Sales, Etc of Assets. Sell, lease, transfer or otherwise dispose of, or permit any of its Subsidiaries to sell, lease, transfer or otherwise dispose of, any assets, or grant any option or other right to purchase, lease or otherwise acquire any assets, except:
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Required Vendor Sales Reporting By responding to this Solicitation, you agree to report to TIPS all sales made under any awarded Agreement with TIPS. Vendor is required to report all sales under the TIPS contract to TIPS. If the TIPS Member entity requesting a price from the awarded Vendor requests the TIPS contract, Vendor must include the TIPS Contract number on any communications with the TIPS Member entity. If awarded, you will be provided access to the Vendor Portal. To report sales, login to the TIPS Vendor Portal and click on the PO’s and Payments tab. Pages 3-7 of the Vendor Portal User Guide will walk you through the process of reporting sales to TIPS. Please refer to the TIPS Accounting FAQ’s for more information about reporting sales and if you have further questions, contact the Accounting Team at xxxxxxxxxx@xxxx-xxx.xxx. The Vendor or vendor assigned dealers are responsible for keeping record of all sales that go through the TIPS Agreement and submitting same to TIPS.
Packaging Materials and Containers for Retail Sale Packaging materials and containers in which a good is packaged for retail sale shall, if classified with the good, be disregarded in determining whether all the non-originating materials used in the production of the good undergo the applicable change in tariff classification set out in Annex 4, and, if the good is subject to a regional value-content requirement, the value of such packaging materials and containers shall be taken into account as originating or non-originating materials, as the case may be, in calculating the regional value content of the good.
Proposed Goods and Services Proposed Goods and Services docx Please upload one or more documents or sheets describing your offerings, line cards, catalogs, links to offerings OR li st links to your offerings that illustrate the catalog of proposed lines of goods and or services you carry and offer unde r this proposal. I does not have to be exhaustive but should, at a minimum tell us what you are offering. It could be as simple as a sheet with your link to your online catalog of goods and services. Resellers/Dealers - COMPLETE AND UPLOAD ONLY IF YOU HAVE RESELLER OF YOUR GOODS OR SERVICES PROPOSED No response If the PROPOSING vendor has resellers that will be selling for the vendor UNDER this contract, the vendor must downl oad the Resellers/Dealers spreadsheet from the attachment tab, fill in the requested information and upload the compl eted spreadsheet. DO NOT UPLOAD encrypted or password protected files. HUB Subcontracting Plan Form OPTIONAL No response Completion of the HUB Subcontracting Plan Form is OPTIONAL. THE FORM INFORMATION HAS NO EFFECT ON YO UR EVALUATION SCORE. IT IS INFORMATIONAL ONLY. Some Texas State agencies and Universities require it be a p art of the file when determining if they can use a TIPS contract. If you choose to complete one, it is not project specific but the general plan the vendor would use. Complete it as best you can. Vendor can download the HUB Subcontracting Plan Form from the "Attachments" tab and upload their HUB Subcontra cting Plan Form. D/M/WBE Certification OPTIONAL No response D/M/WBE Certification documentation may be scanned and uploaded if you desire to claim your status as one of the i dentified enterprises. (Disadvantaged Business Enterprise, Minority Business Enterprise and/or Woman Business Ent erprise) If vendor has more than one certification scan into one document. (PDF Format ONLY) DO NOT UPLOAD encrypted or password protected files. HUB Certification OPTIONAL No response HUB Certification documentation may be scanned and uploaded if you desire to document you status as a HUB compa ny. (Historically Underutilized Business) (PDF Format ONLY) DO NOT UPLOAD encrypted or password protected files. Warranty No response Warranty information (if applicable) must be scanned and uploaded. (PDF Format ONLY) DO NOT UPLOAD encrypted or password protected files. Supplementary No response Supplementary information may be scanned and uploaded. (Company information, brochures, catalogs, etc.) (PDF Fo rmat ONLY) DO NOT UPLOAD encrypted or password protected files. All Other Certificates No response All Other Certificates (if applicable) must be scanned and uploaded. If vendor has more than one other certification sc an into one document. (PDF Format ONLY) DO NOT UPLOAD encrypted or password protected files.
Additional Products and Services Subject to the allocation of funds, the CPO may add similar equipment, supplies, services, or locations, within the scope of this Agreement, to the list of equipment, supplies, services, or locations to be performed or provided by giving written notification to Contractor. For purposes of this Section, the “Effective Date” means the date specified in the notification from the CPO. As of the Effective Date, each item added is subject to this Agreement, as if it had originally been a part, but the charge for each item starts to accrue only on the Effective Date. In the event the additional equipment, supplies, services, or locations are not identical to the items(s) already under this Agreement, the charges therefor will then be Contractor’s normal and customary charges or rates for the equipment, supplies, services, or locations classified in the Fees and Costs (Exhibit “F”).
Product Sales Subject to Sections 10.3(c) and 10.3(d), Licensee agrees that it will not sell, offer for sale, or assist third parties (including Affiliates) in selling Product except for the sale and offer for sale of (A) TAF Product, TAF Combination Product, TDF Product and TDF Combination Product for use in the Field and in the countries of the TDF-TAF Territory, (B) COBI Product and COBI Combination Product for use in the Field and in the countries of the COBI Territory, and (C) EVG Product, EVG Combination Product and Quad Product for use in the Field and in the countries of the EVG-Quad Territory.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Product Quality 4.1 The following provisions shall apply to Product after Production:
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
