TERMINATION BY THE CONTRACTOR If the Work is stopped for a period of thirty days under an order of any court or other public authority having jurisdiction, or as a result of an act of government, such as a declaration of a national emergency making materials unavailable, through no act or fault of the Contractor or a Subcontractor or their agents or employees or any other persons performing any of the Work under a contract with the Contractor, or if the Work should be stopped for a period of thirty days by the Contractor because the Architect has not issued a Certificate for Payment as provided in Paragraph 9.7 of these General Conditions or because the State has not made payment thereon as provided in Paragraph 9.7, then the Contractor may, upon seven additional days written notice to the State and the Architect, terminate the Contract and recover from the State payment for all Work executed and for any proven loss sustained upon any materials, equipment, tools, construction equipment and machinery, including reasonable profit and damages.
TERMINATION BY THE PARTIES This Agreement may be terminated upon sixty (60) days’ written notice (a) by the Independent Directors of the Company or the Advisor, without Cause and without penalty, (b) by the Advisor for Good Reason, or (c) by the Advisor upon a Change of Control. The provisions of Sections 19 through 31 of this Agreement shall survive termination of this Agreement.
Clean-Up Terminations by the Sellers (a) The Sellers shall have the right to elect to terminate this Agreement in the event that the remaining Serviced Appointments have generated LTM Fee Revenue that is less than 5% of the aggregate fee revenue generated by all Appointments that are Serviced Appointments as of January 1, 2024 in the twelve-month period prior to January 1, 2024.
Termination by the Company with Cause The Company shall have the right at any time to terminate the Executive's employment hereunder without prior notice upon the occurrence of any of the following (any such termination being referred to as a termination for "Cause"):
Termination by the Manager This Agreement may be terminated by the Manager if: (a) the Resident fails to check into their assigned Room within five (5) days of the first day of the Semester; (b) the Resident abandons their Room as detailed in section 8.03 of this Agreement; (c) the Resident decides not to accept the Room they were assigned, or any alternate rooms offered to them during the course of this Agreement; or (d) the Resident violates any of the terms of this Agreement, including violations of the Residence Community Living Standards or Institution Standards. Written Notice of Termination of Residency will be delivered to the Resident, and if necessary, the Manager may notify the Primary or Secondary Contact by phone or e-mail of the termination of the Resident’s residency. If the Resident is unavailable to receive service of the notice in person, then delivery of the notice to the Resident’s Room shall be deemed proper service and delivery. The Resident will be allowed 24 hours from the date and time of delivery of the Notice of Termination of Residency to fully vacate and remove all personal belongings from the Residence.
Partial Terminations by the Purchasers In the event so instructed by the Purchasers in writing after the Closing Date and at the Purchasers’ sole expense, each Seller shall execute documents prepared by the Purchasers and reasonably acceptable to such Seller resigning or appointing a successor Appointed Trustee under any Serviced Appointment for which such Seller acts as Appointed Trustee (other than with respect to any Serviced Appointment that is an Excluded Appointment), and shall reasonably cooperate, at the Purchasers’ sole expense, as instructed by the Purchasers, in finding a qualified successor Appointed Trustee, including executing any documents prepared by the Purchasers in connection with the application to a court of competent jurisdiction to appoint a successor Appointed Trustee.
Damages for delay by the Concessionaire In the event that (i) the Concessionaire does not procure fulfilment of any or all of the Conditions Precedent set forth in Clause 4.1.3 within a period of 180 (one hundred and eighty) days from the date of this Agreement, and (ii) the delay has not occurred as a result of failure to fulfil the obligations under Clause 4.1.2 or other breach of this Agreement by the Authority, or due to Force Majeure, the Concessionaire shall pay to the Authority Damages in an amount calculated at the rate of 0.2% (zero point two per cent) of the Performance Security for each day's delay until the fulfilment of such Conditions Precedent, subject to a maximum of 20% (twenty percent) of the Performance Security.
Termination Without Cause by the Company In furtherance of the “at will” basis of Executive’s employment by the Company, the Company may terminate Executive’s employment without Cause upon written notice to Executive. Executive’s termination without Cause will be effective on the date of termination specified by the Company in such written notice. Such written notice shall be deemed received, if mailed first class through the U. S. Postal System, three (3) business days after mailing such written notice to Executive.
Termination by the Company This Agreement may be terminated by the Company at any time prior to the Effective Time:
TERMINATION BY THE OWNER 14.2.1 The Owner may terminate the contract if the Contractor:
