Change Administration Sample Clauses

Change Administration. Except to the extent of ongoing minor “field changes” by the Premises Contractor at the time of construction, any material Discretionary Change or Mandatory Change (collectively “Change”) to Tenant Improvements must be authorized in writing by Tenant and Landlord, on one or more forms to be prepared by the Premises Contractor and approved by Landlord and Tenant. Landlord agrees to update Tenant or the Tenant TI Consultant with respect to the occurrence of minor “field changes” in the ordinary course during the weekly construction meetings. Landlord shall issue written notice to Tenant as soon as reasonably possible after Landlord becomes aware of the need for a material change in the Working Drawings or Tenant Improvements (including without limitation any Mandatory Change), and Tenant shall approve or reject any such material change identified by Landlord promptly, and Tenant acknowledges that its approval may require decisions to be made immediately during the course of construction. Tenant shall be deemed to have approved the proposed material change (including without limitation any Mandatory Changes), unless Tenant disapproves such changes in writing within twenty four (24) hours after presentation to Tenant when Landlord so requests as part of the notice of such change. If Tenant does not respond promptly (within 24 hours) to a requested material change (including without limitation any Mandatory Changes) from Landlord, then Landlord may direct the Premises Contractor to delay that portion of construction and any delay shall be a Tenant Delay. Any costs of changes (including without limitation any Mandatory Changes) associated with Tenant Delay shall be included in the Costs of the TI Work and shall be paid by Tenant to Landlord, unless the Tenant’s Allowance is sufficient to pay the cost of such Change.
View Source

Related to Change Administration

  • Program Administration An activity relating to the general management, oversight and coordination of community development programs. Costs directly related to carrying out eligible activities are not included.

  • Grant Administration Grantee shall use the Grant funds only for the activities described in the approved Scope of Work. Grantee shall maintain financial records relating to the receipt and expenditure of all Grant funds in accordance with the terms set forth under this Agreement for a period of seven (7) years starting on the first day after final payment under the Agreement.

  • Settlement Administration 5.1. The Settlement Administrator shall, under the supervision of the Court, administer the relief provided by this Settlement Agreement by processing Claim Forms in a rational, responsive, cost effective, and timely manner. The Settlement Administrator shall maintain reasonably detailed records of its activities under this Agreement. The Settlement Administrator shall maintain all such records as are required by applicable law in accordance with its normal business practices and such records will be made available to Class Counsel and Defendant’s Counsel upon request. The Settlement Administrator shall also provide reports and other information to the Court as the Court may require. The Settlement Administrator shall provide Class Counsel and Defendant’s Counsel with information concerning Notice, administration, and implementation of the Settlement Agreement. Should the Court request, the Parties shall submit a timely report to the Court summarizing the work performed by the Settlement Administrator, including a report of all amounts from the Settlement Fund paid to Settlement Class Members on account of Approved Claims. Without limiting the foregoing, the Settlement Administrator shall: 5.1.1. Forward to Defendant’s Counsel, with copies to Class Counsel, all original documents and other materials received in connection with the administration of the Settlement, and all copies thereof, within thirty (30) days after the date on which all Claim Forms have been finally approved or disallowed in accordance with the terms of this Agreement; 5.1.2. Receive requests to be excluded from the Settlement Class and other requests and promptly provide to Class Counsel and Defendant’s Counsel copies thereof. If the Settlement Administrator receives any exclusion forms or other requests after the deadline for the submission of such forms and requests, the Settlement Administrator shall promptly provide copies thereof to Class Counsel and Defendant’s Counsel; 5.1.3. Provide weekly reports to Class Counsel and Defendant’s Counsel, including without limitation, reports regarding the number of Claim Forms received, the number approved by the Settlement Administrator, and the categorization and description of Claim Forms rejected, in whole or in part, by the Settlement Administrator; and 5.1.4. Make available for inspection by Class Counsel or Defendant’s Counsel the Claim Forms received by the Settlement Administrator at any time upon reasonable notice. 5.2. The Settlement Administrator shall be obliged to employ reasonable procedures to screen claims for abuse or fraud and deny Claim Forms where there is evidence of abuse or fraud. The Settlement Administrator will reject any claim that does not comply in any material respect with the instructions on the Claim Form or the terms of Paragraphs 1.2 and/or 1.3, above, or is submitted after the Claims Deadline. Each claimant who submits an invalid Claim Form to the Settlement Administrator must be given a notice of the Claim Form’s deficiency and an opportunity to cure the deficiency within twenty-one (21) days of the date of the notice. The Settlement Administrator may contact any Person who has submitted a Claim Form to obtain additional information necessary to verify the Claim Form. 5.3. Defendant’s Counsel and Class Counsel shall have the right to challenge the acceptance or rejection of a Claim Form submitted by Settlement Class Members and to obtain and review supporting documentation relating to such Claim Form. The Settlement Administrator shall follow any agreed decisions of Class Counsel and Defendant’s Counsel as to the validity of any disputed submitted Claim Form. To the extent Class Counsel and Defendant’s Counsel are not able to agree on the disposition of a challenge, the disputed claim shall be submitted to The ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ of JAMS for binding determination. 5.4. In the exercise of its duties outlined in this Agreement, the Settlement Administrator shall have the right to reasonably request additional information from the Parties or any Settlement Class Member.

  • Reinsurance Administration A. Within thirty (30) days after the end of each calendar month, the Cedent shall take all reasonable and appropriate steps to furnish the Reinsurer with a seriatim electronic report, as detailed in Schedule C, for each Reinsured Contract, valued as of the last day of that month. On or before September 30, 2001, the Cedent shall provide the initial seriatim electronic report, which shall cover the period from the Effective Date hereof through August 31, 2001; provided, however, that the initial seriatim electronic report may omit Funding Vehicle Values by MorningStar designation. The Cedent shall provide complete seriatim electronic data, as required herein, on or before April 30, 2002. Failure to provide this information as required shall constitute a material breach within the scope of Article XX, Paragraph G. B. Additionally, within thirty (30) days after the end of each calendar month the Cedent shall furnish the Reinsurer with a separate Summary Statement containing the following: 1. Reinsurance Premiums due to the Reinsurer summarized separately for each premium class by GMDB, EPB, and Income Program, as shown in Exhibit II; 2. benefit claim recoverables due to the Cedent in total and, if applicable, broken down by VNAR, SCNAR, and EEMNAR and Income Program; and 3. the month end date for the period covered by the Summary Statement. C. If the net balance is due to the Reinsurer, the Cedent shall remit the amount due with the Summary Statement, but no later than thirty (30) days after the month end date for the period covered by the Summary Statement. If the net balance is due to the Cedent, the Reinsurer shall remit the amount due to the Cedent within ten (10) days after receipt of the Summary Statement. D. The payment of Reinsurance Premiums is a condition precedent to the liability of the Reinsurer under this Agreement. In the event that the Cedent does not pay the Reinsurance Premiums in a timely manner, as defined below, the Reinsurer may exercise the following rights: 1. The Reinsurer shall charge interest if Reinsurance Premiums are not paid within thirty (30) days of the due date, as defined in Paragraph C of this Article. The interest rate charged shall be based on the ninety-(90) day federal Treasury ▇▇▇▇, as published in The Wall Street Journal on the first business day in the month following the due date of the Reinsurance Premiums, plus one hundred (100) basis points. The method of calculation shall be simple interest (360-day year). 2. The Reinsurer may terminate this Agreement in the event that Reinsurance Premium payments are more than sixty (60) days past due after the due date, as described in Paragraph C of this Article, by giving sixty (60) day written notice of termination to the Cedent. As of the close of the last day of this sixty-(60) day notice period, the Reinsurer's liability with respect to the ceded liabilities shall terminate. If all Reinsurance Premiums that are the subject of a sixty (60) day termination notice shall have been received by the Reinsurer within the time specified, the termination notice shall be deemed vacated and the Agreement shall remain in effect.

  • Policy Administration The Company shall provide all required, necessary and appropriate claims, administrative and other services with respect to the Policies. The Company shall use reasonable care in its administration and claims practices with respect to the Policies and in administering and performing its duties under this Agreement and such practices, administration and performance shall (a) conform with Applicable Law; (b) not be fraudulent; and (c) be no less favorable than those used by the Company with respect to other policies of the Company not reinsured by the Reinsurer.