Payment for Project Services As full consideration for the Services to be performed by Contractor, City agrees to pay Contractor as set forth in accordance with the bid and not to exceed fee of $696,243.00 for the project. A monthly progress payment in the amount of ninety-five percent (95%) of the value of the work completed may be made every thirty (30) days upon application by the Contractor and certification by the Project Manager that such work has been completed. Partial payments will be made once each month as the work satisfactorily progresses and after acceptance by the authorized City representative. The progress estimates shall be based upon materials in place, or on the job site and invoiced, and labor expended thereon. From the total of the amount ascertained will be deducted an amount equivalent to five percent (5%) of the whole, which five percent (5%) will be retained by the City until after completion of the entire Contract in an acceptable manner. Any time after fifty percent (50%) of the value of the work has been completed, the City will make any of the remaining partial payments in full. No such estimates or payments shall be required to be made, when, in the judgment of the City Project Manager, the work is not proceeding in accordance with the provision of the Contract, or when in his judgment the total value of the work done since last estimate amounts to less than Five Hundred Dollars ($500.00). The cost of materials conforming to the plans and specifications (materials being those which are required to be contained and incorporated in a finished contract bid item) delivered to the project and not at the time incorporated in the work, may also be included in the estimate for payment. No such estimate or payment shall be construed to be an acceptance of any defective work or improper material. The Contractor shall be responsible for, and shall not remove from the project any material that has been included in the estimate for payment. Final payment shall be made upon the Project Manager certifying that the Contractor has satisfactorily completed the work in conformity with the Contract Documents.
PAYMENT FOR GOODS AND SERVICES a. DIR Customer shall comply with Chapter 2251, Texas Government Code, or applicable local law, in making payments to the Vendor. Payment under a DIR Contract shall not foreclose the right to recover wrongful payments.
Adjustment for Excess Volume If Sale Area Map indicates that there are incompletely Marked subdivisions and if Contracting Officer determines that the volume cut will be more than 120 percent of the total es- timated volume listed in A2, Forest Service, upon request by Purchaser, shall make an adjustment in Marking or cutting unit boundaries with the objective of designating for cutting the approximate estimated volumes by species listed in A2. Such adjustments in volumes shall be con- fined to (a) Marking adjustments on Sale Area and (b) re- duction in area to be cut over. Such adjustments or re- ductions shall not conflict with the silvicultural treatment being applied on Sale Area and shall not materially change the average value by species of the timber desig- nated for cutting. Such adjustments may be made not- withstanding the provisions of B1.1 and B2.3. If the timber designated for cutting is not reduced by such adjustments to less than 120 percent of the total es- timated quantity listed in A2, Purchaser, after cutting 120 percent of the total estimated volume listed in A2, may elect to have Sale Area reduced to eliminate the remain- ing Included Timber. However, where felling operations have been started, units of minimum practical size shall be retained in Sale Area.
Requirement for Project Planning No physical work will begin on the construction site until the receipt of a Proceed Order issued by the Owner. The Contract assumes that a Proceed Order will be issued in not more than sixty days from the Effective Date of the Contract. Failure of the Contractor to provide the necessary documentation for the issuance of a Proceed Order shall not entitle the Contractor to any extension of time. If a Proceed Order is not issued within sixty days from the award of the Contract and non-issuance is due to nonperformance by the Contractor, the Contractor may be in default.
PAYMENT FOR WORK The H-GAC Customer is responsible for making payment to the Contractor upon delivery and acceptance of the goods or completion of the services and submission of the subsequent invoice.
Payment for Working Overtime (a) For all work done outside ordinary hours, the rates of pay will be time and a half for the first two hours and double time thereafter.
Payment for TIPS Sales TIPS Members may make payments for TIPS Sales directly to Vendor, Vendor’s Authorized Reseller, or as otherwise agreed to in the applicable Supplemental Agreement after receipt of the invoice and in compliance with applicable payment statutes. Regardless of how payment is issued or received for a TIPS Sale, Vendor is responsible for all reporting and TIPS Administration Fee payment requirements as stated herein.
Reimbursement for Travel Harford County Public Schools will reimburse employees for approved transportation at the rate established by the Internal Revenue Service. All requests for transportation reimbursement must be submitted to the Assistant Superintendent for Administrative Services for prior approval before payment can be authorized.
No Adjustment for Certain Transactions Notwithstanding anything in this Article 4, no adjustment shall be made in the acquisition rights attached to the Warrants if the issue of Common Shares is being made pursuant to this Indenture or in connection with (a) any share incentive plan or restricted share plan or share purchase plan in force from time to time for directors, officers, employees, consultants or other service providers of the Corporation; or (b) the satisfaction of existing instruments issued at the date hereof.
Payment for Labor and Materials The Contractor agrees and binds itself to pay for all labor done, and for all the materials used in the construction of the work to be completed pursuant to this contract.
