Landlord Consent means a Landlord Consent substantially in the form of Exhibit G.
Landlord Waiver means a letter in form and substance reasonably acceptable to the Administrative Agent and executed by a landlord in respect of Inventory of a Loan Party located at any leased premises of a Loan Party pursuant to which such landlord, among other things, waives or subordinates on terms and conditions reasonably acceptable to the Administrative Agent any Lien such landlord may have in respect of such Inventory.
Landlord Access Agreement means a Landlord Access Agreement, substantially in the form of Exhibit G, or such other form as may reasonably be acceptable to the Administrative Agent.
Landlord Consent and Estoppel means, with respect to any Leasehold Property, a letter, certificate or other instrument in writing from the lessor under the related lease, pursuant to which, among other things, the landlord consents to the granting of a Mortgage on such Leasehold Property by the Credit Party tenant, such Landlord Consent and Estoppel to be in form and substance acceptable to Collateral Agent in its reasonable discretion, but in any event sufficient for Collateral Agent to obtain a Title Policy with respect to such Mortgage.
Landlord Personal Property Collateral Access Agreement means a Landlord Waiver and Consent Agreement substantially in the form of Exhibit K with such amendments or modifications as may be approved by the Collateral Agent.
this Tenant Work Letter means the relevant portion of Sections 1 through 6 of this Tenant Work Letter.
Landlord Liens means liens on or against the Leased Property or any payment of Rent (a) which result from any act of, or any claim against, Landlord or any owner (other than Tenant) of a direct or indirect interest in the Leased Property, or which result from any violation by Landlord of any terms of this Agreement or the Purchase Agreement, or (b) which result from liens in favor of any taxing authority by reason of any tax owed by Landlord or any fee owner of a direct or indirect interest in the Leased Property; provided, however, that "Landlord Lien" shall not include any lien resulting from any tax for which Tenant is obligated to pay or indemnify Landlord against until such time as Tenant shall have already paid to or on behalf of Landlord the tax or the required indemnity with respect to the same.
Landlord Agreement means an agreement substantially in the form provided by Lender to Borrower or such other form as Lender may agree to accept.
Sublessor means one who conveys real property by sublease."
Lessor means a person who transfers the right to possession and use of goods under a lease. Unless the context clearly indicates otherwise, the term includes a sublessor.
Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.
Landlord Lien State means any state in which a landlord’s claim for rent has priority by operation of Applicable Law over the lien of the Collateral Agent in any of the Collateral.
Work Letter means the work letter between Landlord and Tenant regarding the construction of the Tenant Improvements, if any, in the form of Exhibit C.
Landlord Default shall have the meaning given such term in Article 14.
Sublandlord means the holder of sublandlord’s interest under this Sublease. In the event of any assignment or transfer of the Sublandlord’s interest under this Sublease, which assignment or transfer may occur at any time during the Term in Sublandlord’s sole discretion, Sublandlord shall be and hereby is entirely relieved of all covenants and obligations of Sublandlord hereunder accruing subsequent to the date of the transfer and it shall be deemed and construed, without further agreement between the parties hereto, that any transferee has assumed and shall carry out all covenants and obligations thereafter to be performed by Sublandlord hereunder. Sublandlord may transfer and deliver the then existing Letter of Credit to the transferee of Sublandlord’s interest under this Sublease, and thereupon Sublandlord shall be discharged from any further liability with respect thereto. In addition, Sublandlord shall comply with all of its obligations as “Tenant” under the Master Lease except to the extent that any such obligation is the obligation of Subtenant pursuant to the terms of this Sublease. Notwithstanding any other term or provision of this Sublease, the liability of Subtenant to Sublandlord for any default in Subtenant’s obligations under this Sublease shall be limited to actual, direct damages, and under no circumstances shall Sublandlord, its partners, members, shareholders, directors, agents, officers, employees, contractors, sublessees, successors and/or assigns be entitled to recover from Subtenant (or otherwise be indemnified by Subtenant) for lost revenues, lost profit or other consequential, special or punitive damages arising in connection with this Sublease for any reason, except for any breach by Subtenant under Section 32 of the Master Lease. Notwithstanding any other term or provision of this Sublease, no personal liability shall at any time be asserted or enforceable against Subtenant’s shareholders, directors, officers, or partners on account of any of Subtenant’s obligations or actions under this Sublease.
Ground Lease means a lease creating a leasehold estate in real property where the fee owner as the ground lessor conveys for a term or terms of years its entire interest in the land and buildings and other improvements, if any, comprising the premises demised under such lease to the ground lessee (who may, in certain circumstances, own the building and improvements on the land), subject to the reversionary interest of the ground lessor as fee owner. With respect to any Mortgage Loan where the Mortgage Loan is secured by a Ground Leasehold estate in whole or in part, and the related Mortgage does not also encumber the related lessor’s fee interest in such Mortgaged Property, based upon the terms of the Ground Lease and any estoppel or other agreement received from the ground lessor in favor of Mortgage Loan Seller, its successors and assigns (collectively, the “Ground Lease and Related Documents”), Mortgage Loan Seller represents and warrants that:
Landlord shall have the meaning given such term in the preambles to this Agreement and shall also include their respective permitted successors and assigns.
Tenant Inducement Costs shall not include loss of income resulting from any free rental period, it being agreed that Seller shall bear the loss resulting from any free rental period until the date of Closing and that Purchaser shall bear such loss from and after the date of Closing.
Superior Landlord means and includes people or persons to whom the ownership or interest in the Leasehold Property might revert in the fullness of time.
Tenant Work All work installed or furnished to the Premises by Tenant in connection with Tenant’s initial occupancy pursuant to Rider 2 and the Workletter.
Landlord Delay shall occur if either: (i) Landlord fails to complete the Base Building and/or other improvements on the Project that are required by the DDA, the Parking REA and/or the CC&Rs, and as a direct result of such failure Tenant is unable to obtain a temporary or permanent certificate of occupancy for the Premises upon substantial completion of the Tenant Improvements; or (ii) substantial completion of the Warm Shell Improvements or Tenant Improvements is delayed directly and solely as a result of any of the following and such delay could not have been mitigated by Tenant using commercially reasonable measures, which delay occurs after the Delivery Date and before the Commencement Date and does not result from Tenant's interference or delay in connection with completion of the Tenant Improvements or after a Tenant Default or Work Letter Draw Event: (a) subject to Paragraph 8 above, unreasonable interference by Landlord or Landlord's Contractor with the construction of the Warm Shell Improvements or the Tenant Improvements; (b) Landlord's failure to comply with any deadlines for response to, or submissions from, Tenant as required by this Work Letter; (c) any material Discretionary Changes to Landlord's Plans or the Warm Shell Plans after their final approval by applicable governmental entities (other than Tenant Modifications) that directly affect Tenant's Plans or the Tenant Improvements; and/or (d) Landlord failure to complete portions of the Base Building and/or other improvements on the Project that are Landlord's obligation to complete hereunder, and as a direct result of such failure Tenant and Tenant's contractors do not have access to the Premises to the extent required to complete the Warm Shell Improvements and/or Tenant Improvements. Tenant shall give Landlord at least five (5) days prior notice if Tenant becomes aware that Landlord is in danger of causing a Landlord Delay, and if Landlord takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Commencement Date shall be made on account of such Landlord; provided, however, that if such delay was not reasonably foreseeable by Tenant, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Tenant becomes aware of such delay or potential delay.
Lessors means a lessor under a Superior Lease.
Master Lease means that certain [Master Lease title], relating to the leasing of, inter alia, the Healthcare Facility by Borrower to Master Tenant.
Facility Mortgagee means the holder of any Facility Mortgage.
Alterations means all changes, additions, improvements or repairs to, all alterations, reconstructions, renewals, replacements or removals of and all substitutions or replacements for any of the Improvements or Equipment, both interior and exterior, structural and non-structural, and ordinary and extraordinary.
Facility Lease means a lease or master lease with respect to any Real Property Asset owned or ground leased by any of the Consolidated Parties as lessor, to a third party Tenant, which, in the reasonable judgment of the Administrative Agent, is a triple net lease such that such Tenant is required to pay all taxes, utilities, insurance, maintenance, casualty insurance payments and other expenses with respect to the subject Real Property Asset (whether in the form of reimbursements or additional rent) in addition to the base rental payments required thereunder such that net operating income to the applicable Consolidated Party for such Real Property Asset (before non-cash items) equals the base rent paid thereunder; provided, that each such lease or master lease shall be in form and substance reasonably satisfactory to the Administrative Agent.