Final Completion Date means the date on which Final Completion occurs.
Project Completion Date means the date on which the Completion Certificate is issued;
The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.
Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity
Substantial Completion Date means the date on which Substantial Completion occurs.
project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;
Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.
Target Completion Date has the meaning given such term in Section 3.3(b).
Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.
Scheduled Completion Date shall be the date set forth in Clause 10.3;
Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.
Commercial Operation Date means the date on which a Material Project is substantially complete and commercially operable.
Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.
Outside Completion Date shall have the meaning assigned to such term in Section 6.3(d).
Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:
Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;
Commencement Date or Handover Date means the date on which the Licensed Space of first lot of stations as per Annexure 1 is handed over by DMRC to the Selected Bidder, in accordance with the terms of this agreement.
Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;
Improvement completion assurance means a surety bond, letter of credit,
Scheduled Commercial Operation Date shall have the meaning ascribed to it in Clause 5.4.1;
Commercial Operations Date or "COD": The date on which Facility first achieves Commercial Operations.
Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.
Billing Commencement Date means the earlier of:
Practical Completion means that stage in the execution of a Named Project when the Works have been completed in accordance with the terms of the relevant Building Contract and/or the terms of this Agreement such that the AHP Dwellings comprised within the Named Project are fit for beneficial occupation as a residential development in accordance with applicable NHBC or equivalent requirements current at the date of inspection subject only to the existence of minor defects and/or minor omissions at the time of inspection which are capable of being made good or carried out without materially interfering with the beneficial use and enjoyment of the Named Project and which would be reasonable to include in a snagging list, and Practically Complete shall be construed accordingly; Process has the meaning ascribed to it in the DPA; Procurement Law means (as the case may be):
Inspection Period means the period beginning on the Effective Date and expiring at 5:00 p.m. eastern time on the forty-fifth day after the Effective Date.
Project Start Date means the first Milestone Start Date specified in Schedule B;