DETERMINATION OF LIQUIDATED DAMAGES Sample Clauses

DETERMINATION OF LIQUIDATED DAMAGES. IF ESCROW FAILS TO CLOSE BECAUSE OF BUYER’S DEFAULT UNDER THIS AGREEMENT, SELLER WILL BE DAMAGED AND WILL BE ENTITLED TO COMPENSATION FOR THESE DAMAGES. SUCH DAMAGES WILL BE EXTREMELY DIFFICULT AND IMPRACTICAL TO ASCERTAIN FOR THE FOLLOWING REASONS: (i) THE DAMAGES TO WHICH SELLER WILL BE ENTITLED IN A COURT OF LAW WILL BE BASED ON THE DIFFERENCE BETWEEN THE ACTUAL VALUE OF THE PROPERTY AS OF THE CLOSING DATE AND THE PURCHASE PRICE FOR THE PROPERTY AS SET FORTH IN THIS AGREEMENT, WHICH DIFFERENCE MUST BE BASED ON OPINIONS OF VALUE OF THE PROPERTY WHICH CAN VARY IN SIGNIFICANT AMOUNTS; (ii) SELLER WILL PROBABLY NOT RECOUP THE COST OF ADDITIONAL OPTION ITEMS BUYER REQUESTED IF SELLER RESELLS THE PROPERTY; AND (iii) IT IS IMPOSSIBLE TO PREDICT, AS OF THE EFFECTIVE DATE, WHETHER THE VALUE OF THE PROPERTY WILL INCREASE OR DECREASE AS OF THE CLOSING DATE. BUYER DESIRES TO LIMIT THE AMOUNT OF DAMAGES FOR WHICH BUYER MIGHT BE LIABLE IF BUYER DEFAULTS HEREUNDER. ADDITIONALLY, BOTH PARTIES WANT TO AVOID THE COSTS AND LENGTHY DELAYS RESULTING FROM SELLER FILING A LAWSUIT TO COLLECT ITS ACTUAL DAMAGES DUE TO BUYER'S DEFAULT. THEREFORE, IF BUYER DEFAULTS HEREUNDER, SELLER MAY INSTRUCT ESCROW HOLDER, AS SET FORTH BELOW, TO RETAIN FROM BUYER’S DEPOSITS (THE INITIAL DEPOSIT, THE ADDITIONAL DEPOSIT (IF APPLICABLE), AND ANY OPTION/UPGRADE DEPOSITS) THE GREATER OF: A) THREE PERCENT (3%) OF THE PURCHASE PRICE (INCLUDING OPTIONAL ITEMS), OR
AutoNDA by SimpleDocs
DETERMINATION OF LIQUIDATED DAMAGES. The liquidated damages for each Monthm as expressed in Dollars are determined as follows:
DETERMINATION OF LIQUIDATED DAMAGES 

Related to DETERMINATION OF LIQUIDATED DAMAGES

  • Payment of Liquidated Damages If you supply all or some of your milk to a third party during a Month you must, if required by DFMC, immediately pay to DFMC liquidated damages for that Month calculated as follows: $X = W cents x (Y – Z) Where: $X is the amount payable by you to DFMC for the relevant Month. If $X is a negative amount, no amount is payable by you. Y is the average monthly litres you have supplied to DFMC based on the 12 months immediately preceding the relevant Month (or in the event you have not supplied DFMC for 12 months, the average monthly litres you have supplied to DFMC during the period you have supplied DFMC). Z is the number of litres supplied to DFMC by you for the relevant Month.

  • Notice of Liquidated Damages System Agency will formally notify Grantee in writing when liquidated damages action is imposed, stating the nature of the action, the reasons for imposing, and the method of appealing. Grantee must submit a written appeal, within ten (10) calendar days of receipt of the notice, to the SUD email box, XxxxxxxxxXxxxx.Xxxxxxxxx@xxxx.xxxxx.xx.xx.

  • Withholding for unpaid wages and liquidated damages The FHWA or the contacting agency shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (2.) of this section.

  • CONTRACT TIME AND LIQUIDATED DAMAGES (7-1-95) (Rev. 12-18-07) 108 SP1 G10 A The date of availability for this contract is September 26, 2016. The completion date for this contract is October 31, 2017. Except where otherwise provided by the contract, observation periods required by the contract will not be a part of the work to be completed by the completion date and/or intermediate contract times stated in the contract. The acceptable completion of the observation periods that extend beyond the final completion date shall be a part of the work covered by the performance and payment bonds. The liquidated damages for this contract are Two Thousand Dollars ($ 2,000.00) per calendar day.

  • Liquidated Damages for Delay In addition to the Contractor bearing the actual cost of correcting any non-compliant work or any other actual damages resulting from Contractor’s breach of this Agreement, the Contractor agrees to pay the Contractor delay damages in the amount of $500.00 per day for every day that the goods and/or services to be provided pursuant to this Agreement have not been timely delivered to the District in compliance with the Scope of Services set forth above, unless the delay has been properly excused by the terms of this Agreement. The parties agree that the District’s actual damages for delay are difficult to estimate and that this $500.00 per day sum is a reasonable pre-estimate of the District’s actual damages for each day of delay and that the is $500.00 per day sum is intended by the parties to be in the nature of liquidated damages, not a penalty. It is not the parties’ intent for this provision to limit either party’s remedies against the other for the breach of this Agreement, except for the District’s money damages for unexcused delays caused by the Contractor.

  • Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.

  • Breach of Contract and Liquidated Damages A. Where OGS determines that the Contractor is not in compliance with the requirements of this Contract, and the Contractor refuses to comply with such requirements, or if it is found to have willfully and intentionally failed to comply with the MWBE participation goals set forth in the Contract, the Contractor shall be obligated to pay liquidated damages to OGS.

  • Deduction of Damages from Contract Price Upon prior written notice being issued to the Contractor, CMHA may deduct all or any part of the damages resulting from Contractor’s default from any part of the price still due on this Agreement.

  • Compensation for Damages or Losses When investments by investors of either Contracting Party suffer damages or losses owing to war, armed conflict, a state of national emergency, revolt, insurrection, riot or other similar events in the territory of the other Contracting Party, they shall be accorded by the latter Contracting Party a treatment, as regards compensation or other settlement, not less favourable than that accorded to its own investors or to investors of any Third State.

  • Violation; liability for unpaid wages; liquidated damages In the event of any violation of the clause set forth in paragraph (1.) of this section, the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.

Time is Money Join Law Insider Premium to draft better contracts faster.