Right of Collection Sample Clauses

Right of Collection. The Owner has the right to apply any amounts due Contractor under this Agreement or any other agreement between Owner and Contractor, as payment on such liquidated damages due under this Agreement in Owner’s sole discretion. Notwithstanding anything herein to the contrary, Owner retains its right to liquidated damages due under this Agreement even if Contractor, at Owner’s election and in its sole discretion, is allowed to continue and to finish the Work, or any part of it, after the expiration of the Contract Time including granted time extensions.
Sample 1Sample 2Sample 3See All (11)
AutoNDA by SimpleDocs
Right of Collection. The Division has the right to apply as payment on such liquidated damages, any money the Division owes the Contractor.
Sample 1Sample 2Sample 3See All (7)
Right of Collection. The Government has the right to apply as payment on such liquidated damages, any money the Government owes the Contractor.
Sample 1
Right of Collection. CPE Labs will retain a right to collect any unpaid or delinquent accounts from Customer. Customer agrees to pay for any and all reasonable costs, attorney fees, and the costs of collection in connection with any delinquent account. Such costs billable in collection include any costs incurred by Subcontractor during the collection process.
Sample 1
Right of Collection. CPE Labs will retain a right to collect any unpaid or delinquent accounts. Any returned checks or bank drafts will incur a minimum processing fee of $25 for rebilling. Customer agrees to pay for any and all reasonable costs, attorney fees, and the costs of collection in connection with any delinquent account.
Sample 1

Related to Right of Collection

  • Rights of Collection Exercise on behalf of the Lenders all of its other rights and remedies under this Agreement, the other Loan Documents and Applicable Law, in order to satisfy all of the Borrower's Obligations.

  • Deposit of Collections The Borrower shall promptly (but in no event later than two Business Days after receipt) deposit or cause to be deposited into the Collection Account any and all Available Collections received by the Borrower, the Servicer or any of their Affiliates.

  • Cost of Collection If default is made in the payment of this Note, Borrower shall pay the Holder hereof reasonable costs of collection, including reasonable attorneys' fees.

  • Costs of Collection In the event that after an Event of Default: (i) the Note or any of the Loan Documents is placed in the hands of an attorney for collection or enforcement or is collected or enforced through any legal proceeding; (ii) an attorney is retained to represent Lender in any bankruptcy, reorganization, receivership, or other proceedings affecting creditors’ rights and involving a claim under the Note or any of the Loan Documents; or (iii) an attorney is retained to protect or enforce the lien or any of the terms of this Agreement, the Security Instrument or any of the Loan Documents; then Borrower shall pay to Lender all reasonable attorney’s fees, costs and expenses actually incurred in connection therewith, including costs of appeal, together with interest on any judgment obtained by Lender at the Default Rate.

  • Application of Collections On each Payment Date, all collections for the related Collection Period shall be applied by the Servicer as follows:

  • Compromises and Collection of Collateral The Grantors and the Administrative Agent recognize that setoffs, counterclaims, defenses and other claims may be asserted by obligors with respect to certain of the Receivables, that certain of the Receivables may be or become uncollectible in whole or in part and that the expense and probability of success in litigating a disputed Receivable may exceed the amount that reasonably may be expected to be recovered with respect to a Receivable. In view of the foregoing, each Grantor agrees that the Administrative Agent may at any time and from time to time, if an Event of Default has occurred and is continuing, compromise with the obligor on any Receivable, accept in full payment of any Receivable such amount as the Administrative Agent in its sole discretion shall determine or abandon any Receivable, and any such action by the Administrative Agent shall be commercially reasonable so long as the Administrative Agent acts in good faith based on information known to it at the time it takes any such action.

  • Application of Payments and Collections All items of payment received by Agent by 12:00 noon, Chicago, Illinois, time, on any Business Day shall be deemed received on that Business Day. All items of payment received after 12:00 noon, Chicago, Illinois, time, on any Business Day shall be deemed received on the following Business Day. Borrower irrevocably waives the right to direct the application of any and all payments and collections at any time or times hereafter received by Agent from or on behalf of Borrower, and Borrower does hereby irrevocably agree that Agent shall have the continuing exclusive right to apply and reapply any and all such payments and collections received at any time or times hereafter by Agent or its agent against the Obligations, in such manner as Agent may deem advisable, notwithstanding any entry by Agent or any Lender upon any of its books and records. Amounts received by the Agent shall be for further credit to the accounts of Lenders pursuant to the settlement procedures contained in subsection 3.1.3 of this Agreement. Notwithstanding the foregoing, payments and collections shall not be applied to Obligations consisting of Derivative Obligations or Product Obligations at any time that any other Obligations are then due and payable. If as the result of collections of Accounts as authorized by subsection 6.2.4 hereof or otherwise, a credit balance exists in the Loan Account, such credit balance shall not accrue interest in favor of Borrower, but shall be disbursed to Borrower or otherwise at Borrower's direction in the manner set forth in subsection 3.1.2, upon Borrower's request at any time, so long as no Default or Event of Default then exists. Agent may at its option, offset such credit balance against any of the Obligations upon and during the continuance of an Event of Default.

  • Guaranty of Payment and Not of Collection This Guaranty is a guaranty of payment, and not of collection, and a debt of each Guarantor for its own account. Accordingly, the Guarantied Parties shall not be obligated or required before enforcing this Guaranty against any Guarantor: (a) to pursue any right or remedy the Guarantied Parties may have against the Borrower, any other Loan Party or any other Person or commence any suit or other proceeding against the Borrower, any other Loan Party or any other Person in any court or other tribunal; (b) to make any claim in a liquidation or bankruptcy of the Borrower, any other Loan Party or any other Person; or (c) to make demand of the Borrower, any other Loan Party or any other Person or to enforce or seek to enforce or realize upon any collateral security held by the Guarantied Parties which may secure any of the Guarantied Obligations.

  • Establishment of Collection Account (a) The Servicer, on behalf of the Issuer and the Indenture Trustee, shall establish the Collection Account in the name of the Indenture Trustee for the benefit of the Securityholders. The Collection Account shall be an Eligible Deposit Account initially established with the Indenture Trustee and maintained with the Indenture Trustee. Except as otherwise provided in this Agreement, in the event that the Collection Account maintained with the Indenture Trustee is no longer an Eligible Deposit Account, then the Servicer shall, with the Indenture Trustee’s assistance, as necessary, use reasonable efforts to cause the Collection Account to be moved to an Eligible Institution within thirty days.

  • Allocations of Finance Charge Collections The Servicer shall allocate to the Series 1997-1 Certificateholders and retain in the Collection Account for application as provided herein an amount equal to the product of (A) the Floating Allocation Percentage and (B) the Series 1997-1 Allocation Percentage and (C) the aggregate amount of Collections of Finance Charge Receivables deposited in the Collection Account on such Deposit Date.

Time is Money Join Law Insider Premium to draft better contracts faster.