Practical Completion Stage definition

Practical Completion Stage means that stage of the Works in which Practical Completion will be attained in accordance with this Contract.
Sample 1Sample 2Sample 3
Practical Completion Stage means that stage of the Contract Work in which Practical Completion will be attained in accordance with this Contract.
Sample 1Sample 2Sample 3
Practical Completion Stage. , for a regulated contract, means the stage when—
Sample 1Sample 2

Examples of Practical Completion Stage in a sentence

  • If the Owner’s entitlement to liquidated damages exceeds the amount payable to the Contractor for the Practical Completion Stage, the excess may be recovered by the Owner as a debt due to the Owner by the Contractor.

  • It is submitted to Curtin University at Construction Stage via email and at Practical Completion Stage via the Construction Documentation Portal by the Document Contributor, refer to Section 2.5 Schedule of Documentation to be Supplied.

  • They are then submitted to Curtin University at Practical Completion Stage via the Construction Documentation Portal by the Document Contributor.

  • Liquidated damages may only be deducted by the Owner from the amount payable to the Contractor in respect of the Practical Completion Stage.

  • They are then submitted to Curtin University at Practical Completion Stage via the Construction Documentation Portal by the Document Contributor, refer to Section 2.5 Schedule of Documentation to be supplied.

  • FORM 7 CERTIFICATE OF PRACTICAL COMPLETION (Conditions 17 & 27 of the General Conditions of QBCC Natural Disaster Repairs Contract) NOTE TO CONTRACTOR/CONTRACTOR’S REPRESENTATIVE The Contractor must complete, sign and give a copy of this Certificate to the Owner before demanding the Progress Claim for the Practical Completion Stage.

  • Except in regard to the Progress Payment for the Practical Completion Stage payable in accordance with Condition 11.5, the Owner must pay the Contractor the Progress Payment, or so much of the relevant claim for Progress Payment as is not disputed by the Owner, within 5 business days of receipt of the relevant claim.

  • If the Owner’s entitlement to liquidated damages exceeds the amount payable to the Contractor forthe Practical Completion Stage, the excess may be recovered by the Owner as a debt due to the Owner by the Contractor.

  • When the Contractor has satisfied all of its obligations under Condition 11.2 the Owner must immediately pay the Contractor the progress claim for the Practical Completion Stage (as adjusted under Condition 14, if applicable).

  • Measured in calendar days.Aircraft Maintenance Production/Compression Report Item Number—Optional field used by Program Manager to track aircraft sequence number.Assessment End Date—The Assessment End Date is the date that an overall evaluation of the aircraft is to be completed and the scope of work is known.


More Definitions of Practical Completion Stage

Practical Completion Stage means that stage when the Works are complete in accordance with this Contract and all relevant statutory requirements (apart from minor omissions or minor defects), inspections have been satisfactorily completed and the Works are reasonably suitable for habitation.
Sample 1

Related to Practical Completion Stage

  • Practical Completion means that stage in the execution of a Named Project when the Works have been completed in accordance with the terms of the relevant Building Contract and/or the terms of this Agreement such that the AHP Dwellings comprised within the Named Project are fit for beneficial occupation as a residential development in accordance with applicable NHBC or equivalent requirements current at the date of inspection subject only to the existence of minor defects and/or minor omissions at the time of inspection which are capable of being made good or carried out without materially interfering with the beneficial use and enjoyment of the Named Project and which would be reasonable to include in a snagging list, and Practically Complete shall be construed accordingly; Process has the meaning ascribed to it in the DPA; Procurement Law means (as the case may be):

  • Construction Start Date means the later to occur of the date on which Seller delivers to Buyer (a) a copy of the Notice to Proceed that Seller has delivered to the EPC Contractor for the Project, and (b) a written Certification substantially in the form attached hereto as Appendix IV-1.

  • Date of Practical Completion means the date certified in the QBCC Form 7 - Certificate of Practical Completion in accordance with Condition 28.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Final Completion Date means the date on which Final Completion occurs.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.

  • Completion Deadline means August 15, 2018, or such later date as may be agreed to in writing by the Parties;

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Successful Completion means that in the reasonable opinion of the Customer, Deliverables completed by the Supplier are fit for purpose, completed on time and otherwise meet all the criteria defined under this Contract;

  • COMPLETION TIME means the period by date specified in the acceptance of tender for handing over the erected equipment/plant which are found acceptable by the Engineer being of required standard and conforming to the specifications of the contract.

  • Virtual Completion means the premise is in the opinion of the Employer fit for occupation.

  • Phase 3 means the period commencing on the day after the Phase 2 implementation date and ending on the Phase 3 implementation date (as defined below).

  • Phase 2 means the second implementation phase of this section, beginning June 1, 2022 and continuing thereafter.

  • Phase II Study means a study in humans of the safety, dose ranging or efficacy of a product, as further defined in 21 C.F.R. § 312.21(b) (or the equivalent thereof outside the United States).

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.