Delays During Last Sixty Days of Contract Time At any time during the last sixty days of the Contract Time that the Design Professional finds that the Contractor is behind schedule per the Contract Time, as amended, the Design Professional shall notify the Contractor in writing. Within seven days of the date of the Design Professional's notice, the Contractor shall prepare and deliver to the Design Professional and Owner a written plan explaining how the Contractor intends to bring the Project back on schedule. The Contractor's plan must provide sufficient detail to allow the Design Professional and Owner to determine the proposal's feasibility.
Sunday Premium All hours worked by an Employee on Sunday, shall be paid for on the basis of one and one-half (1½) times the Employee’s Regular Rate of Pay. For the purpose of this Section, Sunday shall be deemed to be the twenty-four (24) hours beginning with the shift change hour nearest to 12:01 a.m.
Show Up Time An employee who reports to work in the usual manner without having been notified that there is no work available and is sent home because of lack of work before having worked four (4) hours shall receive a minimum of four (4) hours pay at their prevailing hourly rate. The employee shall also receive their full accommodation allowance if and when applicable. Each employee must inform the Employer of a means of being contacted on short notice. If an attempt is made by the Employer at least two (2) hours before the employee’s shift commences by way of the contact information provided, in an effort to inform the employee of a lack of work, and the Employer is unable to do so, the employee will not be entitled to show up time.
Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
