Common use of Limits of Liability Clause in Contracts

Limits of Liability. To the fullest extent permitted by applicable law, (1) You agree that We and HomeServe, and both of our respective parents, successors, affiliates, approved technicians and Our and their officers, directors, employees, affiliates, agents, contractors or similar parties acting on behalf of either Us or HomeServe shall not be liable to You or anyone else for: (a) any actual losses or direct damages that exceed the lowest applicable per repair Benefit Limit, or, if there is no maximum Benefit Limit, any actual losses or direct damages that exceed the cost of repairs provided for in the “What is a Covered Repair?” section(s) of this Service Agreement, relating to any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided hereunder giving rise to such loss or damage; or (b) any amount of any form of indirect, special, punitive, incidental or consequential losses or damages, damages based on anticipated or lost profits, wages, or revenue, or damages based on diminution in value or a multiple of earnings, including those caused by any fault, failure, delay or defect in providing any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided under this Service Agreement, regardless of whether such damages were foreseeable and whether or not We or HomeServe or anyone acting on behalf of either Us or HomeServe have been advised of the possibility of such damages (the damages listed in clauses (a) and (b), collectively the “Excluded Damages”); and (2) these limitations and waivers shall apply to all claims and all liabilities and shall survive the cancellation or expiration of this Service Agreement. You may have other rights that vary from state to state. Arbitration: YOU, NHRW AND HOMESERVE ALL AGREE TO RESOLVE DISPUTES BY BINDING ARBITRATION as follows:

Appears in 76 contracts

Samples: Cooling System Terms And, Service Agreement, Service Agreement

AutoNDA by SimpleDocs

Limits of Liability. To the fullest extent permitted by applicable law, (1) You agree that We and HomeServe, and both of our respective parents, successors, affiliates, approved technicians and Our and their officers, directors, employees, affiliates, agents, contractors or similar parties acting on behalf of either Us or HomeServe shall not be liable to You or anyone else for: (a) any actual losses or direct damages that exceed the lowest applicable per repair Benefit Limit, or, if there is no maximum Benefit Limit, any actual losses or direct damages that exceed the cost of repairs provided for in the “What is a Covered Repair?” section(s) of this Service Agreement, relating to any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided hereunder giving rise to such loss or damage; or (b) any amount of any form of indirect, special, punitive, incidental or consequential losses or damages, damages based on anticipated or lost profits, wages, or revenue, or damages based on diminution in value or a multiple of earnings, including those caused by any fault, failure, delay or defect in providing any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided under this Service Agreement, regardless of whether such damages were foreseeable and whether or not We or HomeServe or anyone acting on behalf of either Us or HomeServe have been advised of the possibility of such damages (the damages listed in clauses (a) and (b), collectively the “Excluded Damages”); and (2) these limitations and waivers shall apply to all claims and all liabilities and shall survive the cancellation or expiration of this Service Agreement. You may have other rights that vary from state to state. Arbitration: YOU, NHRW NAW AND HOMESERVE ALL AGREE TO RESOLVE DISPUTES BY BINDING ARBITRATION as follows:

Appears in 65 contracts

Samples: Cooling System Terms And, Service Agreement, Service Agreement

Limits of Liability. To the fullest extent permitted by applicable law, (1) You agree that We and HomeServe, and both of our respective parents, successors, affiliates, approved technicians and Our and their officers, directors, employees, affiliates, agents, contractors or similar parties acting on behalf of either Us or HomeServe shall not be liable to You or anyone else for: (a) any actual losses or direct damages that exceed the lowest applicable per repair Benefit Limit, or, if there is no maximum Benefit Limit, any actual losses or direct damages that exceed the cost of repairs provided for in the “What is a Covered Repair?” section(s) of this Service Agreement, relating to any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided hereunder giving rise to such loss or damage; or (b) any amount of any form of indirect, special, punitive, incidental or consequential losses or damages, damages based on anticipated or lost profits, wages, or revenue, or damages based on diminution in value or a multiple of earnings, including those caused by any fault, failure, delay or defect in providing any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided under this Service Agreement, regardless of whether such damages were foreseeable and whether or not We or HomeServe or anyone acting on behalf of either Us or HomeServe have been advised of the possibility of such damages (the damages listed in clauses (a) and (b), collectively the “Excluded Damages”); and (2) these limitations and waivers shall apply to all claims and all liabilities and shall survive the cancellation or expiration of this Service Agreement. You may have other rights that vary from state to state. Arbitration: YOU, NHRW CNA AND HOMESERVE ALL AGREE TO RESOLVE DISPUTES BY BINDING ARBITRATION as follows:

Appears in 30 contracts

Samples: Service Agreement, Service Agreement, Service Agreement

Limits of Liability. To the fullest extent permitted by applicable law, (1) You agree that We and HomeServe, and both of our Our respective parents, successors, affiliates, approved technicians and Our and their officers, directors, employees, affiliates, agents, contractors or similar parties acting on behalf of either Us or HomeServe shall not be liable to You or anyone else for: (a) any actual losses or direct damages that exceed the lowest applicable per repair Benefit Limit, or, if there is no maximum Benefit Limit, any actual losses or direct damages that exceed the cost of repairs provided for in the “What is a Covered Repair?” section(s) of this Service Agreement, benefit limit set out above relating to any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided hereunder giving rise to such loss or damage; or (b) any amount of any form of indirect, special, punitive, incidental or consequential losses or damages, damages based on anticipated or lost profits, wages, or revenue, or damages based on diminution in value or a multiple of earnings, including those caused by any fault, failure, delay or defect in providing any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided under this Service Agreement, regardless of whether such damages were foreseeable and whether or not We or HomeServe or anyone acting on behalf of either Us or HomeServe have been advised of the possibility of such damages (the damages listed in clauses (a) and (b), collectively the “Excluded Damages”); and (2) these limitations and waivers shall apply to all claims and all liabilities and shall survive the cancellation or expiration of this Service Agreement. You may have other rights that vary from state to state. Arbitration: YOU, NHRW AND HOMESERVE ALL AGREE TO RESOLVE DISPUTES BY BINDING ARBITRATION as follows:

Appears in 16 contracts

Samples: Service Agreement, Service Agreement, Service Agreement

Limits of Liability. To the fullest extent permitted by applicable law, (1) You agree that We and HomeServe, and both of our respective parents, successors, affiliates, approved technicians and Our and their officers, directors, employees, affiliates, agents, contractors or similar parties acting on behalf of either Us or HomeServe shall not be liable to You or anyone else for: (a) any actual losses or direct damages that exceed the lowest applicable per repair Benefit Limit, or, if there is no maximum Benefit Limit, any actual losses or direct damages that exceed the cost of repairs provided for in the “What is a Covered Repair?” section(s) of this Service Agreement, relating to any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided hereunder giving rise to such loss or damage; or (b) any amount of any form of indirect, special, punitive, incidental or consequential losses or damages, damages based on anticipated or lost profits, wages, or revenue, or damages based on diminution in value or a multiple of earnings, including those caused by any fault, failure, delay or defect in providing any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided under this Service Agreement, regardless of whether such damages were foreseeable and whether or not We or HomeServe or anyone acting on behalf of either Us or HomeServe have been advised of the possibility of such damages (the damages listed in clauses (a) and (b), collectively the “Excluded Damages”); and (2) these limitations and waivers shall apply to all claims and all liabilities and shall survive the cancellation or expiration of this Service Agreement. You may have other rights that vary from state to state. Arbitration: YOU, NHRW USPPL AND HOMESERVE ALL AGREE TO RESOLVE DISPUTES BY BINDING ARBITRATION as follows:

Appears in 9 contracts

Samples: Terms and Conditions, Terms and Conditions, Terms and Conditions

Limits of Liability. To the fullest extent permitted by applicable law, (1) You agree that We and We, SLWA, HomeServe, and both all of our respective parents, successors, affiliates, approved technicians and Our and their officers, directors, employees, affiliates, agents, contractors or similar parties acting on behalf of either Us Us, SLWA, or HomeServe shall not be liable to You or anyone else for: (a) any actual losses or direct damages that exceed the lowest applicable per repair Benefit Limit, or, if there is no maximum Benefit Limit, any actual losses or direct damages that exceed the cost of repairs provided for in the “What is a Covered Repair?” section(s) of this Service Agreement, relating to any repairs performed by Us, SLWA, HomeServe or on behalf of either Us Us, SLWA, or HomeServe or services provided hereunder giving rise to such loss or damage; or (b) any amount of any form of indirect, special, punitive, incidental or consequential losses or damages, damages based on anticipated or lost profits, wages, or revenue, or damages based on diminution in value or a multiple of earnings, including those caused by any fault, failure, delay or defect in providing any repairs performed by Us, SLWA, HomeServe or on behalf of either Us Us, SLWA, or HomeServe or services provided under this Service Agreement, regardless of whether such damages were foreseeable and whether or not We We, SLWA or HomeServe or anyone acting on behalf of either Us Us, SLWA, or HomeServe have been advised of the possibility of such damages (the damages listed in clauses (a) and (b), collectively the “Excluded Damages”); and (2) these limitations and waivers shall apply to all claims and all liabilities and shall survive the cancellation or expiration of this Service Agreement. You may have other rights that vary from state to state. Arbitration: YOU, NHRW NAW, SLWA, AND HOMESERVE ALL AGREE TO RESOLVE DISPUTES BY BINDING ARBITRATION as follows:

Appears in 9 contracts

Samples: Service Agreement, Service Agreement, Service Agreement

Limits of Liability. To the fullest extent permitted by applicable law, (1) You agree that We and HomeServe, and both of our respective parents, successors, affiliates, approved technicians and Our and their officers, directors, employees, affiliates, agents, contractors or similar parties acting on behalf of either Us or HomeServe shall not be liable to You or anyone else for: (a) any actual losses or direct damages that exceed the lowest applicable per repair Benefit Limit, or, if there is no maximum Benefit Limit, any actual losses or direct damages that exceed the cost of repairs provided for in the “What is a Covered Repair?” section(s) of this Service Agreement, benefit limit set out above relating to any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided hereunder giving rise to such loss or damage; or (b) any amount of any form of indirect, special, punitive, incidental or consequential losses or damages, damages based on anticipated or lost profits, wages, or revenue, or damages based on diminution in value or a multiple of earnings, including those caused by any fault, failure, delay or defect in providing any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided under this Service Agreement, regardless of whether such damages were foreseeable and whether or not We or HomeServe or anyone acting on behalf of either Us or HomeServe have been advised of the possibility of such damages (the damages listed in clauses (a) and (b), collectively the “Excluded Damages”); and (2) these limitations and waivers shall apply to all claims and all liabilities and shall survive the cancellation or expiration of this Service Agreement. You may have other rights that vary from state to state. Arbitration: YOU, NHRW THW AND HOMESERVE ALL AGREE TO RESOLVE DISPUTES BY BINDING ARBITRATION as follows:

Appears in 6 contracts

Samples: Service Agreement, Heating System Terms And, Service Agreement

Limits of Liability. To the fullest extent permitted by applicable law, (1) You agree that We and HomeServe, and both of our respective parents, successors, affiliates, approved technicians and Our and their officers, directors, employees, affiliates, agents, contractors or similar parties acting on behalf of either Us or HomeServe shall not be liable to You or anyone else for: (a) any actual losses or direct damages that exceed the lowest applicable per repair Benefit Limit, or, if there is no maximum Benefit Limit, any actual losses or direct damages that exceed the cost of repairs provided for in the “What is a Covered Repair?” section(s) of this Service Agreement, relating to any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided hereunder giving rise to such loss or damage; or (b) any amount of any form of indirect, special, punitive, incidental or consequential losses or damages, damages based on anticipated or lost profits, wages, or revenue, or damages based on diminution in value or a multiple of earnings, including those caused by any fault, failure, delay or defect in providing any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided under this Service Agreement, regardless of whether such damages were foreseeable and whether or not We or HomeServe or anyone acting on behalf of either Us or HomeServe have been advised of the possibility of such damages (the damages listed in clauses (a) and (b), collectively the “Excluded Damages”); and (2) these limitations and waivers shall apply to all claims and all liabilities and shall survive the cancellation or expiration of this Service Agreement. You may have other rights that vary from state to state. Arbitration: YOU, NHRW THW AND HOMESERVE ALL AGREE TO RESOLVE DISPUTES BY BINDING ARBITRATION as follows:

Appears in 6 contracts

Samples: Service Agreement, Service Agreement, Service Agreement

Limits of Liability. To the fullest extent permitted by applicable law, (1) You agree that We and HomeServe, and both of our respective parents, successors, affiliates, approved technicians and Our and their officers, directors, employees, affiliates, agents, contractors or similar parties acting on behalf of either Us or HomeServe shall not be liable to You or anyone else for: (a) any actual losses or direct damages that exceed the lowest applicable per repair Benefit Limit, or, if there is no maximum Benefit Limit, any actual losses or direct damages that exceed the cost of repairs provided for in the “What is a Covered Repair?” section(s) of this Service AgreementPrice, relating to any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided hereunder giving rise to such loss or damage; or (b) any amount of any form of indirect, special, punitive, incidental or consequential losses or damages, damages based on anticipated or lost profits, wages, or revenue, or damages based on diminution in value or a multiple of earnings, including those caused by any fault, failure, delay or defect in providing any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided under this Service Agreement, regardless of whether such damages were foreseeable and whether or not We or HomeServe or anyone acting on behalf of either Us or HomeServe have been advised of the possibility of such damages (the damages listed in clauses (a) and (b), collectively the “Excluded Damages”); and (2) these limitations and waivers shall apply to all claims and all liabilities and shall survive the cancellation or expiration of this Service Agreement. You may have other rights that vary from state to state. Arbitration: YOU, NHRW AND HOMESERVE ALL AGREE TO RESOLVE DISPUTES BY BINDING ARBITRATION as follows:

Appears in 5 contracts

Samples: Service      Agreement, Service Agreement, Service      Agreement

Limits of Liability. To the fullest extent permitted by applicable law, (1) You agree that We and HomeServe, and both of our respective parents, successors, affiliates, approved technicians and Our and their officers, directors, employees, affiliates, agents, contractors or similar parties acting on behalf of either Us or HomeServe shall not be liable to You or anyone else for: (a) any actual losses or direct damages that exceed the lowest applicable per repair Benefit Limit, or, if there is no maximum Benefit Limit, any actual losses or direct damages that exceed the cost of repairs provided for in the “What is a Covered Repair?” section(s) of this Service Agreement, relating to any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided hereunder giving rise to such loss or damage; or (b) any amount of any form of indirect, special, punitive, incidental or consequential losses or damages, damages based on anticipated or lost profits, wages, or revenue, or damages based on diminution in value or a multiple of earnings, including those caused by any fault, failure, delay or defect in providing any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided under this Service Agreement, regardless of whether such damages were foreseeable and whether or not We or HomeServe or anyone acting on behalf of either Us or HomeServe have been advised of the possibility of such damages (the damages listed in clauses (a) and (b), collectively the “Excluded Damages”); and (2) these limitations and waivers shall apply to all claims and all liabilities and shall survive the cancellation or expiration of this Service Agreement. You may have other rights that vary from state to state. Arbitration: YOU, NHRW Provider AND HOMESERVE ALL AGREE TO RESOLVE DISPUTES BY BINDING ARBITRATION as follows:

Appears in 5 contracts

Samples: Service Agreement, Service Agreement, Service Agreement

Limits of Liability. To the fullest extent permitted by applicable law, (1) You agree that We and HomeServe, and both of our Our respective parents, successors, affiliates, approved technicians and Our and their officers, directors, employees, affiliates, agents, contractors or similar parties acting on behalf of either Us or HomeServe shall not be liable to You or anyone else for: (a) any actual losses or direct damages that exceed the lowest applicable per repair Benefit Limit, or, if there is no maximum Benefit Limit, any actual losses or direct damages that exceed the cost of repairs provided for in the “What is a Covered Repair?” section(s) of this Service Agreement, benefit limit set out above relating to any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided hereunder giving rise to such loss or damage; or (b) any amount of any form of indirect, special, punitive, incidental or consequential losses or damages, damages based on anticipated or lost profits, wages, or revenue, or damages based on diminution in value or a multiple of earnings, including those caused by any fault, failure, delay or defect in providing any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided under this Service Agreement, regardless of whether such damages were foreseeable and whether or not We or HomeServe or anyone acting on behalf of either Us or HomeServe have been advised of the possibility of such damages (the damages listed in clauses (a) and (b), collectively the “Excluded Damages”); and (2) these limitations and waivers shall apply to all claims and all liabilities and shall survive the cancellation or expiration of this Service Agreement. You may have other rights that vary from state to state. Arbitration: YOU, NHRW NAW AND HOMESERVE ALL AGREE TO RESOLVE DISPUTES BY BINDING ARBITRATION as follows:

Appears in 3 contracts

Samples: Service Agreement, Service Agreement, Service Agreement

Limits of Liability. To the fullest extent permitted by applicable law, (1) You agree that We and We, SLWA, HomeServe, and both all of our respective parents, successors, affiliates, approved technicians and Our and their officers, directors, employees, affiliates, agents, contractors or similar parties acting on behalf of either Us Us, SLWA or HomeServe shall not be liable to You or anyone else for: (a) any actual losses or direct damages that exceed the lowest applicable per repair Benefit Limit, or, if there is no maximum Benefit Limit, any actual losses or direct damages that exceed the cost of repairs provided for in the “What is a Covered Repair?” section(s) of this Service Agreement, relating to any repairs performed by Us, SLWA, HomeServe or on behalf of either Us Us, SLWA or HomeServe or services provided hereunder giving rise to such loss or damage; or (b) any amount of any form of indirect, special, punitive, incidental or consequential losses or damages, damages based on anticipated or lost profits, wages, or revenue, or damages based on diminution in value or a multiple of earnings, including those caused by any fault, failure, delay or defect in providing any repairs performed by Us, SLWA, HomeServe or on behalf of either Us Us, SLWA or HomeServe or services provided under this Service Agreement, regardless of whether such damages were foreseeable and whether or not We We, SLWA or HomeServe or anyone acting on behalf of either Us Us, SLWA or HomeServe have been advised of the possibility of such damages (the damages listed in clauses (a) and (b), collectively the “Excluded Damages”); and (2) these limitations and waivers shall apply to all claims and all liabilities and shall survive the cancellation or expiration of this Service Agreement. You may have other rights that vary from state to state. Arbitration: YOU, NHRW NAW, SLWA AND HOMESERVE ALL AGREE TO RESOLVE DISPUTES BY BINDING ARBITRATION as follows:

Appears in 3 contracts

Samples: Service Agreement, Service Agreement, Service Agreement

Limits of Liability. To the fullest extent permitted by applicable law, (1) You agree that We and HomeServeSLWC, and both of our Our respective parents, successors, affiliates, approved technicians and Our and their officers, directors, employees, affiliates, agents, contractors or similar parties acting on behalf of either Us or HomeServe SLWC shall not be liable to You or anyone else for: (a) any actual losses or direct damages that exceed the lowest applicable per repair Benefit Limit, or, if there is no maximum Benefit Limit, any actual losses or direct damages that exceed the cost of repairs provided for in the “What is a Covered Repair?” section(s) of this Service Agreement, relating to any repairs performed by Us, HomeServe SLWC or on behalf of either Us or HomeServe SLWC or services provided hereunder giving rise to such loss or damage; or (b) any amount of any form of indirect, special, punitive, incidental or consequential losses or damages, damages based on anticipated or lost profits, wages, or revenue, or damages based on diminution in value or a multiple of earnings, including those caused by any fault, failure, delay or defect in providing any repairs performed by Us, HomeServe SLWC or on behalf of either Us or HomeServe SLWC or services provided under this Service Agreement, regardless of whether such damages were foreseeable and whether or not We or HomeServe SLWC or anyone acting on behalf of either Us or HomeServe SLWC have been advised of the possibility of such damages (the damages listed in clauses (a) and (b), collectively the “Excluded Damages”); and (2) these limitations and waivers shall apply to all claims and all liabilities and shall survive the cancellation or expiration of this Service Agreement. You may have other rights that vary from state to statebetween provinces and territories. Arbitration: YOU, NHRW NORTHCOAST AND HOMESERVE SLWC ALL AGREE TO RESOLVE DISAGREEMENTS OR DISPUTES ONLY BY FINAL AND BINDING ARBITRATION OR IN SMALL CLAIMS COURT as follows:

Appears in 3 contracts

Samples: Service Agreement, Service Agreement, Service Agreement

Limits of Liability. To the fullest extent permitted by applicable law, (1) You agree that We We, CSP, and HomeServe, and both all of our respective parents, successors, affiliates, approved technicians and Our and their officers, directors, employees, affiliates, agents, contractors or similar parties acting on behalf of either Us Us, CSP, or HomeServe shall not be liable to You or anyone else for: (a) any actual losses or direct damages that exceed the lowest applicable per repair Benefit Limit, or, if there is no maximum Benefit Limit, any actual losses or direct damages that exceed the cost of repairs provided for in the “What is a Covered Repair?” section(s) of this Service Agreement, relating to any repairs performed by Us, CSP, HomeServe or on behalf of either Us Us, CSP, or HomeServe or services provided hereunder giving rise to such loss or damage; or (b) any amount of any form of indirect, special, punitive, incidental or consequential losses or damages, damages based on anticipated or lost profits, wages, or revenue, or damages based on diminution in value or a multiple of earnings, including those caused by any fault, failure, delay or defect in providing any repairs performed by Us, CSP, HomeServe or on behalf of either Us or HomeServe or services provided under this Service Agreement, regardless of whether such damages were foreseeable and whether or not We We, CSP, or HomeServe or anyone acting on behalf of either Us Us, CSP, or HomeServe have been advised of the possibility of such damages (the damages listed in clauses (a) and (b), collectively the “Excluded Damages”); and (2) these limitations and waivers shall apply to all claims and all liabilities and shall survive the cancellation or expiration of this Service Agreement. You may have other rights that vary from state to state. Arbitration: YOU, NHRW NAW, CSP, AND HOMESERVE ALL AGREE TO RESOLVE DISPUTES BY BINDING ARBITRATION as follows:

Appears in 3 contracts

Samples: Gas Line Terms and Conditions, Service Agreement, Service Agreement

AutoNDA by SimpleDocs

Limits of Liability. To the fullest extent permitted by applicable law, (1) You agree that We and HomeServe, and both of our respective parents, successors, affiliates, approved technicians and Our and their officers, directors, employees, affiliates, agents, contractors or similar parties acting on behalf of either Us or HomeServe shall not be liable to You or anyone else for: (a) any actual losses or direct damages that exceed the lowest applicable per repair Benefit Limit, or, if there is no maximum Benefit Limit, any actual losses or direct damages that exceed the cost of repairs work provided for in the “What is a Covered Repairincluded?” section(s) section of this Service Agreement, relating to any repairs work performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided hereunder giving rise to such loss or damage; or (b) any amount of any form of indirect, special, punitive, incidental or consequential losses or damages, damages based on anticipated or lost profits, wages, or revenue, or damages based on diminution in value or a multiple of earnings, including those caused by any fault, failure, delay or defect in providing any repairs work performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided under this Service Agreement, regardless of whether such damages were foreseeable and whether or not We or HomeServe or anyone acting on behalf of either Us or HomeServe have been advised of the possibility of such damages (the damages listed in clauses (a) and (b), collectively the “Excluded Damages”); and (2) these limitations and waivers shall apply to all claims and all liabilities and shall survive the cancellation or expiration of this Service Agreement. You may have other rights that vary from state to state. Arbitration: YOU, NHRW OLYMPIC AIRE AND HOMESERVE ALL AGREE TO RESOLVE DISPUTES BY BINDING ARBITRATION as follows:

Appears in 2 contracts

Samples: Service Agreement, Service Agreement

Limits of Liability. To the fullest extent permitted by applicable law, (1) You agree that We and HomeServe, and both of our respective parents, successors, affiliates, approved technicians and Our and their officers, directors, employees, affiliates, agents, contractors or similar parties acting on behalf of either Us or HomeServe shall not be liable to You or anyone else for: (a) any actual losses or direct damages that exceed the lowest applicable per repair Benefit Limit, or, if there is no maximum Benefit Limit, any actual losses or direct damages that exceed the cost of repairs provided for in the “What is a Covered Repair?” section(s) of this Service Agreement, relating to any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided hereunder giving rise to such loss or damage; or (b) any amount of any form of indirect, special, punitive, incidental or consequential losses or damages, damages based on anticipated or lost profits, wages, or revenue, or damages based on diminution in value or a multiple of earnings, including those caused by any fault, failure, delay or defect in providing any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided under this Service Agreement, regardless of whether such damages were foreseeable and whether or not We or HomeServe or anyone acting on behalf of either Us or HomeServe have been advised of the possibility of such damages (the damages listed in clauses (a) and (b), collectively the “Excluded Damages”); and (2) these limitations and waivers shall apply to all claims and all liabilities and shall survive the cancellation or expiration of this Service Agreement. You may have other rights that vary from state to state. Arbitration: YOU, NHRW PROVIDER AND HOMESERVE ALL AGREE TO RESOLVE DISPUTES BY BINDING ARBITRATION as follows:

Appears in 2 contracts

Samples: Service Agreement, Service Agreement

Limits of Liability. We will not be responsible for loss or damages due to or resulting from: changes in fuel consumption; improper operation of attic fan or alternate fuel device; your failure to schedule service and or tune-ups; acts of God; terrorism; strikes; riots; material or labor shortages; fire; flood; hurricane; power interruption or loss; accidents; governmental acts; abuse or misuse of equipment; spontaneous part failure; insufficient water; frozen or jellied pipes/lines; or any other conditions beyond our reasonable control, including a vacant, unattended or unoccupied premises (in this Agreement, the term “vacant or unattended premises” shall mean premises at which no adult occupant is present for at least twenty-four (24) consecutive hours). TO THE MAXIMUM EXTENT PERMITTED BY LAW, we will have no liability for direct or indirect, special or consequential damages of any kind. We are not responsible for secondary damage as a result of delay in rendering service. To the fullest extent any warranty exists, our liability for any warranty claim will be limited, as permitted by applicable law, (1) You agree that We and HomeServe, and both to the repair or replacement of our respective parents, successors, affiliates, approved technicians and Our and their officers, directors, employees, affiliates, agents, contractors or similar parties acting on behalf of either Us or HomeServe shall not be liable to You or anyone else for: (a) any actual losses or direct damages that exceed the lowest applicable per repair Benefit Limit, or, if there is no maximum Benefit Limit, any actual losses or direct damages that exceed the cost of repairs provided for in the “What is a Covered Repair?” section(s) of this Service Agreement, relating to any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided hereunder giving rise to such loss or damage; or (b) any amount of any form of indirect, special, punitive, incidental or consequential losses or damages, damages based on anticipated or lost profits, wages, or revenue, or damages based on diminution in value or a multiple of earnings, including those caused by any fault, failure, delay or defect in providing any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe defective parts or services provided under this Service Agreement. Any and all actions, regardless of whether such damages were foreseeable based in contract or tort, whether for personal injury or property damage, and whether brought by Buyer or not We or HomeServe or anyone acting on behalf of either Us or HomeServe have been advised Buyer’s insurance company, must be commenced within one year of the possibility cause of such damages (the damages listed in clauses (a) and (b)action or shall be barred as a matter of law. IN NO EVENT SHALL OUR LIABILITY TO YOU OR OTHERS UNDER THIS AGREEMENT OR OTHERWISE EXCEED $1,000, collectively the “Excluded Damages”); and (2) these limitations and waivers shall apply to all claims and all liabilities and shall survive the cancellation or expiration of this Service Agreement. You may have other rights that vary from state to state. Arbitration: YOU, NHRW AND HOMESERVE ALL AGREE TO RESOLVE DISPUTES BY BINDING ARBITRATION as follows:INCLUDING ANY LIABILITY UNDER SECTION 11.

Appears in 1 contract

Samples: Terms and Conditions

Limits of Liability. To the fullest extent permitted by applicable law, (1) You agree that We and We, HomeServe, and both all of our respective parents, successors, affiliates, approved technicians and Our and their officers, directors, employees, affiliates, agents, contractors or similar parties acting on behalf of either Us Us, or HomeServe shall not be liable to You You, Your Customers, or anyone else for: (a) any actual losses or direct damages that exceed the lowest applicable per repair Benefit Limit, or, if there is no maximum Benefit Limit, any actual losses or direct damages that exceed the cost of repairs provided for in the “What is a Covered Repair?” section(s) of this Service Agreement, relating to any repairs performed by UsUs or HomeServe, HomeServe or on behalf of either Us or HomeServe HomeServe, or services provided hereunder giving rise to such loss or damage; or (b) any amount of any form of indirect, special, punitive, incidental or consequential losses or damages, damages based on anticipated or lost profits, wages, or revenue, or damages based on diminution in value or a multiple of earnings, including those caused by any fault, failure, delay or defect in providing any repairs performed by UsUs or HomeServe, HomeServe or on behalf of either Us or HomeServe HomeServe, or services provided under this Service Agreement, regardless of whether such damages were foreseeable and whether or not We or HomeServe HomeServe, or anyone acting on behalf of either Us or HomeServe HomeServe, have been advised of the possibility of such damages (the damages listed in clauses (a) and (b), collectively the “Excluded Damages”); and (2) these limitations and waivers shall apply to all claims and all liabilities and shall survive the cancellation or expiration of this Service Agreement. You may have other rights that vary from state to state. Arbitration: YOU, NHRW SLWA, AND HOMESERVE ALL AGREE TO RESOLVE DISPUTES BY BINDING ARBITRATION as follows:

Appears in 1 contract

Samples: Service Agreement

Limits of Liability. To the fullest extent permitted by applicable law, (1) You agree that We and HomeServe, and both of our respective parents, successors, affiliates, approved technicians and Our and their officers, directors, employees, affiliates, agents, contractors or similar parties acting on behalf of either Us or HomeServe shall not be liable to You or anyone else for: (a) any actual losses or direct damages that exceed the lowest applicable per repair Benefit Limit, or, if there is no maximum Benefit Limit, any actual losses or direct damages that exceed the cost of repairs provided for in the “What is a Covered Repair?” section(s) of this Service Agreement, relating to any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided hereunder giving rise to such loss or damage; or (b) any amount of any form of indirect, special, punitive, incidental or consequential losses or damages, damages based on anticipated or lost profits, wages, or revenue, or damages based on diminution in value or a multiple of earnings, including those caused by any fault, failure, delay or defect in providing any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided under this Service Agreement, regardless of whether such damages were foreseeable and whether or not We or HomeServe or anyone acting on behalf of either Us or HomeServe have been advised of the possibility of such damages (the damages listed in clauses (a) and (b), collectively the “Excluded Damages”); and (2) these limitations and waivers shall apply to all claims and all liabilities and shall survive the cancellation or expiration of this Service Agreement. You may have other rights that vary from state to state. Arbitration: YOU, NHRW YOU CNA AND HOMESERVE ALL AGREE TO RESOLVE DISPUTES BY BINDING ARBITRATION as follows:

Appears in 1 contract

Samples: Service Agreement

Limits of Liability. To the fullest extent permitted by applicable law, (1) You agree that We and HomeServe, and both of our respective parents, successors, affiliates, approved technicians and Our and their officers, directors, employees, affiliates, agents, contractors or similar parties acting on behalf of either Us or HomeServe shall not be liable to You or anyone else for: (a) any actual losses or direct damages that exceed the lowest applicable per repair Benefit Limit, or, if there is no maximum Benefit Limit, any actual losses or direct damages that exceed the cost of repairs provided for in the “What is a Covered Repair?” section(s) of this Service Agreement, relating to any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided hereunder giving rise to such loss or damage; or (b) any amount of any form of indirect, special, punitive, incidental or consequential losses or damages, damages based on anticipated or lost profits, wages, or revenue, or damages based on diminution in value or a multiple of earnings, including those caused by any fault, failure, delay or defect in providing any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided under this Service Agreement, regardless of whether such damages were foreseeable and whether or not We or HomeServe or anyone acting on behalf of either Us or HomeServe have been advised of the possibility of such damages (the damages listed in clauses (a) and (b), collectively the “Excluded Damages”); and (2) these limitations and waivers shall apply to all claims and all liabilities and shall survive the cancellation or expiration of this Service Agreement. You may have other rights that vary from state to statebetween provinces and territories. Arbitration: YOU, NHRW NORTHCOAST AND HOMESERVE ALL AGREE TO RESOLVE DISAGREEMENTS OR DISPUTES ONLY BY FINAL AND BINDING ARBITRATION OR IN SMALL CLAIMS COURT as follows:

Appears in 1 contract

Samples: Service Agreement

Limits of Liability. To the fullest extent permitted by applicable law, (1) You agree that We and HomeServe, and both of our respective parents, successors, affiliates, approved technicians and Our our and their officers, directors, employees, affiliates, agents, contractors or similar parties acting on behalf of either Us or HomeServe shall not be liable to You or anyone else for: (a) any actual losses or direct damages that exceed the lowest applicable per repair Benefit Protection Limit, or, if there is no maximum Benefit Protection Limit, any actual losses or direct damages that exceed the cost of repairs provided for in the “What is a Covered Repair?” section(s) of this Service Agreement, relating to any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided hereunder giving rise to such loss or damage; or (b) any amount of any form of indirect, special, punitive, incidental or consequential losses or damages, damages based on anticipated or lost profits, wages, or revenue, or damages based on diminution in value or a multiple of earnings, including those caused by any fault, failure, delay or defect in providing any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided under this Service Agreement, regardless of whether such damages were foreseeable and whether or not We or HomeServe or anyone acting on behalf of either Us or HomeServe have been advised of the possibility of such damages (the damages listed in clauses (a) and (b), collectively the “Excluded Damages”); and (2) these limitations and waivers shall apply to all claims and all liabilities and shall survive the cancellation or expiration of this Service Agreement. You may have other rights that vary from state to statebetween provinces and territories. Arbitration: YOU, NHRW NORTHCOAST AND HOMESERVE ALL AGREE TO RESOLVE DISAGREEMENTS OR DISPUTES ONLY BY FINAL AND BINDING ARBITRATION OR IN SMALL CLAIMS COURT as follows:

Appears in 1 contract

Samples: Service Agreement

Limits of Liability. To the fullest extent permitted by applicable law, (1) You agree that We and We, SLWA, HomeServe, and both all of our respective parents, successors, affiliates, approved technicians and Our and their officers, directors, employees, affiliates, agents, contractors or similar parties acting on behalf of either Us Us, SLWA, or HomeServe shall not be liable to You or anyone else for: (a) any actual losses or direct damages that exceed the lowest applicable per repair Benefit Limit, or, if there is no maximum Benefit Limit, any actual losses or direct damages that exceed the cost of repairs provided for in the “What is a Covered Repair?” section(s) of this Service Agreement, relating to any repairs performed by Us, SLWA, HomeServe or on behalf of either Us Us, SLWA, or HomeServe or services provided hereunder giving rise to such loss or damage; or (b) any amount of any form of indirect, special, punitive, incidental or consequential losses or damages, damages based on anticipated or lost profits, wages, or revenue, or damages based on diminution in value or a multiple of earnings, including those caused by any fault, failure, delay or defect in providing any repairs performed by Us, SLWA, HomeServe or on behalf of either Us Us, SLWA, or HomeServe or services provided under this Service Agreement, regardless of whether such damages were foreseeable and whether or not We We, SLWA, or HomeServe or anyone acting on behalf of either Us Us, SLWA, or HomeServe have been advised of the possibility of such damages (the damages listed in clauses (a) and (b), collectively the “Excluded Damages”); and (2) these limitations and waivers shall apply to all claims and all liabilities and shall survive the cancellation or expiration of this Service Agreement. You may have other rights that vary from state to state. Arbitration: YOU, NHRW NAW, SLWA, AND HOMESERVE ALL AGREE TO RESOLVE DISPUTES BY BINDING ARBITRATION as follows:

Appears in 1 contract

Samples: Service Agreement

Limits of Liability. To the fullest extent permitted by applicable law, (1) You agree that We and HomeServe, and both of our respective parents, successors, affiliates, approved technicians and Our our and their officers, directors, employees, affiliates, agents, contractors or similar parties acting on behalf of either Us or HomeServe shall not be liable to You or anyone else for: (a) any actual losses or direct damages that exceed the lowest applicable per repair Benefit Limit, or, if there is no maximum Benefit Limit, any actual losses or direct damages that exceed the cost of repairs provided for in the “What is a Covered Repair?” section(s) of this Service Agreement, relating to any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided hereunder giving rise to such loss or damage; or (b) any amount of any form of indirect, special, punitive, incidental or consequential losses or damages, damages based on anticipated or lost profits, wages, or revenue, or damages based on diminution in value or a multiple of earnings, including those caused by any fault, failure, delay or defect in providing any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided under this Service Agreement, regardless of whether such damages were foreseeable and whether or not We or HomeServe or anyone acting on behalf of either Us or HomeServe have been advised of the possibility of such damages (the damages listed in clauses (a) and (b), collectively the “Excluded Damages”); and (2) these limitations and waivers shall apply to all claims and all liabilities and shall survive the cancellation or expiration of this Service Agreement. You may have other rights that vary from state to statebetween provinces and territories. Arbitration: YOU, NHRW NORTHCOAST AND HOMESERVE ALL AGREE TO RESOLVE DISAGREEMENTS OR DISPUTES ONLY BY FINAL AND BINDING ARBITRATION OR IN SMALL CLAIMS COURT as follows:

Appears in 1 contract

Samples: Service Agreement

Time is Money Join Law Insider Premium to draft better contracts faster.