TENANT'S USE OF THE PREMISES In consideration of the agreements contained herein, Landlord hereby leases the Premises to Tenant, and Tenant hereby leases the Premises from Landlord, for the Term and upon the terms and conditions hereinafter provided. The Premises are leased subject to, and Tenant agrees not to violate, all present and future covenants, conditions and restrictions of record which affect the Land, all of such documents collectively referred to as the "Restrictions". As an appurtenance to the Premises, Tenant shall have the general and nonexclusive right, together with Landlord and the other tenants of the Project and their respective agents, to use the Common Area subject to the terms and conditions of this Lease. Tenant shall use the Premises solely for the purpose set forth in Tenant's Use Clause as designated in Article 2.n and for no other purpose. Tenant shall not use or occupy the Premises in violation of law or any covenant, condition or restriction affecting the Building or Project or the certificate of occupancy issued for the Building or Project, and shall, upon notice from Landlord, immediately discontinue any use of the Premises which is declared by any governmental authority having jurisdiction to be a violation of law or the certificate of occupancy. Tenant, at Tenant's own cost and expense, shall comply with all laws, ordinances, regulations, rules and/or any directions of any governmental agencies or authorities having jurisdiction which shall by reason of the nature of Tenant's use or occupancy of the Promises, impose any duty upon Tenant or Landlord with respect to the Premises or its use or occupation. A judgment of any court of competent jurisdiction or the admission by Tenant in any action or proceeding against Tenant that Tenant has violated any such laws, ordinances, regulations, rules and/or directions in the use of the Premises shall be deemed to be a conclusive determination of that fact as between Landlord and Tenant. Tenant shall not do or permit to be done anything which will invalidate or increase the cost of any fire, extended coverage or other insurance policy covering the Building or Project and/or property located therein, and shall comply with all rules, orders, regulations, requirements and recommendations of the Board of Fire Insurance underwriters or any other organization performing a similar function. Tenant shall promptly upon demand reimburse Landlord for any additional premium charged for such policy by reason of Tenant's failure to comply with the provisions of this Article. Tenant shall not do or permit anything to be done in or about the Premises which will in any way obstruct or interfere with the rights of other tenants or occupants of the Building or Project, or injure or annoy them, or use or allow the Premises to be used for any improper, immoral, unlawful or objectionable purpose, nor shall Tenant cause, maintain or permit any nuisance in, on or about the Premises. Tenant shall not commit or suffer to be committed any waste in or upon the Premises. Tenant acknowledges that Tenant assumes all responsibility regarding the Occupational Safety Health Act, the legal use and adaptability of the Premises and the compliance thereof with all applicable laws and regulations in effect during the form of this Lease.
TENANT'S USE OF PREMISES Tenant agrees that the Premises shall be used and occupied only for the Permitted Uses specified in the Basic Provisions, and for no other use. Tenant shall not use or permit the Premises to be used for any other purpose or purposes or under any other trade name whatsoever without the prior written consent of Landlord, which consent may be withheld or granted at Landlord’s sole and absolute discretion. Tenant’s use of the Premises shall be in compliance with and subject to all applicable governmental laws, ordinances, statutes, orders and regulations and any CC&R’s (including payments thereunder, if any) or any supplement thereto recorded in any official or public records with respect to the Project or any portion thereof. In the event Landlord desires to record CC&R’s against the Project after the date of full execution of this Lease, Landlord shall, at its option, either (i) obtain Tenant’s consent thereto, which consent shall not be unreasonably withheld (provided Tenant’s material rights and obligations under the Lease are not impaired, but provided that any provisions of such CC&R’s which require Tenant to pay reasonable assessments such as for common area maintenance and landscaping shall not be deemed to impair Tenant’s material rights and obligations under this Lease), conditioned or delayed or (ii) elect not to obtain Tenant’s consent thereto, in which event the provisions of this Lease shall prevail over any conflicting provisions of the CC&R’s. Tenant further covenants and agrees that it will not use or suffer or permit any person or persons to use the Premises or any part thereof for conducting therein a second-hand store, auction, distress or fire sale or bankruptcy or going-out-of- business sale, or for any use or purpose in violation of the laws of the United States of America or the laws, ordinances, regulations and requirements of the State, County and City wherein the Premises are situated, including in violation of any of the permitted use restrictions outlined in Exhibit N. Tenant, at Tenant’s sole cost and expense, shall comply with the rules and regulations attached hereto as Attachment 1, together with such additional rules and regulations as Landlord may from time to time prescribe. Tenant shall not commit waste; overload the floors or structure of the Building in which the Premises are located; subject the Premises, the Building, the Common Area or the Project to any use which would damage the same or increase the risk of loss or violate any insurance coverage; permit any unreasonable odors, smoke, dust, gas, substances, noise or vibrations to emanate from the Premises, take any action which would constitute a nuisance or would disturb, obstruct or endanger any other tenants, take any action which would abrogate any warranties; or use or allow the Premises to be used for any unlawful purpose. Tenant shall promptly comply with the reasonable require- Landlord’s Initials CZ Tenant’s Initials HZ ments of any board of fire insurance underwriters or other similar body now or hereafter constituted. Tenant shall not do any act which shall in any way encumber the title of Landlord in and to the Premises, the Building or the Project. Tenant further covenants and agrees that during the term hereof the Premises, and every part thereof, shall be kept by Tenant in a first-class, clean and wholesome condition, free of any objectionable noises, odors or nuisances, and that all fire, safety, health and police regulations shall, in all respects and at all times, be fully complied with by Tenant.
Tenant's Use Tenant shall not use or permit the Premises, or any part thereof, to be used for any purpose other than that for which the Premises are hereby leased; and no use of the Premises shall be made or permitted, nor acts done, which will cause an increase in premiums or a cancellation of any insurance policy covering the Premises or any part thereof, nor shall Tenant sell or permit to be sold, kept, or used in or about the Premises, any article prohibited by the standard form of fire insurance policies. Tenant shall, at its sole cost, comply with all requirements of any insurance company or organization necessary for the maintenance of reasonable fire and public liability insurance covering the Premises and appurtenances.
Landlord’s General Conditions for Tenant’s Agents and Tenant Improvement Work Tenant’s and Tenant’s Agent’s construction of the Tenant Improvements shall comply with the following: (i) the Tenant Improvements shall be constructed in strict accordance with the Approved Working Drawings; (ii) Tenant’s Agents shall submit schedules of all work relating to the Tenant’s Improvements to Contractor and Contractor shall, within five (5) business days of receipt thereof, inform Tenant’s Agents of any changes which are necessary thereto, and Tenant’s Agents shall adhere to such corrected schedule; and (iii) Tenant shall abide by all rules made by Landlord’s Building manager with respect to the use of freight, loading dock and service elevators, storage of materials, coordination of work with the contractors of other tenants, and any other matter in connection with this Tenant Work Letter, including, without limitation, the construction of the Tenant Improvements.
Tenant’s Entry Into the Premises Prior to Substantial Completion Subject to the terms hereof and provided that Tenant and its agents do not interfere with, or delay, Contractor’s work in the Building and the Premises, at Landlord’s reasonable discretion, Contractor shall allow Tenant access to the Premises prior to the Substantial Completion of the Premises for the purpose of Tenant installing any necessary furniture, equipment or fixtures (including Tenant’s data and telephone equipment) in the Premises. Prior to Tenant’s entry into the Premises as permitted by the terms of this Section 6.01, Tenant shall submit a schedule to Landlord and Contractor, for their approval, which schedule shall detail the timing and purpose of Tenant’s entry, and Landlord will reasonably cooperate with Tenant to coordinate Landlord’s Contractor’s work of constructing the Tenant Improvements with such access by Tenant for the installation of Tenant’s furniture, equipment and fixtures. In connection with any such entry, Tenant acknowledges and agrees that Tenant’s employees, agents, contractors, consultants, workmen, mechanics, suppliers and invitees shall fully cooperate, work in harmony and not, in any manner, interfere with Landlord or Landlord’s Contractor, agents or representatives in performing work in the Building and the Premises, or interfere with the general operation of the Building and/or the Project; and such entry shall be subject to the site management rules of Landlord and Landlord’s Contractor. If at any time any such person representing Tenant shall not be cooperative or shall otherwise cause or threaten to cause any such disharmony or interference, including, without limitation, labor disharmony, and Tenant fails to immediately institute and maintain corrective actions as directed by Landlord, then Landlord may revoke Tenant’s entry rights upon twenty-four (24) hours’ prior written notice to Tenant. Tenant acknowledges and agrees that any such entry into and occupancy of the Premises or any portion thereof by Tenant or any person or entity working for or on behalf of Tenant shall be deemed to be subject to all of the terms, covenants, conditions and provisions of the Lease, excluding only the covenant to pay Rent (until the occurrence of the Lease Commencement Date). Tenant further acknowledges and agrees that Landlord shall not be liable for any injury, loss or damage which may occur to any of Tenant’s work made in or about the Premises in connection with such entry or to any property placed therein prior to the Lease Commencement Date, the same being at Tenant’s sole risk and liability. Tenant shall be liable to Landlord for any damage to any portion of the Premises, including the Tenant Improvement work, caused by Tenant or any of Tenant’s employees, agents, contractors, consultants, workmen, mechanics, suppliers and invitees. If the performance of Tenant’s work in connection with such entry causes extra costs to be incurred by Landlord or requires the use of any Building services, Tenant shall promptly reimburse Landlord for such extra costs and/or shall pay Landlord for such Building services at Landlord’s standard rates then in effect. In addition, Tenant shall hold Landlord harmless from and indemnify, protect and defend Landlord against any loss or damage to the Building or Premises and against injury to any persons caused by Tenant’s actions pursuant to this Section 6.01.
USE OF THE LEASED PREMISES (a) Lessor, in consideration of the rents to be paid and covenants herein contained, hereby leases to Lessee the Leased Premises.
Repair of Damage to Premises by Landlord Tenant shall promptly notify Landlord of any damage to the Premises resulting from fire or any other casualty. If the Premises or any Common Areas serving or providing access to the Premises shall be damaged by fire or other casualty, Landlord shall promptly and diligently, subject to reasonable delays for insurance adjustment or other matters beyond Landlord’s reasonable control, and subject to all other terms of this Article 11, restore the Base Building and such Common Areas. Such restoration shall be to substantially the same condition of the Base Building and the Common Areas prior to the casualty, except for modifications required by zoning and building codes and other laws or by the holder of a mortgage on the Building or Project or any other modifications to the Common Areas deemed desirable by Landlord, which are consistent with the character of the Project, provided that access to the Premises and any common restrooms serving the Premises shall not be materially impaired. Upon the occurrence of any damage to the Premises, upon notice (the “Landlord Repair Notice”) to Tenant from Landlord, Tenant shall assign to Landlord (or to any party designated by Landlord) all insurance proceeds payable to Tenant under Tenant’s insurance required under Section 10.3 of this Lease, and Landlord shall repair any injury or damage to the Tenant Improvements and the Original Improvements installed in the Premises and shall return such Tenant Improvements and Original Improvements to their original condition; provided that if the cost of such repair by Landlord exceeds the amount of insurance proceeds received by Landlord from Tenant’s insurance carrier, as assigned by Tenant, the cost of such repairs shall be paid by Tenant to Landlord prior to Landlord’s commencement of repair of the damage. In the event that Landlord does not deliver the Landlord Repair Notice within sixty (60) days following the date the casualty becomes known to Landlord, Tenant shall, at its sole cost and expense, repair any injury or damage to the Tenant Improvements and the Original Improvements installed in the Premises and shall return such Tenant Improvements and Original Improvements to their original condition. Whether or not Landlord delivers a Landlord Repair Notice, prior to the commencement of construction, Tenant shall submit to Landlord, for Landlord’s review and approval, all plans, specifications and working drawings relating thereto, and Landlord shall select the contractors to perform such improvement work. Landlord shall not be liable for any inconvenience or annoyance to Tenant or its visitors, or injury to Tenant’s business resulting in any way from such damage or the repair thereof; provided however, that if such fire or other casualty shall have damaged the Premises or Common Areas necessary to Tenant’s occupancy, and the Premises are not occupied by Tenant as a result thereof, then during the time and to the extent the Premises are unfit for occupancy, the Rent shall be abated in proportion to the ratio that the amount of rentable square feet of the Premises which is unfit for occupancy for the purposes permitted under this Lease bears to the total rentable square feet of the Premises. In the event that Landlord shall not deliver the Landlord Repair Notice, Tenant’s right to rent abatement pursuant to the preceding sentence shall terminate as of the date which is reasonably determined by Landlord to be the date Tenant should have completed repairs to the Premises assuming Tenant used reasonable due diligence in connection therewith.
Construction of Tenant Improvements Promptly following approval of the Final TI Working Drawings, Landlord shall apply for and use reasonable efforts to obtain the necessary permits and approvals to allow construction of Landlord’s TI Work. Upon receipt of such permits and approvals, Landlord shall, at Tenant’s expense (subject to the application of the Tenant Improvement Allowance provided in this Workletter, and subject to any other applicable provisions of the Lease or of this Workletter expressly making any specific item of expense or cost the responsibility of Landlord), diligently construct and complete Landlord’s TI Work substantially in accordance with the Approved TI Plans, subject to Unavoidable Delays and Tenant Delays (if any). Such construction shall be performed in a good and workmanlike manner and shall conform to all applicable governmental codes, laws and regulations in force at the time such work is completed. Without limiting the generality of the foregoing, Landlord shall be responsible for compliance of Landlord’s TI Work with the requirements of the Americans with Disabilities Act and all similar or related requirements pertaining to access by persons with disabilities, but nothing in this sentence shall be construed to make Landlord responsible for bearing the cost of any such compliance, to the extent the compliance work is reasonably attributable to or related to the particular nature or design of the Tenant Improvements or is for any other reason expressly made Tenant’s cost or responsibility under any applicable provision of the Lease or of this Workletter. Landlord shall have the right, in its sole discretion, to decide whether and to what extent to use union labor on or in connection with Landlord’s Work, and shall use the TI General Contractor to construct all of Landlord’s TI Work. Landlord and Tenant shall each have a right to approve all subcontractors engaged in connection with the construction of the Tenant Improvements and to review and approve all competitive bids for any elements of the Tenant Improvements, such approval in each instance not to be unreasonably withheld, conditioned or delayed by either party.
Tenants Selection of Contractors Tenant hereby agrees to the retention by Landlord of Erland Construction, Inc., on behalf of Tenant, for the construction of the Tenant Improvements ("Contractor"). Tenant further agrees that Contractor will be retained on a construction management basis at a fee equal to three and nine-tenths percent (3.9%) of the cost of Tenant Improvements. Contractor shall retain only subcontractors designated by Landlord in connection with any structural, fire sprinkler, or heating, air-conditioning or ventilation work to be performed in the Premises or for any work to be done to the Base Building or the Building Systems.
Overstandard Tenant Use If Tenant uses water, electricity, heat or air conditioning in excess of that supplied by Landlord pursuant to Section 6.1 of this Lease, Tenant shall pay to Landlord, upon billing, the cost of such excess utility consumption, the cost of the installation, operation, and maintenance of equipment which is required to be installed in order to supply such excess consumption; and, to the extent no previously installed, Landlord may install devices to separately sub-meter any increased use and in such event Tenant shall pay the increased cost directly to Landlord, on demand, at the rates charged by the public utility company furnishing the same, including the cost of such additional metering (or sub-metering) devices. Tenant’s use of electricity shall never exceed the capacity of the feeders to the Property or the risers or wiring installation; provided, however, Tenant shall have the right, subject to the terms of Article 8, to increase such capacity. Notwithstanding anything to the contrary in this Lease, Tenant may operate the HVAC within the Premises at its discretion; provided, however, if Tenant desires to use heat, ventilation or air conditioning during hours other than those for which Landlord is obligated to supply such utilities pursuant to the terms of Section 6.1 of this Lease, Tenant shall reimburse Landlord for the actual cost of supplying chilled water and gas to the Premises during non-Building Hours at the actual rates charged by the utilities, which cost shall be equitably prorated among all Building occupants (other than the Bank) operating HVAC during the same non-Building Hours. For purposes of an example, Exhibit K, attached hereto, sets forth the calculation of such actual utilities costs, with the actual calculation being subject to the actual rates charged by the utilities. Landlord shall, at its sole cost, as part of the Core and Shell Work, provide a cloud-based software system (Workspeed) to allow Tenant to control Tenant’s after-hours HVAC.
