Common use of RCW Clause in Contracts

RCW. The Principal, and (Surety), a corporation organized under the laws of the State of and licensed to do business in the State of Washington as surety and named in the current list of “Surety Companies Acceptable in Federal Bonds” as published in the Federal Register by the Audit Staff Bureau of Accounts, U.S. Treasury Dept., are jointly and severally held and firmly bound to the City, in the sum of US Dollars ($ ) Total Contract Amount, subject to the provisions herein. This statutory payment bond shall become null and void, if and when the Principal, its heirs, executors, administrators, successors, or assigns shall pay all persons in accordance with RCW Titles 39.08 and 39.12 including all workers, laborers, mechanics, subcontractors, and material suppliers, and all persons who shall supply such contractor or subcontractor with provisions and supplies for the carrying on of such work; and if such payment obligations have not been fulfilled, this bond shall remain in full force and effect. The Surety for value received agrees that no change, extension of time, alteration or addition to the terms of the Contract, the specifications accompanying the Contract, or to the work to be performed under the Contract shall in any way affect its obligation on this bond, except as provided herein, and waives notice of any change, extension of time, alteration or addition to the terms of the Contract or the work performed. The Surety agrees that modifications and changes to the terms and conditions of the Contract that increase the total amount to be paid the Principal shall automatically increase the obligation of the Surety on this bond and notice to Surety is not required for such increased obligation. This bond may be executed in two (2) original counterparts, and shall be signed by the parties’ duly authorized officers. This bond will only be accepted if it is accompanied by a fully executed and original power of attorney for the officer executing on behalf of the surety. PRINCIPAL SURETY Principal Signature Date Surety Signature Date Printed Name Printed Name Title Title Name, address, and telephone of local office/agent of Surety Company is: Approved as to form: Signature Title Date The City of Sedro-Woolley, Washington, (City) has awarded to (Principal), a contract for the construction of the project designated as Project No. , in Sedro-▇▇▇▇▇▇▇, Washington (Contract), and said Principal is required to furnish a bond for performance of all obligations under the Contract. The Principal, and (Surety), a corporation organized under the laws of the State of and licensed to do business in the State of Washington as surety and named in the current list of “Surety Companies Acceptable in Federal Bonds” as published in the Federal Register by the Audit Staff Bureau of Accounts, U.S. Treasury Dept., are jointly and severally held and firmly bound to the City, in the sum of

RCW. The Principal, and (Surety), a corporation organized under the laws of the State of and licensed to do business in the State of Washington as surety and named in the current list of “Surety Companies Acceptable in Federal Bonds” as published in the Federal Register by the Audit Staff Bureau of Accounts, U.S. Treasury Dept., are jointly and severally held and firmly bound to the City, in the sum of US Dollars ($ ) Total Contract Amount, subject to the provisions herein. This statutory payment bond shall become null and void, if and when the Principal, its heirs, executors, administrators, successors, or assigns shall pay all persons in accordance with RCW Titles 39.08 39.08, 39.12, and 39.12 60.28 including all workers, laborers, mechanics, subcontractors, and material suppliersmaterialmen, and all persons person who shall supply such contractor or subcontractor with provisions and supplies for the carrying on of such work, and all taxes incurred on said Contract under Titles 50 and 51 RCW and all taxes imposed on the Principal under Title 82 RCW; and if such payment obligations have not been fulfilled, this bond shall remain in full force and effect. The Surety for value received agrees that no change, extension of time, alteration or addition to the terms of the Contract, the specifications accompanying the Contract, or to the work to be performed under the Contract shall in any way affect its obligation on this bond, except as provided herein, and waives notice of any changechanges, extension of time, alteration or addition to the terms of the Contract or the work performed. The Surety agrees that modifications and changes to the terms and conditions of the Contract that increase the total amount to be paid the Principal shall automatically increase the obligation of the Surety on this bond and notice to Surety is not required for such increased obligation. This bond may be executed in two (2) original counterparts, and shall be signed by the parties’ duly authorized officers. This bond will only be accepted if it is accompanied by a fully executed and original power of attorney for the officer office executing on behalf of the surety. PRINCIPAL SURETY Principal Signature Date Surety Signature Date Printed Name Date Printed Name Date Title Title Name, address, and telephone of local office/agent of Surety Company is: Approved as to form: Signature Contract Title Contract Date The City Contractor Name Contractor Address Contractor Phone Contractor Federal ID # RCW 60.28.010 Retained percentage, labor and material Contracts for public improvements or work other than for professional services, provides that there shall be reserved by the city from the monies earned by the contractor on estimates during the progress of Sedro-Woolley, Washington, (City) has awarded to (Principal)the improvement or work, a contract sum of five percent of such estimates, said sum to be retained by the city as a trust fund for the construction protection and payment of any persons performing work or supplying provisions or supplies during the work. The monies reserved for contract retainage may be reserved by the contractor choosing one of the project designated as Project No. , in Sedro-▇▇▇▇▇▇▇, Washington (Contract), and said Principal is required to furnish a bond for performance of all obligations under the Contract. The Principal, and (Surety), a corporation organized under the laws of the State of and licensed to do business in the State of Washington as surety and named in the current list of “Surety Companies Acceptable in Federal Bonds” as published in the Federal Register by the Audit Staff Bureau of Accounts, U.S. Treasury Dept., are jointly and severally held and firmly bound to the City, in the sum offollowing four options:

RCW. The Principal, and (Surety), a corporation organized condition of this obligation is such that if the Principal shall satisfy all payment obligations to persons who may lawfully claim under the laws of the State of trust fund created pursuant to chapter 60.28 RCW and licensed to do business in the State of Washington as surety and named in the current list of “Surety Companies Acceptable in Federal Bonds” as published in the Federal Register by the Audit Staff Bureau of Accounts, U.S. Treasury Dept., are jointly and severally held and firmly bound to the City, in and indemnify and hold the sum City harmless from any and all loss, costs, and damages that the City may sustain by release of US Dollars ($ ) Total Contract Amountsaid retainage to Principal/Surety, subject to the provisions herein. This statutory payment bond then this obligation shall become be null and void, if void provided the Surety is notified by the City that the requirements under RCW 60.28.021 have been satisfied and when the Principal, its heirs, executors, administrators, successors, or assigns shall pay all persons in accordance with RCW Titles 39.08 and 39.12 including all workers, laborers, mechanics, subcontractors, and material suppliers, and all persons who shall supply such contractor or subcontractor with provisions and supplies for obligation is duly released by the carrying on of such workCity; and if such payment obligations have not been fulfilled, this bond otherwise it shall remain in full force and effect. The IT IS HEREBY DECLARED AND AGREED that the Surety for value received agrees that no change, extension of time, alteration or addition to the terms of the Contract, the specifications accompanying the Contract, or to the work to shall be performed liable under the Contract shall in any way affect its this obligation on this bond, except as provided herein, and waives notice of any change, extension of time, alteration or addition to the terms of the Contract or the work performedPrincipal. The Surety agrees will not be discharged or released from liability for any act, omission, or defense of any kind or nature that modifications would not also discharge the Principal. IT IS FURTHER DECLARED AND AGREED that this obligation shall be binding upon and changes inure to the terms and conditions benefit of the Contract that increase Principal, the total amount to be paid Surety, the Principal shall automatically increase City, the obligation beneficiaries of the Surety on trust fund created by chapter 60.28 RCW and their respective heirs, executors, administrators, successors and assigns. SIGNED AND SEALED this bond and notice to Surety is not required for such increased obligationday of , 20 . This bond may be executed in two (2) original counterparts, and shall be signed by the parties’ duly authorized officers. This bond will only be accepted if it is accompanied by a fully executed and original power of attorney for the officer executing on behalf of the surety. PRINCIPAL SURETY Principal Signature Date Surety Signature Date Printed Name Printed Name Title Title By: By: Name, address, and telephone of local office/agent of Surety Company isTitle: Approved as to formName/Title: Signature Title Date The Address: Address: City/State/Zip: City/State/Zip: Telephone No.: Telephone No.: Witness: Witness: City of Sedro-WoolleyMukilteo By: Its: Date: Intent to Pay Prevailing Wage (Contractor generates) Department of Labor/Industries Employment Standards Division General Administration Building Olympia, Washington, Washington 98504 (City) has awarded to (Principal), a contract for the construction of the project designated as Project No. , in Sedro-▇▇▇) ▇▇▇-▇, Washington (Contract), ▇▇▇ All contractors and said Principal sub-contractors are required to file the Intent form. State approval of the Notice of Intents is required to furnish a bond for performance of all obligations under the Contract. The Principal, and (Surety), a corporation organized under the laws of the State of and licensed to do business in the State of Washington as surety and named in the current list of “Surety Companies Acceptable in Federal Bonds” as published in the Federal Register by the Audit Staff Bureau of Accounts, U.S. Treasury Dept., are jointly and severally held and firmly bound prior to the City, in the sum ofrelease of any payments. RCW 39.12 and WAC 296-127 THESE DOCUMENTS ARE REQUIRED TO BE ON FILE WITH THE CITY PRIOR TO RELEASE OF RETAINAGE:

RCW. The Principal, and (Surety), a corporation corporation, organized under the laws of the State of and licensed to do business in the State of Washington as surety and named in the current list of “Surety Companies Acceptable in Federal Bonds” as published in the Federal Register by the Audit Staff Bureau of Accounts, U.S. Treasury Dept., are jointly and severally held and firmly bound to the City, City of Port Angeles in the sum of US Dollars Dolla rs ($ ) Total Contract Amount, subject to the provisions herein. This statutory payment bond shall become null and void, if and when the PrincipalPrincipa l, its heirs, executors, administrators, successors, or assigns shall a ssigns sha ll pay all persons in accordance with RCW Titles 39.08 60.28, 39.08, and 39.12 RCW including all workers, laborers, mechanics, subcontractors, and material suppliersmaterialmen, and all persons who shall supply such contractor or subcontractor with provisions and supplies for the carrying on of such work, and all taxes incurred on said Contract under Title 50 and 51 RCW and all taxes imposed on the Principal under Title 82 RCW; and if such payment obligations have not been fulfilled, this bond shall remain in full force and effect. The Surety for value received agrees that no change, extension of time, alteration or addition to the terms of the Contract, the specifications accompanying the Contract, or to the work to be performed under the Contract shall in any way affect its obligation on this bond, except as provided herein, and waives notice of any change, extension of time, alteration or addition to the terms of the Contract or the work performed. The Surety agrees that modifications and changes to the terms and conditions of the Contract that increase the total amount to be paid the Principal shall automatically increase the obligation of the Surety on this bond and notice to Surety is not required for such increased obligation. This bond may be executed in two (2) original counterparts, and shall be signed by the parties’ ' duly authorized officers. This bond will only be accepted if it is accompanied by a fully executed and original power of attorney for the officer executing on behalf of the surety. PRINCIPAL SURETY ____ _ ____ Principal Signature Date Surety Signature Date ____ _ ____ Printed Name Printed Name ____ _ ____ Title Title Name, address, and telephone of local office/agent of Surety Company is: Approved as to form: Signature Title Date The ____ ____ ____ City of Sedro-Woolley, Washington, (City) has awarded to (Principal), a contract for the construction Port Angeles Engineering Office Public Works and Utilities Department PROJECT NAME: PROJECT/CONTRACT NUMBER: ORIGINATOR: □ City □ Contractor ITEM: REFERENCE DRAWING OR SPECIFICATION: DESCRIPTION OF CLARIFICATION/REQUEST: DATE REPLY REQUESTED: CRITICAL TO SCHEDULE: □ YES □ NO ORIGINATOR SIGNATURE: DATE: COMMENTS: City of the project designated as Project No. , in Sedro-Port Angeles Public Works Department ▇▇▇ ▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇ / ▇▇▇▇ ▇▇▇▇▇▇▇, Washington ▇▇ ▇▇▇▇▇ Origina l Contract Origina l Substantial Completion Previous Change Orders Previous Time Extensionby Change Order (Contractda ys)* This Change Order Amount (including applicable taxes) Suspension of Work (days) New Contract Amount Change Order #1 Time Extension (days) New Substantial Completion CONTRACTOR: CITY OF PORT ANGELES Signature Signature Name & Title Name & Title Date: Date: This Change Proposal shall represent full and complete compensation and final settlement of all Claims for all (1) time; (2) direct, indirect, and said Principal is required to furnish a bond for performance of all obligations under the Contract. The Principal, overhead costs; (3) profit; and (Surety)4) costs or damages associated with delay, a corporation organized under the laws inconvenience, disruption of the State schedule, impact, ripple effect, loss of and licensed efficiency or productivity, acceleration of work, lost profits, and/or any other costs or damages related to do business in the State of Washington as surety and named in the current list of “Surety Companies Acceptable in Federal Bonds” as published in the Federal Register any work either covered or affected by the Audit Staff Bureau of AccountsChange Proposal, U.S. Treasury Dept., are jointly and severally held and firmly bound or related to the Cityevents giving rise to the Change Proposal. TO: City of Port Angeles Public Works & Utilities Department ▇▇▇ ▇ ▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇, in the sum of▇▇ ▇▇▇▇▇ DATE: PERIOD From: to [end of period]:

RCW. The Principal, and (Surety), a corporation organized under the laws of the State of of_________ _ and licensed to do business in the State of Washington as surety and named in the current list of “Surety Companies Acceptable in Federal Bonds” as published in the Federal Register by the Audit Staff Bureau of Accounts, U.S. Treasury Dept., are jointly and severally held and firmly bound to the City, in the sum of of_______ _ _ __ _ _ _ _ _ _ _ _ _ __ _ _ _ _________US Dollars ($ $_______________ ) Total Contract Amount, subject to the provisions herein. This statutory payment bond shall become null and void, if and when the Principal, its heirs, executors, administrators, successors, or assigns shall pay all persons in accordance with RCW Titles 39.08 39.08, 39.12, and 39.12 60.28 including all workers, laborers, mechanics, subcontractors, and material suppliersmaterialmen, and all persons person who shall supply such contractor or subcontractor with provisions and supplies for the carrying on of such work, and all taxes incurred on said Contract under Titles 50 and 51 RCW and all taxes imposed on the Principal under Title 82 RCW; and if such payment obligations have not been fulfilled, this bond shall remain in full force and effect. The Surety for value received agrees that no change, extension of extensionof time, alteration or addition to the terms of the Contract, the specifications accompanying the Contract, or to the work to be performed under the Contract shall in any way affect its obligation on this bond, except as provided herein, and waives notice of any changechanges, extension of time, alteration or addition to the terms of the Contract or the work performed. The Surety agrees that modifications and changes to the terms and conditions of the Contract that increase the total amount to be paid the Principal shall automatically increase the obligation of the Surety on this bond and notice to Surety is not required for such increased obligation. This bond may be executed in two (2) original counterparts, and shall be signed by the parties’ duly authorized officers. This bond will only be accepted if it is accompanied by a fully executed and original power of attorney for the officer office executing on behalf of the surety. PRINCIPAL SURETY Principal Signature Date Surety Signature Date Printed Name Date Printed Name Date Title Title Name, address, and telephone of local office/agent of Surety Company is: Approved as to form: Signature Contract Title Contract Date The City Contractor Name Contractor Address Contractor Phone Contractor Federal ID # RCW 60.28.010 Retained percentage, labor and material Contracts for public improvements or work other than for professional services, provides that there shall be reserved by the city f rom the monies earned by the contractor on estimates during the progress of Sedro-Woolley, Washington, (City) has awarded to (Principal)the improvement or work, a contract sum of f ive p ercent of such estimates, said sum to be retained by the city as a trust fund for the construction protection and payment of any persons performing work or supplying provisions or supplies during the work. The monies reserved for contract retainage may be reserved by the contractor choosing one of the project designated as Project No. , in Sedro-▇▇▇▇▇▇▇, Washington (Contract), and said Principal is required to furnish a bond for performance of all obligations under the Contract. The Principal, and (Surety), a corporation organized under the laws of the State of and licensed to do business in the State of Washington as surety and named in the current list of “Surety Companies Acceptable in Federal Bonds” as published in the Federal Register by the Audit Staff Bureau of Accounts, U.S. Treasury Dept., are jointly and severally held and firmly bound to the City, in the sum offollowing four options:

RCW. The Principal, and (Surety), a corporation organized under the laws of the State of and licensed to do business in the State of Washington as surety and named in the current list of “Surety Companies Acceptable in Federal Bonds” as published in the Federal Register by the Audit Staff Bureau of Accounts, U.S. Treasury Dept., are jointly and severally held and firmly bound to the City, in the sum of US Dollars ($ ) Total Contract Amount, subject to the provisions herein. US Dollars ($ ) Total This statutory payment bond shall become null and void, if and when the Principal, its heirs, executors, administrators, successors, or assigns shall pay all persons in accordance with RCW Titles 39.08 39.08, 39.12, and 39.12 60.28 including all workers, laborers, mechanics, subcontractors, and material suppliersmaterialmen, and all persons person who shall supply such contractor or subcontractor with provisions and supplies for the carrying on of such work, and all taxes incurred on said Contract under Titles 50 and 51 RCW and all taxes imposed on the Principal under Title 82 RCW; and if such payment obligations have not been fulfilled, this bond shall remain in full force and effect. The Surety for value received agrees that no change, extension of time, alteration or addition to the terms of the Contract, the specifications accompanying the Contract, or to the work to be performed under the Contract shall in any way affect its obligation on this bond, except as provided herein, and waives notice of any changechanges, extension of time, alteration or addition to the terms of the Contract or the work performed. The Surety agrees that modifications and changes to the terms and conditions of the Contract that increase the total amount to be paid the Principal shall automatically increase the obligation of the Surety on this bond and notice to Surety is not required for such increased obligation. This bond may be executed in two (2) original counterparts, and shall be signed by the parties’ duly authorized officers. This bond will only be accepted if it is accompanied by a fully executed and original power of attorney for the officer office executing on behalf of the surety. PRINCIPAL SURETY Principal Signature Date Surety Signature Date Printed Name Date Printed Name Date Title Title Name, address, and telephone of local office/agent of Surety Company is: Approved as Words and terms shall be given their ordinary and usual meanings. Where used in the Contract Documents, the following words and terms shall have the meanings indicated. The meanings shall be applicable to form: Signature Title Date The City of Sedro-Woolleythe singular, Washingtonplural, (City) has awarded to (Principal)masculine, a contract for the construction feminine and neuter of the project designated as Project No. , in Sedro-▇▇▇▇▇▇▇, Washington (Contract), words and said Principal is required to furnish a bond for performance of all obligations under the Contract. The Principal, and (Surety), a corporation organized under the laws of the State of and licensed to do business in the State of Washington as surety and named in the current list of “Surety Companies Acceptable in Federal Bonds” as published in the Federal Register by the Audit Staff Bureau of Accounts, U.S. Treasury Deptterms., are jointly and severally held and firmly bound to the City, in the sum of

RCW. Date Signed [ ] 4) I hereby elect to submit a bond for all or any portion of the contract retainage in a form acceptable to the Owner and from an authorized surety insurer. I understand that the Owner my require that the authorized surety insurer have a minimum financial strength rating so long as the minimum rating does not exceed A-. If this option is selected the Owner will provide a Retainage Bond form for the Contractor to complete. Date Signed The City of Mukilteo, Washington (City) has awarded to Excavation West, Inc (Principal), a contract for the construction of the project designated as WWTP – Erosion Repair, Project No. SW220200, in Mukilteo, Washington (Contract), and said Principal is required to furnish a bond for performance of all obligations under the Contract. The Principal, and (Surety), a corporation corporation, organized under the laws of the State of and licensed to do business in the State of Washington as surety and named in the current list of “Surety Companies Acceptable in Federal Bonds” as published in the Federal Register by the Audit Staff Bureau of Accounts, U.S. Treasury Dept., are jointly and severally held and firmly bound to the City, in the sum of US Dollars ($ $280,670.89) Total Contract Amount, subject to the provisions herein. This statutory payment bond NOW, THEREFORE, if the Principal herein shall become null faithfully and truly observe and comply with the terms, conditions, and provisions of said contract in all respects and shall well and truly and fully do and perform all matters and things by them undertaken to be performed under said contract, upon the terms proposed therein, and within the time prescribed therein, and until the same is accepted, and shall in all respects, faithfully perform said contract according to law, and shall further indemnify, save harmless and reimburse the City of Mukilteo from and for any defect or defects in any of the workmanship or materials entering into any part of the work of the contractor performed pursuant to this contract, which shall develop or be discovered within one year after the final acceptance of said contract, then this obligation to be void, if and when the Principal, its heirs, executors, administrators, successors, or assigns shall pay all persons in accordance with RCW Titles 39.08 and 39.12 including all workers, laborers, mechanics, subcontractors, and material suppliers, and all persons who shall supply such contractor or subcontractor with provisions and supplies for the carrying on of such work; and if such payment obligations have not been fulfilled, this bond shall otherwise to remain in full force and effect, provided, the liability hereunder for defects in materials or workmanship for a period of one year after the acceptance of the work shall not exceed the sum of ten percent (10%) of the amount hereinabove set forth as the penal sum of this Bond. The Surety for value received agrees that no change, extension of time, alteration or addition to the terms of the Contract, the specifications accompanying the Contract, or to the work to be performed under the Contract shall in any way affect its obligation on this bond, except as provided herein, and waives notice of any change, extension of time, alteration or addition to the terms of the Contract or the work performed. The Surety agrees that modifications and changes to the terms and conditions of the Contract that increase the total amount to be paid the Principal shall automatically increase the obligation of the Surety on this bond and notice to Surety is not required for such increased obligation. This bond may be executed in two (2) original counterparts, and shall be signed by the parties’ duly authorized officers. This bond will only be accepted if it is accompanied by a fully executed and original power of attorney for the officer office executing on behalf of the surety. PRINCIPAL SURETY Principal Signature Date Surety Signature Date Printed Name Date Printed Name Date Title Title Name, address, and telephone of local office/agent of Surety Company isare: Approved as to form: Signature Title Date The City of Sedro-WoolleyMukilteo, Washington, Washington (City) has awarded to Excavation West, Inc (Principal), a contract for the construction of the project designated as WWTP – Erosion Repair, Project No. SW220200, in Sedro-▇▇▇▇▇▇▇Mukilteo, Washington (Contract), and said Principal is required under the terms of that Contract to furnish a payment bond for performance of all obligations under the Contract. The Principal, and (Surety), a corporation organized under the laws of the State of and licensed to do business in the State of Washington as surety and named in the current list of “Surety Companies Acceptable in Federal Bonds” as published in the Federal Register by the Audit Staff Bureau of Accounts, U.S. Treasury Dept., are jointly and severally held and firmly bound to the City, in the sum ofaccord with Title

RCW. No worker, laborer, or mechanic employed in the performance of any part of this Contract shall be paid less than the prevailing rate of wage as determined by the Industrial Statistician of the Department of Labor and Industries for the State of Washington. In accordance with RCW 35.23.352(13), prevailing wages for all work performed pursuant to each Task Order issued under this Contract must be the prevailing wage rates in effect at the beginning date of each contract year that this Contract remains in effect. Prevailing wage rates shall be updated annually. Prior to making any payment under this Contract, the Contractor shall submit to the City an approved copy of the “Statement of Intent to Pay Prevailing Wages” from the Department of Labor and Industries. It is the Contractor’s responsibility to obtain and file the Statement. The PrincipalContractor shall be responsible for all filing fees. Notice from the Contractor and all subcontractors of intent to pay prevailing wages and prevailing wage rates for the Project must be posted for the benefit of the workers. Each invoice shall include a signed statement that prevailing wages have been paid by the Contractor and all subcontractors. At the beginning of each contract year, the Contractor shall file a new “Statement of Intent to Pay Prevailing Wages” and submit an approved Copy to the City. At the end of each contract year, the Contractor shall file an “Affidavit of Wages Paid” with the Department of Labor and Industries for all work completed within that contract year. The Contractor shall submit an approved Affidavit to the City. In case any dispute arises regarding the prevailing rates of wages for work of a similar nature, and (Surety)such dispute cannot be resolved by the parties of interest, a corporation organized under including labor and management representatives, the laws matter shall be referred for arbitration to the Director of the Department of Labor and Industries of the State of Washington, and licensed to do business his/her decision therein shall be final and conclusive and binding on all parties involved in the State of Washington dispute as surety and named provided for by RCW 39.12.060, as it may be amended in the current list of “Surety Companies Acceptable in Federal Bonds” as published in the Federal Register by the Audit Staff Bureau of Accounts, U.S. Treasury Deptfuture., are jointly and severally held and firmly bound to the City, in the sum of US Dollars ($ ) Total Contract Amount, subject to the provisions herein. This statutory payment bond shall become null and void, if and when the Principal, its heirs, executors, administrators, successors, or assigns shall pay all persons in accordance with RCW Titles 39.08 and 39.12 including all workers, laborers, mechanics, subcontractors, and material suppliers, and all persons who shall supply such contractor or subcontractor with provisions and supplies for the carrying on of such work; and if such payment obligations have not been fulfilled, this bond shall remain in full force and effect. The Surety for value received agrees that no change, extension of time, alteration or addition to the terms of the Contract, the specifications accompanying the Contract, or to the work to be performed under the Contract shall in any way affect its obligation on this bond, except as provided herein, and waives notice of any change, extension of time, alteration or addition to the terms of the Contract or the work performed. The Surety agrees that modifications and changes to the terms and conditions of the Contract that increase the total amount to be paid the Principal shall automatically increase the obligation of the Surety on this bond and notice to Surety is not required for such increased obligation. This bond may be executed in two (2) original counterparts, and shall be signed by the parties’ duly authorized officers. This bond will only be accepted if it is accompanied by a fully executed and original power of attorney for the officer executing on behalf of the surety. PRINCIPAL SURETY Principal Signature Date Surety Signature Date Printed Name Printed Name Title Title Name, address, and telephone of local office/agent of Surety Company is: Approved as to form: Signature Title Date The City of Sedro-Woolley, Washington, (City) has awarded to (Principal), a contract for the construction of the project designated as Project No. , in Sedro-▇▇▇▇▇▇▇, Washington (Contract), and said Principal is required to furnish a bond for performance of all obligations under the Contract. The Principal, and (Surety), a corporation organized under the laws of the State of and licensed to do business in the State of Washington as surety and named in the current list of “Surety Companies Acceptable in Federal Bonds” as published in the Federal Register by the Audit Staff Bureau of Accounts, U.S. Treasury Dept., are jointly and severally held and firmly bound to the City, in the sum of

RCW. The Principal, and _____ _ (Surety), a corporation corporation, organized under the laws of the State of ______ and licensed to do business in the State of Washington as surety and named in the current list of “"Surety Companies Acceptable in Federal Bonds” " as published in the Federal Register by the Audit Staff Bureau of Accounts, U.S. Treasury ▇▇▇▇ ▇▇▇▇ Dept., are a re jointly and severally held and firmly bound to the City, City of Port Angeles in the sum of of_____ _ _ US Dollars ($ $_____ ) Total Contract Amount, subject to the provisions herein. This statutory payment bond shall become null and void, if and when the Principal, its heirs, executors, administrators, successors, or assigns shall pay all persons in accordance with RCW Titles 39.08 60.28, 39.08, and 39.12 RCW including all workers, laborers, mechanics, subcontractors, and material suppliersmaterialmen, and all persons who shall supply such contractor or subcontractor with provisions and supplies for the carrying on of such work, and all taxes incurred on said Contract under Title 50 and 51 RCW and all taxes imposed on the Principal under Title 82 RCW; and if such payment obligations have not been fulfilled, this bond shall remain in full force and effect. The Surety for value received agrees that no change, extension of time, alteration or addition to the terms of the Contract, the specifications accompanying the Contract, or to the work to be performed under the Contract shall in any way affect its obligation on this bond, except as provided herein, and waives notice of any change, extension of time, alteration or addition to the terms of the Contract or the work performed. The Surety agrees that modifications and changes to the terms and conditions of the Contract that increase the total amount to be paid the Principal shall automatically increase the obligation of the Surety on this bond and notice to Surety is not required for such increased obligation. This bond may be executed in two (2) original counterparts, counterparts and shall be signed by the parties’ ' duly authorized officers. This bond will only be accepted if it is accompanied by a fully executed and original power of attorney for the officer executing on behalf of the surety. PRINCIPAL SURETY ____ _ ____ Principal Signature Date Surety Signature Date ____ _ ____ Printed Name Printed Name ____ _ ____ Title Title Name, address, and telephone of local office/agent of Surety Company is: Approved as to form: Signature Title Date The ____ ____ ____ City of Sedro-Woolley, Washington, (City) has awarded to (Principal), a contract for the construction Port Angeles Engineering Office Public Works and Utilities Department PROJECT NAME: PROJECT/CONTRACT NUMBER: ORIGINATOR:  City  Contractor ITEM: REFERENCE DRAWING OR SPECIFICATION: DESCRIPTION OF CLARIFICATION/REQUEST: DATE REPLY REQUESTED: CRITICAL TO SCHEDULE:  YES  NO ORIGINATOR SIGNATURE: DATE: COMMENTS: City of the project designated as Project No. , in Sedro-Port Angeles Public Works Department ▇▇▇ ▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇ / ▇▇▇▇ ▇▇▇▇▇▇▇, Washington ▇▇ ▇▇▇▇▇ Origina l Contract Origina l Substantial Completion Previous Change Orders Previous Time Extension by Change Order (Contractda ys)* This Change Order Amount (including applicable taxes) Suspension of Work (days) New Contract Amount Change Order #1 Time Extension (days) New Substantial Completion CONTRACTOR: CITY OF PORT ANGELES Signature Signature Name & Title Name & Title Date: Date: This Change Proposal shall represent full and complete compensation and final settlement of all Claims for all (1) time; (2) direct, indirect, and said Principal is required to furnish a bond for performance of all obligations under the Contract. The Principal, overhead costs; (3) profit; and (Surety)4) costs or damages associated with delay, a corporation organized under the laws inconvenience, disruption of the State schedule, impact, ripple effect, loss of and licensed efficiency or productivity, acceleration of work, lost profits, and/or any other costs or damages related to do business in the State of Washington as surety and named in the current list of “Surety Companies Acceptable in Federal Bonds” as published in the Federal Register any work either covered or affected by the Audit Staff Bureau of AccountsChange Proposal, U.S. Treasury Dept., are jointly and severally held and firmly bound or related to the Cityevents giving rise to the Change Proposal. TO: City of Port Angeles Public Works & Utilities Department ▇▇▇ ▇ ▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇, in the sum of▇▇ ▇▇▇▇▇ DATE: PERIOD From: to [end of period]:

RCW. The Principal, and (Surety), a corporation corporation, organized under the laws of the State of and licensed to do business in the State of Washington as surety and named in the current list of “Surety Companies Acceptable in Federal Bonds” as published in the Federal Register by the Audit Staff Bureau of Accounts, U.S. Treasury Dept., are jointly and severally held and firmly bound to the City, in the sum of Sixty-Five Thousand Two Hundred Ninety Seven 50/100 US Dollars ($ 65,297.50) Total Contract Amount, subject to the provisions herein. This statutory payment bond shall become null and void, if and when the Principal, its heirs, executors, administrators, successors, or assigns shall pay all persons in accordance with RCW Titles 39.08 39.08, 39.12, and 39.12 60.28 including all workers, laborers, mechanics, subcontractors, and material suppliersmaterialmen, and all persons person who shall supply such contractor or subcontractor with provisions and supplies for the carrying on of such work, and all taxes incurred on said Contract under Titles 50 and 51 RCW and all taxes imposed on the Principal under Title 82 RCW; and if such payment obligations have not been fulfilled, this bond shall remain in full force and effect. The Surety for value received agrees that no change, extension of time, alteration or addition to the terms of the Contract, the specifications accompanying the Contract, or to the work to be performed under the Contract shall in any way affect its obligation on this bond, except as provided herein, and waives notice of any change, extension of time, alteration or addition to the terms of the Contract or the work performed. The Surety agrees that modifications and changes to the terms and conditions of the Contract that increase the total amount to be paid the Principal shall automatically increase the obligation of the Surety on this bond and notice to Surety is not required for such increased obligation. This bond may be executed in two (2) original counterparts, and shall be signed by the parties’ duly authorized officers. This bond will only be accepted if it is accompanied by a fully executed and original power of attorney for the officer office executing on behalf of the surety. PRINCIPAL SURETY Principal Signature Date Surety Signature Date Printed Name Date Printed Name Date Title Title Name, address, and telephone of local office/agent of Surety Company is: Approved as Contract Title: Project No.: Contractor Name: KNOW ALL BY THESE PRESENTS: That the undersigned, , existing under and by virtue of the laws of the State of Washington and authorized to form: Signature Title Date The City do business in the State of Sedro-Woolley, Washington, (City) has awarded to (as “Principal), a contract for the construction of the project designated as Project No. , in Sedro-▇▇▇▇▇▇▇, Washington (Contract)”, and said Principal is required to furnish a bond for performance of all obligations under the Contract. The Principal, organized and (Surety), a corporation organized existing under the laws of the State of and licensed authorized to do transact business in the State of Washington Washington, as surety and named in the current list of “Surety Companies Acceptable in Federal Bonds” as published in the Federal Register by the Audit Staff Bureau of Accounts, U.S. Treasury Dept.Surety”, are jointly and severally held and firmly bound to unto the City of Mukilteo, hereinafter called “City”, and are similarly held and bound unto the beneficiaries of the trust fund created by chapter 60.28 RCW, in the penal sum ofof ($ ), which is 5% of the Principal’s price on the Contract identified above, plus five percent (5%) of any increases in the Contract amount that have occurred or may occur due to change orders, increases in quantities or the addition of any new item of work.

RCW. The Principal, and (Surety), a corporation organized under the laws of the State of and licensed to do business in the State of Washington as surety and named in the current list of “Surety Companies Acceptable in Federal Bonds” as published in the Federal Register by the Audit Staff Bureau of Accounts, U.S. Treasury Dept., are jointly and severally held and firmly bound to the City, in the sum of US Dollars ($ ) Total Contract Amount, subject to the provisions herein. This statutory payment bond shall become null and void, if and when the Principal, its heirs, executors, administrators, successors, or assigns shall pay all persons in accordance with RCW Titles 39.08 39.08, 39.12, and 39.12 60.28 including all workers, laborers, mechanics, subcontractors, and material suppliersmaterialmen, and all persons person who shall supply such contractor or subcontractor with provisions and supplies for the carrying on of such work, and all taxes incurred on said Contract under Titles 50 and 51 RCW and all taxes imposed on the Principal under Title 82 RCW; and if such payment obligations have not been fulfilled, this bond shall remain in full force and effect. The Surety for value received agrees that no change, extension of time, alteration or addition to the terms of the Contract, the specifications accompanying the Contract, or to the work to be performed under the Contract shall in any way affect its obligation on this bond, except as provided herein, and waives notice of any changechanges, extension of time, alteration or addition to the terms of the Contract or the work performed. The Surety agrees that modifications and changes to the terms and conditions of the Contract that increase the total amount to be paid the Principal shall automatically increase the obligation of the Surety on this bond and notice to Surety is not required for such increased obligation. This bond may be executed in two (2) original counterparts, and shall be signed by the parties’ duly authorized officers. This bond will only be accepted if it is accompanied by a fully executed and original power of attorney for the officer office executing on behalf of the surety. PRINCIPAL SURETY Principal Signature Date Surety Signature Date Printed Name Date Printed Name Date Title Title Name, address, and telephone of local office/agent of Surety Company is: Approved as to form: Signature Title Contract Date The City Contractor Name Contractor Address Contractor Phone Contractor Federal ID # RCW 60.28.010 Retained percentage, labor and material Contracts for public improvements or work other than for professional services, provides that there shall be reserved by the city from the monies earned by the contractor on estimates during the progress of Sedro-Woolley, Washington, (City) has awarded to (Principal)the improvement or work, a contract sum of five percent of such estimates, said sum to be retained by the city as a trust fund for the construction protection and payment of any persons performing work or supplying provisions or supplies during the work. The monies reserved for contract retainage may be reserved by the contractor choosing one of the project designated as Project No. , in Sedro-▇▇▇▇▇▇▇, Washington (Contract), and said Principal is required to furnish a bond for performance of all obligations under the Contract. The Principal, and (Surety), a corporation organized under the laws of the State of and licensed to do business in the State of Washington as surety and named in the current list of “Surety Companies Acceptable in Federal Bonds” as published in the Federal Register by the Audit Staff Bureau of Accounts, U.S. Treasury Dept., are jointly and severally held and firmly bound to the City, in the sum offollowing four options:

RCW. The Principal, and (Surety), a corporation corporation, organized under the laws of the State of and licensed to do business in the State of Washington as surety and named in the current list of “Surety Companies Acceptable in Federal Bonds” as published in the Federal Register by the Audit Staff Bureau of Accounts, U.S. Treasury Dept., are jointly and severally held and firmly bound to the City, in the sum of US Dollars ($ $280,670.89) Total Contract Amount, subject to the provisions herein. This statutory payment bond shall become null and void, if and when the Principal, its heirs, executors, administrators, successors, or assigns shall pay all persons in accordance with RCW Titles 39.08 39.08, 39.12, and 39.12 60.28 including all workers, laborers, mechanics, subcontractors, and material suppliersmaterialmen, and all persons person who shall supply such contractor or subcontractor with provisions and supplies for the carrying on of such work, and all taxes incurred on said Contract under Titles 50 and 51 RCW and all taxes imposed on the Principal under Title 82 RCW; and if such payment obligations have not been fulfilled, this bond shall remain in full force and effect. The Surety for value received agrees that no change, extension of time, alteration or addition to the terms of the Contract, the specifications accompanying the Contract, or to the work to be performed under the Contract shall in any way affect its obligation on this bond, except as provided herein, and waives notice of any change, extension of time, alteration or addition to the terms of the Contract or the work performed. The Surety agrees that modifications and changes to the terms and conditions of the Contract that increase the total amount to be paid the Principal shall automatically increase the obligation of the Surety on this bond and notice to Surety is not required for such increased obligation. This bond may be executed in two (2) original counterparts, counterparts and shall be signed by the parties’ duly authorized officers. This bond will only be accepted if it is accompanied by a fully executed and original power of attorney for the officer office executing on behalf of the surety. PRINCIPAL SURETY Principal Signature Date Surety Signature Date Printed Name Date Printed Name Date Title Title Name, address, and telephone of local office/agent of Surety Company is: Approved as Contract Title: Project No.: Contractor Name: KNOW ALL BY THESE PRESENTS: That the undersigned, , existing under and by virtue of the laws of the State of Washington and authorized to form: Signature Title Date The City do business in the State of Sedro-Woolley, Washington, (City) has awarded to (as “Principal), a contract for the construction of the project designated as Project No. , in Sedro-▇▇▇▇▇▇▇, Washington (Contract)”, and said Principal is required to furnish a bond for performance of all obligations under the Contract. The Principal, organized and (Surety), a corporation organized existing under the laws of the State of and licensed authorized to do transact business in the State of Washington Washington, as surety and named in the current list of “Surety Companies Acceptable in Federal Bonds” as published in the Federal Register by the Audit Staff Bureau of Accounts, U.S. Treasury Dept.Surety”, are jointly and severally held and firmly bound to unto the City of Mukilteo, hereinafter called “City”, and are similarly held and bound unto the beneficiaries of the trust fund created by chapter 60.28 RCW, in the penal sum ofof ($ ), which is 5% of the Principal’s price on the Contract identified above, plus five percent (5%) of any increases in the Contract amount that have occurred or may occur due to change orders, increases in quantities or the addition of any new item of work.

RCW. The Principal, and (Surety), a corporation organized under the laws of the State of and licensed to do business in the State of Washington as surety and named in the current list of “Surety Companies Acceptable in Federal Bonds” as published in the Federal Register by the Audit Staff Bureau of Accounts, U.S. Treasury Dept., are jointly and severally held and firmly bound to the City, in the sum of US Dollars ($ ) Total Contract Amount, subject to the provisions herein. This statutory payment bond shall become null and void, if and when the Principal, its heirs, executors, administrators, successors, or assigns shall pay all persons in accordance with RCW Titles 39.08 39.08, 39.12, and 39.12 60.28 including all workers, laborers, mechanics, subcontractors, and material suppliersmaterialmen, and all persons person who shall supply such contractor or subcontractor with provisions and supplies for the carrying on of such work, and all taxes incurred on said Contract under Titles 50 and 51 RCW and all taxes imposed on the Principal under Title 82 RCW; and if such payment obligations have not been fulfilled, this bond shall remain in full force and effect. The Surety for value received agrees that no change, extension of time, alteration or addition to the terms of the Contract, the specifications accompanying the Contract, or to the work to be performed under the Contract shall in any way affect its obligation on this bond, except as provided herein, and waives notice of any changechanges, extension of time, alteration or addition to the terms of the Contract or the work performed. The Surety agrees that modifications and changes to the terms and conditions of the Contract that increase the total amount to be paid the Principal shall automatically increase the obligation of the Surety on this bond and notice to Surety is not required for such increased obligation. This bond may be executed in two (2) original counterparts, and shall be signed by the parties’ duly authorized officers. This bond will only be accepted if it is accompanied by a fully executed and original power of attorney for the officer office executing on behalf of the surety. PRINCIPAL SURETY Principal Signature Date Surety Signature Date Printed Name Date Printed Name Date Title Title Name, address, and telephone of local office/agent of Surety Company is: Approved as to formRETAINAGE AGREEMENT Contract Title Street Related Water and Storm Improvements Contract Date Contractor Name Contractor Address Contractor Phone Contractor Federal ID # State Law on How Contract Retainage Monies can be Reserved: Signature Title Date The City RCW 60.28.010 Retained percentage, labor and material Contracts for public improvements or work other than for professional services, provides that there shall be reserved by the city from the monies earned by the contractor on estimates during the progress of Sedro-Woolley, Washington, (City) has awarded to (Principal)the improvement or work, a contract sum of five percent of such estimates, said sum to be retained by the city as a trust fund for the construction protection and payment of any persons performing work or supplying provisions or supplies during the work. The monies reserved for contract retainage may be reserved by the contractor choosing one of the project designated as Project Nofollowing four options: All investments selected below are subject to City approval. , Contractor Options (Contractor shall place an “x” in Sedro-▇▇▇▇▇▇▇, Washington (Contract), and said Principal is required to furnish a bond for performance of all obligations under the Contract. The Principal, and (Surety), a corporation organized under the laws one of the State of and licensed to do business in the State of Washington as surety and named in the current list of “Surety Companies Acceptable in Federal Bonds” as published in the Federal Register by the Audit Staff Bureau of Accounts, U.S. Treasury Deptboxes below., are jointly and severally held and firmly bound to the City, in the sum of)