Capacity Deficiency Damages definition

Capacity Deficiency Damages shall have the meaning set forth in Section 3.4(g) hereof.

Examples of Capacity Deficiency Damages in a sentence

  • Each Party agrees and acknowledges that (i) the damages that Buyer would incur due to the Capacity Deficiency would be difficult or impossible to predict with certainty, and (ii) it is impractical and difficult to assess actual damages in the circumstances stated, and therefore the Capacity Deficiency Damages as agreed to by the Parties and set forth herein are a fair and reasonable calculation of such damages.

  • The contractor and the City will agree and covenant that the contractor has incorporated a stipulated fee into its contract with the City that has a specified additional indemnification, noting that it is both parties full intention that this provision shall be enforceable and said provision shall be in compliance with Florida Statute §725.06.

Related to Capacity Deficiency Damages

  • Daily Delay Damages means with respect to a Guaranteed Project Milestone, an amount equal to (a) the Project Development Security Amount posted as of the first date that Daily Delay Damages are payable under this Agreement with respect to such Guaranteed Project Milestone, divided by (b) 120.

  • Delay Damages means the damages assessed pursuant to Section 3.2(a) hereof.

  • Rejection Damages Claim means any Claim on account of the rejection of an Executory Contract or Unexpired Lease pursuant to section 365 of the Bankruptcy Code.

  • Catastrophic Damage as used hereunder is major change or damage to In- cluded Timber on Sale Area, to Sale Area, to access to Sale Area, or a combination thereof:

  • Final RTO Unforced Capacity Obligation means the capacity obligation for the PJM Region, determined in accordance with RAA, Schedule 8. Financial Close:

  • Seller Damages shall have the meaning given to such term in Section 14.3.

  • Actual Damages has the meaning set forth in Section 12.4(C).

  • Consequential Loss means loss of profits, anticipated loss of profit or revenue, loss of production, loss of business opportunity, loss of or damage to goodwill or reputation, loss of use or any other similar loss, but excludes:

  • Major Damage means damage that in the estimation of the surveyor exceeds USD

  • Economic damages means objectively verifiable monetary losses, including medical expenses, loss of earnings, burial costs, loss of use of property, cost of replacement or repair, cost of obtaining substitute domestic services, loss of employment, and loss of business or employment opportunities.

  • Daily Unforced Capacity Obligation means the capacity obligation of a Load Serving Entity during the Delivery Year, determined in accordance with Reliability Assurance Agreement, Schedule 8, or, as to an FRR entity, in Reliability Assurance Agreement, Schedule 8.1. Day-ahead Congestion Price: “Day-ahead Congestion Price” shall mean the Congestion Price resulting from the Day-ahead Energy Market. Day-ahead Energy Market:

  • Consequential Damages means Losses claimed to have resulted from any indirect, incidental, reliance, special, consequential, punitive, exemplary, multiple or any other Loss, including damages claimed to have resulted from harm to business, loss of anticipated revenues, savings, or profits, or other economic Loss claimed to have been suffered not measured by the prevailing Party’s actual damages, and any other damages typically considered consequential damages under Applicable Law, regardless of whether the Parties knew or had been advised of the possibility that such damages could result in connection with or arising from anything said, omitted, or done hereunder or related hereto, including willful acts or omissions.

  • Noneconomic damages ’ means damages for phys-

  • Environmental Damages means all claims, judgments, damages, losses, penalties, fines, liabilities, encumbrances, liens, costs and expenses of investigation and defense of any claim, including, without limitation, attorney’s fees, that are incurred at any time as a result of the existence of Environmental Conditions upon, about or beneath the Project Site or migrating or threatening to migrate to or from the Site, and including, without limitation:

  • Indemnity Threshold has the meaning set forth in Section 9.3.

  • Defect Liability Period in relation to a work means the specified period from the date of COMPLETION CERTIFICATE upto the date of issue of FINAL CERTIFICATE during which the CONTRACTOR stands responsible for rectifying all defects that may appear in the works executed by the CONTRACTOR in pursuance of the CONTRACT and includes warranties against Manufacturing/Fabrication/ Erection/Construction defects covering all materials plants, equipment, components, and the like supplied by the CONTRACTOR, works executed against workmanship defects.

  • Defects Liability Period means the warranty period following the taking over, during which the Contractor is responsible for making good, defects and damage in Goods and Services provided, under the Contract.

  • Force Majeure Failure has the meaning set forth in Section 8.1(d).

  • Defects Liability Period (Warranty Period) means the period stated in the Schedule A Special Stipulations, following the taking over, during which the Contractor is responsible for making good defects and damage in accordance with Clause 15.

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.

  • Unwind Costs means an amount determined by the Calculation Agent equal to the sum of (without duplication) all costs, fees, charges, expenses (including loss of funding), tax and duties incurred by the Issuer and/or any of its Affiliates in connection with the redemption of the Credit- Linked Notes and the related termination, settlement or re- establishment of any hedge or related trading position.

  • Compensatory Damages are those amounts awarded to compensate for the actual damages sustained, and are not awarded as a penalty, nor fixed in amount by statute.

  • Punitive Damages are those damages awarded as a penalty, the amount of which is neither governed nor fixed by statute.

  • Cover Damages means, with respect to any Delivery Shortfall, an amount equal to (a) the positive net amount, if, any, by which the Replacement Price exceeds the applicable Price that would have been paid pursuant to Section 5.1 and the Cover Sheet, multiplied by the quantity of that Delivery Shortfall, plus (b) any applicable penalties and other costs assessed by ISO-NE or any other Person against Buyer as a result of Seller’s failure to deliver such Products in accordance with the terms of this Agreement. Buyer shall provide a statement for the applicable period explaining in reasonable detail the calculation of any Cover Damages.

  • Electrical Losses means all applicable losses, including the following: (a) any transmission or transformation losses between the CAISO revenue meter(s) and the Delivery Point; and

  • Epidemic Failure means a series of repeating failures or defects resulting in at least a 0.5% failure rate for the same Product or Material during any twelve-month period.