Effect of Failure to Comply Failure to comply with reporting requirements shall result in the withholding of funds, the return of improper payments or Unallowable Costs, will be considered a material breach of this Agreement and may be the basis to recover Grant Funds. Grantee's failure to comply with this ARTICLE XIII, ARTICLE XIV, or ARTICLE XV shall be considered prima facie evidence of a breach and may be admitted as such, without further proof, into evidence in an administrative proceeding before Grantor, or in any other legal proceeding. Grantee should refer to the State of Illinois Grantee Compliance Enforcement System for policy and consequences for failure to comply.
Failure to Comply 8.2.1 If the Developer fails to observe or perform any condition of this Agreement after the Municipality has given the Developer thirty (30) days written notice of the failure or default, then in each such case:
Failure to Complete If Artist becomes ill, dies, or is otherwise unable or unwilling to complete the Project in accordance with the Agreement, any work already done on the Project will be the City’s property. The City will be entitled to withhold any sums not yet paid to Artist, and may use any such sums toward completion of the Project in any manner the City deems appropriate.
Indemnity by Tenant To the extent permitted by Law, Tenant hereby indemnifies, and agrees to protect, defend and hold the Indemnitees harmless, against any and all actions, claims, demands, liability, costs and expenses, including attorneys’ fees and expenses for the defense thereof, arising from Tenant’s occupancy of the Premises, from the undertaking of any Tenant Additions or repairs to the Premises, from the conduct of Tenant’s business on the Premises, or from any breach or default on the part of Tenant in the performance of any covenant or agreement on the part of Tenant to be performed pursuant to the terms of this Lease, or from any willful act or negligence of Tenant, its agents, contractors, servants, employees, customers or invitees, in or about the Premises or the Property or any part of either. In case of any action or proceeding brought against the Indemnitees by reason of any such claim, upon notice from Landlord, Tenant covenants to defend such action or proceeding by counsel chosen by Landlord, in Landlord’s sole discretion. Landlord reserves the right to settle, compromise or dispose of any and all actions, claims and demands related to the foregoing indemnity. The foregoing indemnity shall not operate to relieve Indemnitees of liability to the extent such liability is caused by the willful and wrongful act of Indemnitees. Further, the foregoing indemnity is subject to and shall not diminish any waivers in effect in accordance with Section 16.04 by Landlord or its insurers to the extent of amounts, if any, paid to Landlord under its “All-Risks” property insurance.
Notice by Tenant Tenant shall give immediate notice to Landlord in case of fire or accidents in the Premises or in the building of which the Premises are a part or of defects therein or in any fixtures or equipment.
Waiver by Tenant Tenant waives the benefits of any statute now or hereafter in effect which would otherwise afford Tenant the right to make repairs at Landlord’s expense or to terminate this Lease because of Landlord’s failure to keep the Premises in good order, condition, and repair.
Maintenance by Tenant Tenant shall keep the Premises, including all windows, signs, and sidewalks, service ways, loading areas adjacent to the Premises, landscaping and irrigation systems (if any), and all paved surfaces and parking lots (including striping of the parking lot and preventing potholes and other surface inadequacies based on the intended purpose of such paved surfaces and parking lots) in good, clean, rubbish-free condition, free from waste and nuisance at all times, reasonable wear and tear and damage by casualty excepted. Tenant shall, subject to Landlord's maintenance responsibilities provided for above, make all needed repairs, including without being limited to, maintenance of all direct utility connections and replacement of any cracked or broken windows or other glass. Tenant shall, at Tenant's expense, keep in good working condition the heating, ventilating, and air conditioning systems, the sprinkler system, if any, and the water heater, maintaining, repairing, and replacing such items as may be necessary from time to time, reasonable wear and tear and damage by casualty excepted. Tenant shall comply at its sole cost and expense with all governmental laws, ordinances, and regulations which must be complied with by reason of the nature of the use of the Premises by Tenant, except that Tenant shall not be obligated to make any structural changes or alterations to the Premises in order to comply therewith unless made necessary by the negligent act or omission of Tenant, in which event Tenant shall comply at its expense in accordance with plans and specifications approved by Landlord. If any repairs or replacements required to be made by Tenant hereunder are not made within fifteen (15) days after written notice delivered to Tenant by Landlord, Landlord may, at its option, make such repairs or replacements without liability to Tenant for any loss or damage which may result to its stock or business by reason of such repairs or replacements, and Tenant shall pay to Landlord upon demand as additional rental hereunder the cost of such repairs and replacements, plus interest at a rate equal to the lower of eight percent (8%) per annum, or the maximum rate permitted by the usury laws of the State of Texas, from the date of payment by Landlord until Landlord is repaid by Tenant.
Repairs by Tenant Tenant shall, at its sole cost and expense, promptly perform all maintenance, repairs, refurbishing and replacement work to the Leased Premises that are not Landlord’s express responsibility under this Lease, and shall keep the Leased Premises in good condition and repair, reasonable wear and tear excepted. Tenant’s repair obligations include repairs to: (a) floor covering, (b) interior partitions, (c) doors, (d) the interior side of demising walls, (e) electronic, phone and data cabling and related equipment that is installed by or for the exclusive benefit of Tenant and located in the Leased Premises or other portions of the Building, (f) supplemental air conditioning units, private showers and kitchens, including hot water heaters, plumbing and similar facilities serving Tenant exclusively, and (g) alterations performed by contractors retained by Tenant, including related HVAC balancing. All Tenant’s work shall be performed in accordance with the rules and procedures described in Section 5.2 hereof. Upon termination of this Lease, Tenant will surrender and deliver the Leased Premises to Landlord in the same condition in which the Leased Premises existed on the Commencement Date, subject, however, to (i) the provisions of Article VI hereof, (ii) the alterations permitted pursuant to this Lease, (iii) the provisions of Section 5.3, and (iv) except for ordinary wear and tear. If Tenant should fail or refuse to make such repairs, refurbishings or replacements or perform said maintenance as and when reasonably required, Landlord may, at its option, but without any obligation to do so, cure such failure or refusal and Landlord’s costs shall be reimburseable by Tenant as additional rent, by Tenant, immediately upon invoicing by Landlord. Notwithstanding the foregoing, Landlord agrees to perform, as Above Standard Services, Tenant’s repair and maintenance obligations with respect to the Leased Premises. Tenant shall notify Landlord of the need for any such repair and maintenance and Landlord shall endeavor to respond timely to each such request.
Tenant’s Remedies Notwithstanding any other provision of this Lease, if any default hereunder by Landlord is not cured within the applicable cure period provided in Paragraph 20(c) or any other applicable CERTAIN CONFIDENTIAL PORTIONS OF THIS EXHIBIT WERE OMITTED AND REPLACED WITH “[***]”. A COMPLETE VERSION OF THIS EXHIBIT HAS BEEN FILED SEPARATELY WITH THE SECRETARY OF THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO AN APPLICATION REQUESTING CONFIDENTIAL TREATMENT UNDER RULE 406 OF THE SECURITIES ACT OF 1933. cure period provided in this Lease (including any Mortgagee’s additional cure period), Tenant’s exclusive remedies shall be (i) an action for specific performance, or (ii) an action for actual damages. Notwithstanding any other provision of this Lease, the liability of Landlord to Tenant for any breach or default by Landlord under the terms of this Lease, or for any other matter related to this Lease or to the Premises or Project, shall be limited to Tenant’s actual direct, but not consequential, damages therefor, and any judgment against Landlord in connection therewith shall be recoverable only from the interest of Landlord in the Buildings. Tenant hereby waives any claim for damages for any disturbance, loss of business, nuisance, injury or inconvenience to or interference with Tenant’s business, any loss of occupancy or quiet enjoyment of the Premises, and any other loss arising from Landlord’s entry and acts pursuant to Paragraph 18 or otherwise with respect to any act, omission or breach of Landlord. Without limiting the preceding sentence, in no event shall Landlord be liable to Tenant for any consequential damages, including, without limitation, any losses arising from any interruption of Tenant’s business, or for lost profits, or for charges or expenses which continue but would have been earned if the business had gone on without interruption, or for any other loss, claim, cost, expense or damage which would be covered by a standard policy of business interruption insurance. Landlord, or if Landlord is a partnership its partners whether general or limited, or if Landlord is a corporation its directors, officers or shareholders, or if Landlord is a limited liability company its members or managers, shall never be personally liable for any such judgment. Any lien obtained to enforce such judgment and any levy of execution thereon shall be subject and subordinate to any Mortgage (excluding any Mortgage which was created as part of an effort to defraud creditors, i.e., a fraudulent conveyance); provided, however that any such judgment and any such levy of execution thereon shall not be subject or subordinated to any Mortgage that is created or recorded in the official records of the county in which the Project is located after the date of the judgment giving rise to such lien. Landlord’s interest in the Buildings shall include any insurance proceeds received by Landlord which are not controlled by any Mortgagee or other lender. Tenant hereby waives the benefit of any Laws granting it (A) the right to perform Landlord’s obligations, or (B) the right to terminate this Lease or withhold Rent on account of any Landlord default, including, without limitation, Sections 1932(1), 1941 and 1942 of the California Civil Code.
Alterations by Tenant Tenant shall not make any alterations, renovations, improvements or other installations (collectively “Alterations”) in, on or to any part of the Premises (including, without limitation, any alterations of the front, signs, structural alterations, or any cutting or drilling into any part of the Premises or any securing of any fixture, apparatus, or equipment of any kind to any part of the Premises) unless and until Tenant shall have caused plans and specifications therefore to have been prepared, at Tenant’s expense, by an architect or other duly qualified person and shall have obtained Landlord’s approval thereof. Tenant shall submit to Landlord detailed drawings and plans of the proposed Alterations at the time Landlord’s approval is sought. If such approval is granted, Tenant shall cause the work described in such plans and specifications to be performed, at its expense, promptly, efficiently, competently and in a good and workmanlike manner by duly qualified and licensed persons or entities approved by Landlord, using first grade materials. All such work shall comply with all applicable codes, rules, regulations and ordinances. The Tenant shall at all times maintain fire insurance with extended coverage in an amount adequate to cover the cost of replacement of all alterations, decorations, additions or improvements to the Premises by Tenant in the event of fire or extended coverage loss. Tenant shall deliver to the Landlord certificates of such fire insurance policies, which shall contain a clause requiring the insurer to give the Landlord ten (10) days notice of cancellation of such policies.
