PARTIAL OCCUPANCY OR USE § 9.9.1 The Owner may occupy or use any completed or partially completed portion of the Work at any stage when such portion is designated by separate agreement with the Design-Builder, provided such occupancy or use is consented to, by endorsement or otherwise, by the insurer providing property insurance and authorized by public authorities having jurisdiction over the Project. Such partial occupancy or use may commence whether or not the portion is substantially complete, provided the Owner and Design-Builder have accepted in writing the responsibilities assigned to each of them for payments, retainage, if any, security, maintenance, heat, utilities, damage to the Work and insurance, and have agreed in writing concerning the period for correction of the Work and commencement of warranties required by the Design-Build Documents. When the Design-Builder considers a portion substantially complete, the Design-Builder shall prepare and submit a list to the Owner as provided under Section 9.8.2. Consent of the Design-Builder to partial occupancy or use shall not be unreasonably withheld. The stage of the progress of the Work shall be determined by written agreement between the Owner and Design-Builder.
Occupancy Period a. The student may begin occupancy of their assigned room space on the dates listed in the University catalog. Failure to occupy the room by the first official day of classes each semester may result in a reassignment of the room; however, the residential student agreement will remain enforced. Students are expected to occupy their assigned room. Students who choose to vacate their assignment without being officially exempted from the agreement have abrogated their right to that space, and are required to return any key(s) for the vacated assignment as directed. Failure to return key(s) as directed will result in billing for associated lock changes(s). Students remain liable for room charges during the life of the agreement. Students returning during the agreement period will be reassigned to an available space.
Termination for Changes in Budget or Law The JBE’s payment obligations under this Agreement are subject to annual appropriation and the availability of funds. Expected or actual funding may be withdrawn, reduced, or limited prior to the expiration or other termination of this Agreement. Funding beyond the current appropriation year is conditioned upon appropriation of sufficient funds to support the activities described in this Agreement. The JBE may terminate this Agreement or limit Contractor’s Services (and reduce proportionately Contractor’s fees) upon Notice to Contractor without prejudice to any right or remedy of the JBE if: (i) expected or actual funding to compensate Contractor is withdrawn, reduced or limited; or (ii) the JBE determines that Contractor’s performance under this Agreement has become infeasible due to changes in applicable laws.
Termination of Occupancy Upon termination of occupancy of a County Assisted Unit by a Tenant, such Unit will be deemed to be continuously occupied by a household of the same income level as the initial income level of the vacating Tenant, until such unit is reoccupied, at which time categorization of the Unit will be established based on the occupancy requirements of Section 2.1.
Maximum Occupancy No more than two (2) guests per one (1) resident (who is present) are permitted in a student room/suite/apartment at any given time unless otherwise approved by the University (Residential Life).
MINOR CHANGES IN THE WORK 7.4.1 The Architect will have authority to order minor changes in the Work not involving adjustment in the Contract Sum or extension of the Contract Time and not inconsistent with the intent of the Contract Documents. Such changes shall be effected by written order and shall be binding on the Owner and Contractor. The Contractor shall carry out such written orders without delay.
Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
Extension of Concession Period Subject to the provisions of Clause 35.6, in the event that a material default or breach of this Agreement set forth in Clause 35.2 causes delay in achieving COD or leads to suspension of or reduction in collection of Fee, as the case may be, the Authority shall, in addition to payment of compensation under Clause 35.2, extend the Concession Period, such extension being equal in duration to the period by which COD was delayed or the collection of Fee remained suspended on account thereof, as the case may be.
Beneficial Occupancy A. The County may, at any time, and from time to time, during the performance of the Work, enter the structure for the purpose of installing any necessary Work by County labor of other contracts, and for any other purpose in connection with the installation of facilities. In doing so, the County shall endeavor not to interfere with the Contractor and the Contractor shall not interfere with other Work being done by or on behalf of the County.
Termination for Concessionaire Default 37.1.1 Save as otherwise provided in this Agreement, in the event that any of the defaults specified below shall have occurred, and the Concessionaire fails to cure the default within the Cure Period set forth below, or where no Cure Period is specified, then within a Cure Period of 60 (sixty) days, the Concessionaire shall be deemed to be in default of this Agreement (the “Concessionaire Default”), unless the default has occurred solely as a result of any breach of this Agreement by the Authority or due to Force Majeure. The defaults referred to herein shall include:
