Minor Change Orders definition

Minor Change Orders means changes in the Improvements, the Plans or the other Construction and Development Documents which do not modify the scope or overall quality of the Project or involve extensions of time of the Required Completion Date under the General Construction Contract and the performance of which costs less than $250,000 each and less than $1,000,000 in the aggregate.
View Source
Minor Change Orders means changes in the Improvements, the Plans or the other Construction and Development Documents which do not modify the scope or overall quality of the Project or involve extensions of time of the Required Completion Date under the General Construction Contract and the performance of which costs less than Five Hundred Thousand Dollars ($500,000) each or Three Million Dollars ($3,000,0000) in the aggregate.
View Source

Examples of Minor Change Orders in a sentence

  • Minor Change Orders (under $50,000 per change which do not affect the systems or structure of the Building) shall not require Landlord’s approval.

  • Change Orders other than Minor Change Orders shall be subject to Bank’s reasonable review and approval.

  • Lender’s approval will be required for changes in the Plans or the other Construction and Development Documents which are not Minor Change Orders.

  • Except for Minor Change Orders, Borrower shall not amend or modify any provisions of the Plans or Construction and Development Documents without providing prior written notice, along with copies of such amendments or modifications, to Lender and obtaining its prior consent.

  • Except for Minor Change Orders, Borrower will not amend or modify (or permit the amendment or modification of) any provisions of the Plans, Construction and Development Documents without providing prior written notice, along with copies of such amendments or modifications, to Agent and obtaining the prior consent required by Section 4.15.

  • Dividend Member may also require Minor Change Orders to be made, without any limitation to the amount, provided that the Members shall fund increases in the Development Budget as a result of Minor Change Order required by Dividend Member in accordance with their Capital Sharing Ratios.

  • Except for Minor Change Orders, Borrower will not amend or modify any provisions of the Plans, Construction and Development Documents or the Project Covenant Documents without providing prior written notice, along with copies of such amendments or modifications, to Lender and obtaining the prior consent required by Section 4.15.

  • Other than with respect to Minor Change Orders, any amendments or changes to the Renovation Budget shall require the approval of Lender in its reasonable discretion.

  • Agent’s approval will be required for changes in the Plans or the other Construction and Development Documents which are not Minor Change Orders, which approval shall not be unreasonably withheld, conditioned or delayed.

  • Agent's approval will be required for changes in the Plans or the other Construction and Development Documents which are not Minor Change Orders.

Related to Minor Change Orders

  • Change Orders mean changes or modifications to any Construction Contract or any other contract with labor or material suppliers.

  • Change Order means a written order to the Contractor signed by the Contracting Officer, issued after execu- tion of the Contract, authorizing a change in the term or scope of the Contract.

  • Construction Change Directive means a written order prepared by Owner Parties and signed by Owner directing Contractor to perform a change in the Work prior to agreeing to a change, if any, to the Contract Time, schedule of performance of the Work, Contract Sum, or Contractor’s compensation.

  • Change Order Request means a written request or proposal for a Change Order submitted by either Company or Contractor and including:

  • Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.