Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Equipment and Software Requirements In order to view and retain electronic communications that we make available to you, you must have: • A PC or other device with an Internet browser that has “cookies” enabled and supports 128 bit encryption • An Internet connection • An email address • A PDF viewer (such as Adobe Reader) • A printer or computer with sufficient electronic storage space All communications shall be delivered to the last address we have on file for you. These notices will be sent through electronic delivery (email) and will be considered delivered the same day as sent. If you have opted out of electronic delivery, communications sent to you through the United States Postal Service are considered delivered 5 business days after the postmark date. It is your responsibility to notify the Custodian of any email address change or residential address change. We will not be held liable for any losses or damages if you have not provided Custodian with the most current address information. The electronically signed copy of this document should be considered equivalent to a printed hard copy form. It is considered a true and complete record of the document, admissible in arbitration and/or administrative hearings or proceedings. Your electronic signature on the Application and other electronic forms such as the Investment Direction are considered valid and the same as if the paper form or Application were signed.
Configuration The configuration for the Purchase Right Aircraft will be the Detail Specification for Model 767-3S2F aircraft at the revision level in effect at the time of the Supplemental Agreement. Such Detail Specification will be revised to include (i) changes required to obtain required regulatory certificates and (ii) other changes as mutually agreed upon by Boeing and Customer.
Technical and Interconnection Requirements 2.1 Consumer agrees that his Rooftop Solar PV System and Net Metering System will conform to the standards and requirements specified in the Policy, Regulations and Supply Code as amended from time to time.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
ELECTRICITY INFORMATION EXCHANGE PROTOCOLS 31.1 Protocols for exchanging information: The Distributor and the Trader must, when exchanging information to which an EIEP listed in Schedule 3 relates, comply with that EIEP.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Customer Support and Training System Agency will provide support for the CMBHS, including problem tracking and problem resolution. System Agency will provide telephone numbers for Grantees to obtain access to expert assistance for CMBHS-related problem resolution. System Agency will provide initial CMBHS training. Grantee shall provide subsequent ongoing end-user training.
Forecasting Requirements for Trunk Provisioning Within ninety (90) days of executing this Agreement, Reconex shall provide Verizon a two (2) year traffic forecast. This initial forecast will provide the amount of traffic to be delivered to and from Verizon over each of the Local Interconnection Trunk groups over the next eight (8) quarters. The forecast shall be updated and provided to Verizon on an as-needed basis but no less frequently than semiannually. All forecasts shall comply with the Verizon CLEC Interconnection Trunking Forecast Guide and shall include, at a minimum, Access Carrier Terminal Location (“ACTL”), traffic type (Local Traffic/Toll Traffic, Operator Services, 911, etc.), code (identifies trunk group), A location/Z location (CLLI codes for Reconex-IPs and Verizon-IPs), interface type (e.g., DS1), and trunks in service each year (cumulative).
Technical Specifications The Technical Specifications furnished on the CD are intended to establish the standards for quality, performance and technical requirements for all labor, workmanship, material, methods and equipment necessary to complete the Work. When specifications and drawings are provided or referenced by the County, these are to be considered part of the Scope of Work, and to be specifically documented in the Detailed Scope of Work. For convenience, the County supplied specifications, if any, and the Technical Specifications furnished on the CD.
