CHARACTERISTICS OF THE ACADEMY 10) The characteristics of the Academy set down in Section 1(6) of the Academies Act 2010, are that:
POSSESSION OF THE APARTMENT 7.1 Schedule for possession of the said Apartment - The Promoter agrees and understands that timely delivery of possession of the Apartment to the allottee’s and the common areas to the association of allottee’s or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the Apartment along with ready and complete common areas with all specifications, amenities and facilities of the project in place on (Date) unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee’s agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, provided that such Force Majeure conditions are not of a nature, which make it impossible for the contract to be implemented. The Allottee’s agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee’s the entire amount received by the Promoter from the allotment within 45 days from that date. The promoter shall intimate the allottee’s about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee’s, the Allottee’s agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
Restrictions on Business Activities There is no agreement, commitment, judgment, injunction, order or decree binding upon the Company or to which the Company is a party which has or could reasonably be expected to have the effect of prohibiting or materially impairing any business practice material to the Company, any acquisition of property by the Company or the conduct of business by the Company as currently conducted or as proposed to be conducted.
Sleeping Rooms to be Blocked A. The Contractor shall block sleeping rooms as set forth in Table 1, below. Table 1: Dates Single Occupancy Total by Date Date1 60 60 Date4 60 60 Date 5 Check Out Check Out Total Rooms to be Blocked: 240 240
MAINTENANCE OF THE SAID BUILDING / APARTMENT / PROJECT The Promoter shall be responsible to provide and maintain essential services in the Project till the taking over of the maintenance of the project by the association of the allottees. The cost of such maintenance has been included in the Total Price of the [Apartment/Plot]. [Insert any other clauses in relation to maintenance of project, infrastructure and equipment]
Amounts and Terms of the Advances and Letters of Credit SECTION 2.01. The Advances and Letters of Credit. (a)
Overriding powers of the Authority 17.10.1 If in the reasonable opinion of the Authority, the Concessionaire is in material breach of its obligations under this Agreement and, in particular, the Maintenance Requirements, and such breach is causing or likely to cause material hardship or danger to the Users, the Authority may, without prejudice to any of its rights under this Agreement including Termination thereof, by notice require the Concessionaire to take reasonable measures immediately for rectifying or removing such hardship or danger, as the case may be.
AMOUNTS AND TERMS OF THE ADVANCES SECTION 2.01 The Revolving Advances and Letters of Credit 19 SECTION 2.02 Making the Revolving Advances 20 SECTION 2.03 Swingline Loans 21 SECTION 2.04 Issuance of and Drawings and Reimbursement Under Letters of Credit 22 SECTION 2.05 The CAF Advances 23 SECTION 2.06 Competitive Bid Procedure 23 SECTION 2.07 Fees 26 SECTION 2.08 Termination or Reduction of the Revolving Commitments 26 SECTION 2.09 Repayment 27 SECTION 2.10 Interest 27 SECTION 2.11 Interest Rate Determination 28 SECTION 2.12 Optional Conversion of Revolving Advances 29 SECTION 2.13 Optional Prepayments of Revolving Advances 29 SECTION 2.14 Increased Costs 29 SECTION 2.15 Illegality 30 SECTION 2.16 Payments and Computations 30 SECTION 2.17 Taxes 31 SECTION 2.18 Sharing of Payments, Etc. 33 SECTION 2.19 Use of Proceeds 33 SECTION 2.20 Extension Option 33 SECTION 2.21 Increase in the Aggregate Revolving Commitments 34 SECTION 2.22 Evidence of Debt 35 ARTICLE III CONDITIONS TO EFFECTIVENESS AND LENDING SECTION 3.01 Conditions Precedent to Effectiveness of Sections 2.01 and 2.05 35 SECTION 3.02 Conditions Precedent to Each Revolving Borrowing, Issuance and Commitment Increase 36 SECTION 3.03 Conditions Precedent to Each CAF Borrowing 37 SECTION 3.04 Determinations Under Section 3.01 37 ARTICLE IV
Certain Rights of the Administrative Agent If the Administrative Agent shall request instructions from the Required Lenders with respect to any action or actions (including the failure to act) in connection with this Agreement, the Administrative Agent shall be entitled to refrain from such act or taking such act, unless and until it shall have received instructions from such Lenders; and the Administrative Agent shall not incur liability to any Person by reason of so refraining. Without limiting the foregoing, no Lender shall have any right of action whatsoever against the Administrative Agent as a result of the Administrative Agent acting or refraining from acting hereunder in accordance with the instructions of the Required Lenders where required by the terms of this Agreement.
