Rate Redetermination for Environmental Modification In the event of a contract modification under B8.33 or partial termination under B8.34, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber remaining immediately prior to the revision and the appraised unit value of Included Timber to be cut under the modification. The appraisal shall consider the estimated cost of any construction work listed in the Schedule of Items that was performed and abandoned. Tentative Rates and Flat Rates in effect at the time of the revision will be adjusted by said differences to become Current Contract Rates. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essential reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. However, existing Base Indices shall not be changed under this Subsection. Redetermined rates, or differences for rates subject to B3.2, and Required Deposits shall be considered established under B3.1 for timber Scaled subsequent to the contract revision.
Rate Redetermination Rates may be redetermined as set forth in this Section. Bid Premium Rates shall be added to all redetermined rates, except as provided in B3.31, B3.32, and B3.33. Rate redeterminations shall be made in accordance with the standard Forest Service methods in effect 45 days prior to rate redetermination. Such methods shall take into consideration factors that may affect timber value at rate redetermination date. Redetermined rates shall not be less than Base Rates listed in A4, except for reduction under B3.31, B3.32, or B3.33. Required Deposits shall be redetermined. Redetermined Specified Road construction cost is subject to the limitations of B5.26.
Emergency Rate Redetermination Forest Service shall redetermine rates if, upon Purchaser's application, Forest Service determies that, because of changes in the timber market since the award date or the last rate redetermination under this provision, the Producer Price Index identified in A20 has declined by 25 percent. Rates shall be redetermined under B3.3 and shall be considered established under B3.1 for timber Scaled subsequent to Purchaser's application. This Subsection shall not apply during Contract Term Extension.
Rate Redetermination after Catastro- phic Damage In event of Catastrophic Damage and ad- justment, if any, of Included Timber, Contracting Officer shall make an appraisal to determine for each species the catastrophe-caused difference between the appraised unit value of Included Timber remaining immediately prior to the catastrophe and the appraised unit value of existing and potential Included Timber immediately after the ca- tastrophe. Included Timber is any that would not be elimi- nated under B8.32. Potential Included Timber is any that would be added under B8.32. Tentative Rates and Flat Rates in effect at the time of catastrophe shall be adjusted by said differences to be- come the redetermined rates for the purpose of a contract modification under B8.32. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to new Base Rate limitations of 25 cents per hun- dred cubic feet or equivalent. However, existing Base In- dices shall not be changed under this Subsection. Upon agreement under B8.32, redetermined rates and Required Deposits shall be considered established under B3.1 for timber Scaled subsequent to Catastrophic Damage. At time of such appraisal, Specified Road construc- tion cost shall include the estimated cost of any construc- tion work listed in the Schedule of Items performed and abandoned.
Rate Redetermination for Market Change In the event of delay or interruption, exceeding 90 days, under B8.33, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber immediately prior to the delay or interruption and the appraised unit value of Included Timber immediately after the delay or interruption. The appraisal shall be done after any rate redetermination done pursuant to B3.31, using remaining volumes. Tentative Rates and Flat Rates in effect at the time of delay or interruption or established pursuant to B3.31 will be reduced, if appraised rates declined during the delay or interruption, to become Current Contract Rates. Increases in rates will not be considered. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essential reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. However, existing Base Indices shall not be changed under this Subsection. Redetermined rates shall be considered established under B3.1 for timber Scaled subsequent to the delay or interruption.
Treatment of Unallowable Costs Previously Submitted for Payment Defendants further agree that within 90 days of the Effective Date of this Agreement they shall identify to applicable Medicare and TRICARE fiscal intermediaries, carriers, and/or contractors, and Medicaid and FEHBP fiscal agents, any Unallowable Costs (as defined in this Paragraph) included in payments previously sought from the United States, or any State Medicaid program, including, but not limited to, payments sought in any cost reports, cost statements, information reports, or payment requests already submitted by Defendants or any of their subsidiaries or affiliates, and shall request, and agree, that such cost reports, cost statements, information reports, or payment requests, even if already settled, be adjusted to account for the effect of the inclusion of the Unallowable Costs. Defendants agree that the United States, at a minimum, shall be entitled to recoup from Defendants any overpayment plus applicable interest and penalties as a result of the inclusion of such Unallowable Costs on previously-submitted cost reports, information reports, cost statements, or requests for payment. Any payments due after the adjustments have been made shall be paid to the United States pursuant to the direction of the Department of Justice and/or the affected agencies. The United States reserves its rights to disagree with any calculations submitted by Defendants or any of their subsidiaries or affiliates on the effect of inclusion of Unallowable Costs (as defined in this Paragraph) on Defendants or any of their subsidiaries or affiliates’ cost reports, cost statements, or information reports.
Allocation of Senior Reduction Amount to the Reference Tranches On each Payment Date prior to the Termination Date, after allocation of the Tranche Write-down Amount or Tranche Write-up Amount, if any, for such Payment Date as described above, the Senior Reduction Amount will be allocated to reduce the Class Notional Amount of each Class of Reference Tranche in the following order of priority, in each case until its Class Notional Amount is reduced to zero:
Repayment of Amounts Advanced for Network Upgrades Upon the Commercial Operation Date, the Interconnection Customer shall be entitled to a repayment, equal to the total amount paid to the Participating TO for the cost of Network Upgrades. Such amount shall include any tax gross-up or other tax-related payments associated with Network Upgrades not refunded to the Interconnection Customer pursuant to Article 5.17.8 or otherwise, and shall be paid to the Interconnection Customer by the Participating TO on a dollar-for-dollar basis either through (1) direct payments made on a levelized basis over the five-year period commencing on the Commercial Operation Date; or (2) any alternative payment schedule that is mutually agreeable to the Interconnection Customer and Participating TO, provided that such amount is paid within five (5) years from the Commercial Operation Date. Notwithstanding the foregoing, if this LGIA terminates within five (5) years from the Commercial Operation Date, the Participating TO’s obligation to pay refunds to the Interconnection Customer shall cease as of the date of termination. Any repayment shall include interest calculated in accordance with the methodology set forth in FERC’s regulations at 18 C.F.R. §35.19a(a)(2)(iii) from the date of any payment for Network Upgrades through the date on which the Interconnection Customer receives a repayment of such payment. Interest shall continue to accrue on the repayment obligation so long as this LGIA is in effect. The Interconnection Customer may assign such repayment rights to any person. If the Large Generating Facility fails to achieve commercial operation, but it or another Generating Facility is later constructed and makes use of the Network Upgrades, the Participating TO shall at that time reimburse Interconnection Customer for the amounts advanced for the Network Upgrades. Before any such reimbursement can occur, the Interconnection Customer, or the entity that ultimately constructs the Generating Facility, if different, is responsible for identifying the entity to which reimbursement must be made.
Allocation of Subordinate Reduction Amount to the Reference Tranches On each Payment Date prior to the Termination Date, after allocation of the Senior Reduction Amount and the Tranche Write-down Amount or Tranche Write-up Amount, if any, for such Payment Date as described above, the Subordinate Reduction Amount will be allocated to reduce the Class Notional Amount of each Class of Reference Tranche in the following order of priority, in each case until its Class Notional Amount is reduced to zero:
Final Audit Report Contractor shall promptly submit to the State a copy of any final audit report of an audit performed on Contractor’s records that relates to or affects this Contract or the Work, whether the audit is conducted by Contractor or a third party.
