Additional Requirements from Authorized Users An Authorized User may have distinct requirements that must be met by all individuals employed by or working for the Authorized User. The Contractor’s Staff Members will be expected to comply with these requirements as a condition of the placement.
Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract.
Additional Requirements for Sleeping Rooms The Contractor shall provide departing Attendees a secured area for storing belongings.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Requirements Pertaining Only to Federal Grants and Subrecipient Agreements If this Agreement is a grant that is funded in whole or in part by Federal funds:
OBLIGATIONS AND ACTIVITIES OF CONTRACTOR AS BUSINESS ASSOCIATE 1. Contractor agrees not to use or further disclose PHI County discloses to Contractor other than as permitted or required by this Business Associate Contract or as required by law.
Packaging Materials and Containers for Retail Sale Packaging materials and containers in which a good is packaged for retail sale shall, if classified with the good, be disregarded in determining whether all the non-originating materials used in the production of the good undergo the applicable change in tariff classification set out in Annex 4, and, if the good is subject to a regional value-content requirement, the value of such packaging materials and containers shall be taken into account as originating or non-originating materials, as the case may be, in calculating the regional value content of the good.
Customer to Provide Certain Information to Bank Upon request, Customer shall promptly provide to Bank such information about itself and its financial status as Bank may reasonably request, including Customer's organizational documents and its current audited and unaudited financial statements.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
New Hampshire Specific Data Security Requirements The Provider agrees to the following privacy and security standards from “the Minimum Standards for Privacy and Security of Student and Employee Data” from the New Hampshire Department of Education. Specifically, the Provider agrees to:
