Adjustment of Commencement Date; Possession 3.01 If Landlord is required to perform Landlord Work prior to the Commencement Date: (a) the date set forth in Section 1.06 as the Commencement Date shall instead be defined as the “Target Commencement Date”; (b) the actual Commencement Date shall be the date on which the Landlord Work is Substantially Complete (defined below); and (c) the Termination Date will the last day of the Term as determined based upon the actual Commencement Date. Landlord’s failure to Substantially Complete the Landlord Work by the Target Commencement Date shall not be a default by Landlord or otherwise render Landlord liable for damages. Promptly after the determination of the Commencement Date, Landlord and Tenant shall enter into a commencement letter agreement in the form attached as Exhibit D. If the Termination Date does not fall on the last day of a calendar month, Landlord and Tenant may elect to adjust the Termination Date to the last day of the calendar month in which Termination Date occurs by the mutual execution of a commencement letter agreement setting forth such adjusted date. The Landlord Work shall be deemed to be “Substantially Complete” on the date that all Landlord Work has been performed, other than any details of construction, mechanical adjustment or any other similar matter, the non-completion of which does not materially interfere with Tenant’s use of the Premises. If Landlord is delayed in the performance of the Landlord Work as a result of the acts or omissions of Tenant, the Tenant Related Parties (defined in Section 13) or their respective contractors or vendors, including, without limitation, changes requested by Tenant to approved plans, Tenant’s failure to comply with any of its obligations under this Lease, or the specification of any materials or equipment with long lead times (a “Tenant Delay”), the Landlord Work shall be deemed to be Substantially Complete on the date that Landlord could reasonably have been expected to Substantially Complete the Landlord Work absent any Tenant Delay.
TERM; POSSESSION The term of this Lease (the “Term”) shall commence on the Commencement Date as described below and, unless sooner terminated, shall expire on the Expiration Date set forth in the Basic Lease Information (the “Expiration Date”). The “Commencement Date” shall be the earlier of (a) the date on which Landlord tenders possession of the Premises to Tenant, with all of Landlord’s construction obligations, if any, “Substantially Completed” as provided in the Construction Rider attached as Exhibit B (the “Construction Rider”) or, in the event of any “Tenant Delay,” as defined in the Construction Rider, the date on which Landlord could have done so had there been no such Tenant Delay; or (b) the date upon which Tenant, with Landlord’s written permission, actually occupies and conducts business in any portion of the Premises. The parties anticipate that the Commencement Date will occur on or about the Scheduled Commencement Date set forth in the Basic Lease Information (the “Scheduled Commencement Date”). Landlord shall pay Tenant’s hold-over charges if the Premises are not Substantially Completed within seventy-five (75) days after Lease execution, provided, however, that Landlord shall not be liable for any other claims, damages or liabilities if the Premises are not ready for occupancy by the Scheduled Commencement Date. When the Commencement Date has been established, Landlord and Tenant shall at the request of either party confirm the Commencement Date and Expiration Date in writing.
Documents, Records and Funds in Possession of the Servicer to be Held for the Trustee The Servicer shall transmit to the Trustee or, at the direction of the Trustee, the Custodian as required by this Agreement all documents and instruments in respect of a Mortgage Loan coming into the possession of the Servicer from time to time and shall account fully to the Trustee for any funds received by the Servicer or which otherwise are collected by the Servicer as Liquidation Proceeds or Insurance Proceeds in respect of any Mortgage Loan. The documents constituting the Servicing File shall be held by the Servicer as custodian and bailee for the Trustee. All Mortgage Files and funds collected or held by, or under the control of, the Servicer in respect of any Mortgage Loans, whether from the collection of principal and interest payments or from Liquidation Proceeds, including but not limited to, any funds on deposit in the Servicer Custodial Account, shall be held by the Servicer for and on behalf of the Trustee and shall be and remain the sole and exclusive property of the Trustee, subject to the applicable provisions of this Agreement. The Servicer also agrees that it shall not knowingly create, incur or subject any Mortgage File or any funds that are deposited in the Servicer Custodial Account, Certificate Account or any Escrow Account, or any funds that otherwise are or may become due or payable to the Trustee for the benefit of the Certificateholders, to any claim, lien, security interest, judgment, levy, writ of attachment or other encumbrance created by the Servicer, or assert by legal action or otherwise any claim or right of setoff against any Mortgage File or any funds collected on, or in connection with, a Mortgage Loan, except, however, that the Servicer shall be entitled to set off against and deduct from any such funds any amounts that are properly due and payable to the Servicer under this Agreement.
Books and Records; Certain Funds Received After the Cut-Off Date From and after the sale of the Mortgage Loans to the Purchaser, record title to each Mortgage (other than with respect to any Outside Serviced Mortgage Loan) and each Note shall be transferred to the Trustee subject to and in accordance with this Agreement. Any funds due after the Cut-Off Date in connection with a Mortgage Loan received by the Seller shall be held in trust on behalf of the Trustee (for the benefit of the Certificateholders) as the owner of such Mortgage Loan and shall be transferred promptly to the Certificate Administrator. All scheduled payments of principal and interest due on or before the Cut-Off Date but collected after the Cut-Off Date, and all recoveries and payments of principal and interest collected on or before the Cut-Off Date (only in respect of principal and interest on the Mortgage Loans due on or before the Cut-Off Date and principal prepayments thereon), shall belong to, and shall be promptly remitted to, the Seller. The transfer of each Mortgage Loan shall be reflected on the Seller’s balance sheets and other financial statements as the sale of such Mortgage Loan by the Seller to the Purchaser. The Seller intends to treat the transfer of each Mortgage Loan to the Purchaser as a sale for tax purposes. Following the transfer of the Mortgage Loans by the Seller to the Purchaser, the Seller shall not take any actions inconsistent with the ownership of the Mortgage Loans by the Purchaser and its assignees. The transfer of each Mortgage Loan shall be reflected on the Purchaser’s balance sheets and other financial statements as the purchase of such Mortgage Loan by the Purchaser from the Seller. The Purchaser intends to treat the transfer of each Mortgage Loan from the Seller as a purchase for tax purposes. The Purchaser shall be responsible for maintaining, and shall maintain, a set of records for each Mortgage Loan which shall be clearly marked to reflect the transfer of ownership of each Mortgage Loan by the Seller to the Purchaser pursuant to this Agreement. It is expressly agreed and understood that, notwithstanding the assignment of the Loan Documents, it is expressly intended that the Seller will receive the benefit of any securitization indemnification provisions in the Loan Documents.
Documents Records and Funds in Possession of Master Servicer to be Held for the Trustee Notwithstanding any other provisions of this Agreement, the Master Servicer shall transmit to the Trustee as required by this Agreement all documents and instruments in respect of a Mortgage Loan coming into the possession of the Master Servicer from time to time and shall account fully to the Trustee for any funds received by the Master Servicer or which otherwise are collected by the Master Servicer as Liquidation Proceeds or Insurance Proceeds in respect of any Mortgage Loan. All Mortgage Files and funds collected or held by, or under the control of, the Master Servicer in respect of any Mortgage Loans, whether from the collection of principal and interest payments or from Liquidation Proceeds, including but not limited to, any funds on deposit in the Certificate Account, shall be held by the Master Servicer for and on behalf of the Trustee and shall be and remain the sole and exclusive property of the Trustee, subject to the applicable provisions of this Agreement. The Master Servicer also agrees that it shall not create, incur or subject any Mortgage File or any funds that are deposited in the Certificate Account, Distribution Account or any Escrow Account, or any funds that otherwise are or may become due or payable to the Trustee for the benefit of the Certificateholders, to any claim, lien, security interest, judgment, levy, writ of attachment or other encumbrance, or assert by legal action or otherwise any claim or right of setoff against any Mortgage File or any funds collected on, or in connection with, a Mortgage Loan, except, however, that the Master Servicer shall be entitled to set off against and deduct from any such funds any amounts that are properly due and payable to the Master Servicer under this Agreement.
Completion Date Completion date" shall be the date on which the improvements erected and to be erected upon the leased premises shall have been completed in accordance with the plans and specifications described in article 6.00. The completion date shall constitute the commencement of the term of this Lease for all purposes, whether or not Lessee has actually taken possession. Lessor shall use its best efforts to establish the completion date as the date set forth in section 1.03. In the event that the improvements have not in fact been completed as of that date, Lessee shall notify Lessor in writing of its objections. Lessor shall have a reasonable time after delivery of the notice in which to take such corrective action as may be necessary and shall notify Lessee in writing as soon as it deems such corrective action has been completed and the improvements are ready for occupancy. Upon completion of construction, Lessee shall deliver to Lessor a letter accepting the leased premises as suitable for the purposes for which they are let and the date of such letter shall constitute the commencement of the term of this Lease. Whether or not Lessee has executed such letter of acceptance, taking possession of the leased premises by Lessee shall be deemed to establish conclusively that the improvements have been completed in accordance with the plans and specifications, are suitable for the purposes for which the leased premises are let, and that the leased premises are in good and satisfactory condition as of the date possession was so taken by Lessee, except for latent defects, if any.
Title to Properties; Possession Under Leases (a) Such Borrower and each of its Subsidiaries have good and marketable title to, or valid leasehold interests in, all its material properties and assets, except for minor defects in title that do not materially interfere with its ability to conduct its business as currently conducted or to utilize such properties and assets for their intended purposes.
Documents, Records and Funds in Possession of the Master Servicer to be Held for the Trustee. The Master Servicer shall account fully to the Trustee for any funds it receives or otherwise collects as Liquidation Proceeds or Insurance Proceeds in respect of any Mortgage Loan. All Mortgage Files and funds collected or held by, or under the control of, the Master Servicer in respect of any Mortgage Loans, whether from the collection of principal and interest payments or from Liquidation Proceeds, including any funds on deposit in the Certificate Account, shall be held by the Master Servicer for and on behalf of the Trustee and shall be and remain the sole and exclusive property of the Trustee, subject to the applicable provisions of this Agreement. The Master Servicer also agrees that it shall not create, incur or subject any Mortgage File or any funds that are deposited in the Certificate Account, the Collection Account, Distribution Account, or any Escrow Account, or any funds that otherwise are or may become due or payable to the Trustee for the benefit of the Certificateholders, to any claim, lien, security interest, judgment, levy, writ of attachment, or other encumbrance, or assert by legal action or otherwise any claim or right of setoff against any Mortgage File or any funds collected on, or in connection with, a Mortgage Loan, except, however, that the Master Servicer shall be entitled to set off against and deduct from any such funds any amounts that are properly due and payable to the Master Servicer under this Agreement.
GRANTOR'S RIGHT TO POSSESSION AND TO COLLECT ACCOUNTS Until default and except as otherwise provided below with respect to accounts, Grantor may have possession of the tangible personal property and beneficial use of all the Collateral and may use it in any lawful manner not inconsistent with this Agreement or the Related Documents, provided that Grantor's right to possession and beneficial use shall not apply to any Collateral where possession of the Collateral by Lender is required by law to perfect Lender's security interest in such Collateral. Until otherwise notified by Lender, Grantor may collect any of the Collateral consisting of accounts. At any time and even though no Event of Default exists, Lender may exercise its rights to collect the accounts and to notify account debtors to make payments directly to Lender for application to the Indebtedness. If Lender at any time has possession of any Collateral, whether before or after an Event of Default, Lender shall be deemed to have exercised reasonable care in the custody and preservation of the Collateral if Lender takes such action for that purpose as Grantor shall request or as Lender, in Lender's sole discretion, shall deem appropriate under the circumstances, but failure to honor any request by Grantor shall not of itself be deemed to be a failure to exercise reasonable care. Lender shall not be required to take any steps necessary to preserve any rights in the Collateral against prior parties, nor to protect, preserve or maintain any security interest given to secure the Indebtedness.
After the Closing Date Buyer shall accept payment of all accounts receivable in the normal course of conducting the Business. Upon payment of any amounts from Delinquent Members, Buyer shall credit such payment first to the amounts owed by such Delinquent Member indicated on the Seller Receivable List, and then for Buyer's account.
