RIGHT TO ENTER THE APARTMENT FOR REPAIRS The Promoter / maintenance agency /association of allottees shall have rights of unrestricted access of all Common Areas, garages/closed parking's and parking spaces for providing necessary maintenance services and the Allottee agrees to permit the association of allottees and/or maintenance agency to enter into the [Apartment/Plot] or any part thereof, after due notice and during the normal working hours, unless the circumstances warrant otherwise, with a view to set right any defect.
Representations and Warranties of the Corporation The Corporation hereby represents and warrants to the Purchaser as follows:
POSSESSION OF THE APARTMENT 7.1 Schedule for possession of the said Apartment - The Promoter agrees and understands that timely delivery of possession of the Apartment to the allottee’s and the common areas to the association of allottee’s or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the Apartment along with ready and complete common areas with all specifications, amenities and facilities of the project in place on (Date) unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee’s agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, provided that such Force Majeure conditions are not of a nature, which make it impossible for the contract to be implemented. The Allottee’s agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee’s the entire amount received by the Promoter from the allotment within 45 days from that date. The promoter shall intimate the allottee’s about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee’s, the Allottee’s agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
Representations and Warranties of the Vendor The Vendor hereby makes the following representations and warranties to the Purchaser and acknowledges that the Purchaser is relying on such representations and warranties in entering into this Agreement and completing the Transaction:
Representations and Warranties of the Issuer The Issuer represents and warrants that:
Representations of the Parties Each party hereto hereby further represents and warrants to the other that: (i) it is registered as an investment adviser under the Advisers Act and is registered or licensed as an investment adviser under the laws of all jurisdictions in which its activities require it to be so registered or licensed; and (ii) it will use its reasonable best efforts to maintain each such registration or license in effect at all times during the term of this Agreement; and (iii) it will promptly notify the other if it ceases to be so registered, if its registration is suspended for any reason, or if it is notified by any regulatory organization or court of competent jurisdiction that it should show cause why its registration should not be suspended or terminated; and (iv) it is duly authorized to enter into this Agreement and to perform its obligations hereunder. The Sub-Adviser further represents that it has adopted a written Code of Ethics in compliance with Rule 17j-1(b) of the ICA. The Sub-Adviser shall be subject to such Code of Ethics and shall not be subject to any other Code of Ethics, including the Investment Manager's Code of Ethics, unless specifically adopted by the Sub-Adviser. The Investment Manager further represents and warrants to the Sub-Adviser that (i) the appointment of the Sub-Adviser by the Investment Manager has been duly authorized and (ii) it has acted and will continue to act in connection with the transactions contemplated hereby, and the transactions contemplated hereby are, in conformity with the ICA, the Company's governing documents and other applicable law.
Representations of the District The District represents, covenants and warrants to the Developer as follows:
Representations and Warranties of the Company The Company represents and warrants to each Underwriter that:
Representations of the Developer The Developer represents, covenants and warrants to the District as follows:
