FAA Noise and Emissions Requirements for Changes to a Sample Clauses

FAA Noise and Emissions Requirements for Changes to a. Type Design (TC/STC) by Any Person. For the purpose of complying with 14 CFR Part 34, each voluntary change in the type design of an airplane that may increase fuel venting or exhaust emissions is an “emissions change,” requiring further demonstration of compliance. Likewise, for the purpose of complying with 14 CFR Part 36, each voluntary change in the type design of an aircraft that may increase the noise levels of that aircraft is an “acoustical change,” requiring further demonstration of compliance. The FAA retains all findings of acoustical or emissions change under 14 CFR § 21.93(b) & (c).
Sample 1
AutoNDA by SimpleDocs

Related to FAA Noise and Emissions Requirements for Changes to a

  • Forecasting Requirements for Trunk Provisioning Within ninety (90) days of executing this Agreement, Reconex shall provide Verizon a two (2) year traffic forecast. This initial forecast will provide the amount of traffic to be delivered to and from Verizon over each of the Local Interconnection Trunk groups over the next eight (8) quarters. The forecast shall be updated and provided to Verizon on an as-needed basis but no less frequently than semiannually. All forecasts shall comply with the Verizon CLEC Interconnection Trunking Forecast Guide and shall include, at a minimum, Access Carrier Terminal Location (“ACTL”), traffic type (Local Traffic/Toll Traffic, Operator Services, 911, etc.), code (identifies trunk group), A location/Z location (CLLI codes for Reconex-IPs and Verizon-IPs), interface type (e.g., DS1), and trunks in service each year (cumulative).

  • Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.

  • Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.

  • Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.

  • Changes to Scope of Work The City of Nashua may, at any time, by written order, make changes to the general scope, character, or cost of this contract and in the services or work to be performed, either increasing or decreasing the scope, character, or cost of Independent Contractor's performance under the contract. Independent Contractor shall provide to the City of Nashua within 10 calendar days, a written proposal for accomplishing the change. The proposal for a change shall provide enough detail, including personnel hours for each sub-task and cost breakdowns of tasks, for the City of Nashua to be able to adequately analyze the proposal. The City of Nashua will then determine in writing if Independent Contractor should proceed with any or all of the proposed change. If the change causes an increase or a decrease in Independent Contractor's cost or time required for performance of the contract as a whole, an equitable adjustment shall be made and the contract accordingly modified in writing. Any claim of Independent Contractor for adjustment under this clause shall be asserted in writing within 30 days of the date the City of Nashua notified Independent Contractor of the change. When Independent Contractor seeks changes, Independent Contractor shall, before any work commences, estimate their effect on the cost of the contract and on its schedule and notify the City of Nashua in writing of the estimate. The proposal for a change shall provide enough detail, including personnel hours for each sub-task and cost breakdowns of tasks, for the City of Nashua to be able to adequately analyze the proposal. The City of Nashua will then determine in writing if Independent Contractor should proceed with any or all of the proposed change. Except as provided in this paragraph, Independent Contractor shall implement no change unless the City of Nashua in writing approves the change. Unless otherwise agreed to in writing, the provisions of this contract shall apply to all changes. The City of Nashua may provide verbal approval of a change when the City of Nashua, in its sole discretion, determines that time is critical or public health and safety are of concern. Any verbal approval shall be confirmed in writing as soon as practicable. Any change undertaken without prior City of Nashua approval shall not be compensated and is, at the City of Nashua's election, sufficient reason for contract termination.

  • Changes to Agreement We reserve the right to change any of the terms of this Agreement or any Specifications or Guidelines governing the Service at any time in our sole discretion. All changes will be effective upon posting to the Service. However, for all changes to this Agreement, excluding Specifications and Guidelines, we will post a notice of change for thirty (30) days. You are responsible for reviewing the notice and any applicable changes. YOUR CONTINUED USE OF THIS SERVICE FOLLOWING OUR POSTING OF ANY CHANGES WILL CONSTITUTE YOUR ACCEPTANCE OF SUCH CHANGES. 11) Prime Publishing Intellectual Property. Without our prior written consent, you may not use our intellectual property, including, without limitation, our trademarks, trade names, trade dress, or copyrighted material, in any manner. 12) Communications. Prime Publishing and its Affiliates may communicate with you in connection with the Service, electronically and in other Media, and you consent to such communications regardless of any "Customer Communication Preferences" (or similar preferences or requests) you may have indicated on the web sites of Prime Publishing or its Affiliates or by any other means. 13) Waiver. PRIME PUBLISHING AND ITS AFFILIATES WILL NOT BE LIABLE FOR ANY INDIRECT, INCIDENTAL, OR CONSEQUENTIAL DAMAGES (INCLUDING BUT NOT LIMITED TO SUCH DAMAGES ARISING FROM BREACH OF CONTRACT OR WARRANTY OR FROM NEGLIGENCE OR STRICT LIABILITY) ARISING OUT OF OR IN CONNECTION WITH THIS AGREEMENT, EVEN IF WE HAVE BEEN ADVISED OF (OR KNEW OR SHOULD KNOWN OF) THE POSSIBILITY OF SUCH DAMAGES. 14) Disclaimer. PRIME PUBLISHING PROVIDES THE SERVICE "AS IS" WITHOUT WARRANTY OF ANY KIND. 15)

  • NMHS Governance, Safety and Quality Requirements 3.1 Participates in the maintenance of a safe work environment.

  • Certain State Law Requirements for Contracts The contents of this Section are required by Texas Law and are included by County regardless of content.

  • Amendments - Changes/Extra Work The Subrecipient shall make no changes to this Contract without the County’s written consent. In the event that there are new or unforeseen requirements, the County has the discretion with the Subrecipient’s concurrence, to make changes at any time without changing the scope or price of the Contract.‌ If County-initiated changes or changes in laws or government regulations affect price, the Subrecipient’s ability to deliver services, or the project schedule, the Subrecipient will give County written notice no later ten (10) days from the date the law or regulation went into effect or the date the change was proposed and Subrecipient was notified of the change. Such changes shall be agreed to in writing and incorporated into a Contract amendment. Said amendment shall be issued by the County-assigned Contract Administrator, shall require the mutual consent of all Parties, and may be subject to approval by the County Board of Supervisors. Nothing herein shall prohibit the Subrecipient from proceeding with the work as originally set forth or as previously amended in this Contract.

  • Changes to tariffs and charges (a) If we vary our standing offer prices, we will publish the variation in a newspaper and on our website at least 10 business days before it starts. We will also include details with your next bill if the variation affects you.

Time is Money Join Law Insider Premium to draft better contracts faster.