INDEMNIFICATION RELATING TO THIRD PARTY RIGHTS The Contractor will also indemnify and hold the Authorized Users harmless from and against any and all damages, expenses (including reasonable attorneys' fees), claims, judgments, liabilities and costs that may be finally assessed against the Authorized Users in any action for infringement of a United States Letter Patent, or of any copyright, trademark, trade secret or other third party proprietary right except to the extent such claims arise from the Authorized Users gross negligence or willful misconduct, provided that the State shall give Contractor: (i) prompt written notice of any action, claim or threat of infringement suit, or other suit, (ii) the opportunity to take over, settle or defend such action, claim or suit at Contractor's sole expense, and (iii) assistance in the defense of any such action at the expense of Contractor. If usage shall be enjoined for any reason or if Contractor believes that it may be enjoined, Contractor shall have the right, at its own expense and sole discretion to take action in the following order of precedence: (i) to procure for the Authorized User the right to continue Usage (ii) to modify the service or Product so that Usage becomes non-infringing, and is of at least equal quality and performance; or (iii) to replace said service or Product or part(s) thereof, as applicable, with non-infringing service or Product of at least equal quality and performance. If the above remedies are not available, the parties shall terminate the Contract, in whole or in part as necessary and applicable, provided the Authorized User is given a refund for any amounts paid for the period during which Usage was not feasible. The foregoing provisions as to protection from third party rights shall not apply to any infringement occasioned by modification by the Authorized User of any Product without Contractor’s approval. In the event that an action at law or in equity is commenced against the Authorized User arising out of a claim that the Authorized User's use of the service or Product under the Contract infringes any patent, copyright or proprietary right, and Contractor is of the opinion that the allegations in such action in whole or in part are not covered by the indemnification and defense provisions set forth in the Contract, Contractor shall immediately notify the Authorized User and the Office of the Attorney General in writing and shall specify to what extent Contractor believes it is obligated to defend and indemnify under the terms and conditions of the Contract. Contractor shall in such event protect the interests of the Authorized User and secure a continuance to permit the Authorized User to appear and defend its interests in cooperation with Contractor, as is appropriate, including any jurisdictional defenses the Authorized User may have. This constitutes the Authorized User’s sole and exclusive remedy for patent infringement, or for infringement of any other third party proprietary right.
YOUR BILLING RIGHTS - KEEP THIS NOTICE FOR FUTURE USE This notice tells you about your rights and our responsibilities under the Fair Credit Billing Act.
Indemnification Procedure for Third Party Claims (a) In the event that any party (the “Indemnified Person”) desires to make a claim against any other party (the “Indemnifying Person”) in connection with any Losses for which the Indemnified Person may seek indemnification hereunder in respect of a claim or demand made by any Person not a party to this Agreement against the Indemnified Person (a “Third-Party Claim”), such Indemnified Person must notify the Indemnifying Person in writing, of the Third-Party Claim (a “Third-Party Claim Notice”) as promptly as reasonably possible after receipt, but in no event later than fifteen (15) calendar days after receipt, by such Indemnified Person of notice of the Third-Party Claim; provided, that failure to give a Third-Party Claim Notice on a timely basis shall not affect the indemnification provided hereunder except to the extent the Indemnifying Person shall have been actually and materially prejudiced as a result of such failure. Upon receipt of the Third-Party Claim Notice from the Indemnified Person, the Indemnifying Person shall be entitled, at the Indemnifying Person’s election, to assume or participate in the defense of any Third-Party Claim at the cost of Indemnifying Person. In any case in which the Indemnifying Person assumes the defense of the Third-Party Claim, the Indemnifying Person shall give the Indemnified Person ten (10) calendar days’ notice prior to executing any settlement agreement and the Indemnified Person shall have the right to approve or reject the settlement and related expenses; provided, however, that upon rejection of any settlement and related expenses, the Indemnified Person shall assume control of the defense of such Third-Party Claim and the liability of the Indemnifying Person with respect to such Third-Party Claim shall be limited to the amount or the monetary equivalent of the rejected settlement and related expenses.
Procedure for Third Party Claims Any person that intends to claim indemnification under this Article 13 (an "Indemnitee") arising out of a Third Party claim shall promptly notify the indemnifying party (the "Indemnitor") of such claim in respect of which the Indemnitee intends to claim such indemnifi- cation, and the Indemnitor shall, to the extent applicable, assume the defense thereof with counsel mutually satisfactory to the parties; provided, however, that an Indemnitee shall have the right to retain its own counsel, with the reasonable fees and expenses thereof to be paid by the Indemnitor, if representation of such Indemnitee by the counsel retained by the Indemnitor would be inappropriate due to actual or potential differing interests between such Indemnitee and any other party represented by such counsel in such proceedings. The parties' indemnity obligations under this Article 13 shall not apply to amounts paid in settlement of any loss, claim, liability or action if such settlement is effected without the consent of the Indemnitor, which consent shall not be withheld unreasonably. Any Indemnitee's failure to deliver notice to the Indemnitor within a reasonable time after the commencement of any such action, if materially prejudicial to the Indemnitor's ability to defend such action, shall relieve the Indemnitor of any liability to the Indemnitee under this Article 13, but not any liability that it may have to the Indemnitee otherwise than under this Article 13. The Indemnitee and its employees and agents shall cooperate fully with the Indemnitor and its legal representatives in the investigation and defense of any action, claim or liability covered by this indemnification.
Indemnification Procedures for Non-Third Party Claims In the event any Indemnified Party should have an indemnification claim against the Shareholder under this Agreement that does not involve a claim by a third party, the Indemnified Party shall promptly deliver notice of such claim to the Shareholder in writing and in reasonable detail. The failure by any Indemnified Party to so notify the Shareholder shall not relieve the Shareholder from any liability that it may have to such Indemnified Party, except to the extent that the Shareholder has been actually prejudiced by such failure. If the Shareholder does not notify the Indemnified Party within fifteen (15) Business Days following its receipt of such notice that the Shareholder disputes such claim, such claim specified by the Shareholder in such notice shall be conclusively deemed a liability of the Shareholder under this Article VII and the Shareholder shall pay the amount of such liability to the Indemnified Party on demand, or in the case of any notice in which the amount of the claim is estimated, on such later date when the amount of such claim is finally determined. If the Shareholder disputes its liability with respect to such claim in a timely manner, Shareholder and the Indemnified Party shall proceed in good faith to negotiate a resolution of such dispute and, if not resolved through negotiations, such dispute shall be submitted to arbitration pursuant to Section 9.9.
Procedures for Third Party Claims In the case of any claim for indemnification arising from a claim of a third-party other than an Infringement Claim subject to Section 13.3 above (a “Third-Party Claim”), a party seeking indemnification hereunder (each an “Indemnified Party”) shall give prompt written notice, following such Indemnified Party’s receipt of such claim or demand, to the party from which indemnity is sought (each an “Indemnifying Party”) of any claim or demand of which such Indemnified Party has knowledge and as to which it may request indemnification hereunder; provided, however, that failure to give such notice will not affect such Indemnified Party’s rights hereunder unless, and then solely to the extent that, the rights of the Indemnifying Parties from whom indemnity is sought are prejudiced as a result of such failure. The Indemnifying Party shall have the right (and if it elects to exercise such right, shall do so within twenty (20) days after receiving such notice from the Indemnified Party) to defend and to direct the defense against any such claim or demand, in its name or in the name of the Indemnified Party, as the case may be, at the expense of the Indemnifying Party, and with counsel selected by the Indemnifying Party; provided, that the Indemnifying Party shall be entitled to assume control of the defense of such action only if the Indemnifying Party acknowledges in writing its indemnity obligations and assumes and holds the Indemnified Party harmless from and against all Losses resulting from such Third-Party Claim; and provided further that the Indemnifying Party shall not be entitled to assume control of such defense if (i) the Indemnifying Party shall not have notified the Indemnified Party of its exercise of its right to defend such Third-Party claim within such twenty (20) day period; (ii) such claim or demand seeks an injunction or other equitable relief against the Indemnified Party, (iii) the Indemnified Party shall have reasonably concluded that (x) there is a conflict of interest between the Indemnified Party and the Indemnifying Party in the conduct of the defense of such claim or demand or (y) the Indemnified Party has one or more defenses not available to the Indemnifying Party, (iv) such claim relates to or arises in connection with any criminal proceeding, action, indictment, allegation or investigation, or (v) the appropriate court rules that the Indemnifying Party failed or is failing to vigorously prosecute or defend such Third-Party Claim. Notwithstanding anything in this Agreement to the contrary, the Indemnified Party shall, at the expense of the Indemnifying Party, cooperate with the Indemnifying Party, and keep the Indemnifying Party fully informed, in the defense of such claim or demand. The Indemnified Party shall have the right to participate in the defense of any claim or demand with counsel employed at its own expense; provided, however, that, in the case of any claim or demand described in clause (i) or (ii) of the second preceding sentence or as to which the Indemnifying Party shall not in fact have employed counsel to assume the defense of such claim or demand, the reasonable fees and disbursements of such counsel shall be at the expense of the Indemnifying Party. The Indemnifying Party shall have no indemnification obligations with respect to any such claim or demand which shall be settled by the Indemnified Party without the prior written consent of the Indemnifying Party, which consent shall not be unreasonably withheld, delayed or conditioned. The Indemnifying Party shall not settle any such claim without the prior written consent of the Indemnified Party (which consent shall not be unreasonably withheld, delayed or conditioned if such settlement is accompanied by a document releasing the Indemnified Party from all liability with respect to the matter in controversy that is binding, valid and enforceable against all applicable Parties). Notwithstanding the foregoing, if the Indemnified Party fails to object to the settlement within five (5) Business Days of receipt of a written notice from the Indemnifying Party containing the terms and condition of such settlement, the Indemnified Party shall be deemed to have consented to the settlement.
PROCEDURE FOR NOTIFICATION AND APPLICATION FOR INDEMNIFICATION (a) Indemnitee agrees to notify promptly the Company in writing upon being served with any summons, citation, subpoena, complaint, indictment, information or other document relating to any Proceeding, claim, issue or matter therein which may be subject to indemnification, hold harmless or exoneration rights, or advancement of Expenses covered hereunder. The failure of Indemnitee to so notify the Company shall not relieve the Company of any obligation which it may have to Indemnitee under this Agreement, or otherwise.
Subcontracting for Medicaid Services Notwithstanding any permitted subcontracting of services to be performed under this Agreement, Party shall remain responsible for ensuring that this Agreement is fully performed according to its terms, that subcontractor remains in compliance with the terms hereof, and that subcontractor complies with all state and federal laws and regulations relating to the Medicaid program in Vermont. Subcontracts, and any service provider agreements entered into by Party in connection with the performance of this Agreement, must clearly specify in writing the responsibilities of the subcontractor or other service provider and Party must retain the authority to revoke its subcontract or service provider agreement or to impose other sanctions if the performance of the subcontractor or service provider is inadequate or if its performance deviates from any requirement of this Agreement. Party shall make available on request all contracts, subcontracts and service provider agreements between the Party, subcontractors and other service providers to the Agency of Human Services and any of its departments as well as to the Center for Medicare and Medicaid Services.
Indemnification Procedures for Third Party Claims If a claim by a third party (including claims for breaches of fiduciary duties) is made against an Indemnified Party and such Indemnified Party intends to seek indemnity with respect thereto from the Company (in the case of a Purchaser Indemnified Party seeking such indemnity) or the Purchaser (in the case of a Company Indemnified Party seeking indemnity) (each of the Company or the Purchaser, as the case may be, in such capacity, an “Indemnifying Party”), such Indemnified Party shall give notice in writing as promptly as reasonably practicable to such Indemnifying Party of any Proceeding commenced against or by it in respect of which indemnity may be sought hereunder, but failure to so notify such Indemnifying Party shall not relieve such Indemnifying Party from any liability that it may have on account of this Article VI, so long as such failure shall not have materially prejudiced the position of such Indemnifying Party. Upon such notification, the Indemnifying Party shall assume the defense of such Proceeding brought by a third party, and, after such assumption, the Indemnified Party shall not be entitled to reimbursement of any expenses thereafter incurred by it in connection with such Proceeding, except as described below. In any such Proceeding, any Indemnified Party shall have the right to retain its own counsel (including local counsel), but the fees and expenses of such counsel shall be at the expense of such Indemnified Party unless (i) the Indemnifying Party shall have failed to promptly assume and thereafter conduct such defense, (ii) the Indemnifying Party and the Indemnified Party shall have mutually agreed to the contrary, (iii) in the reasonable determination of counsel for the Indemnified Party, representation of such Indemnified Party by counsel obtained by the Indemnifying Party would be inappropriate due to actual or potential conflicting interests between such Indemnified Party and any other party represented by such counsel in such proceeding. No Indemnifying Party, in the defense of a third-party claim, shall, except with the consent of the Indemnified Party, consent to entry of any judgment or enter into any settlement that does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Indemnified Party of a release from all liability in respect of such claim. The Indemnifying Party shall not be liable for any settlement of any Proceeding effected without its written consent (which shall not be unreasonably withheld, delayed or conditioned by such Indemnifying Party), but if settled with such consent or if there be final judgment for the plaintiff, the Indemnifying Party shall indemnify the Indemnified Party from and against any Loss by reason of such settlement or judgment. The Indemnifying Party will advance expenses to an Indemnified Party as reasonably incurred so long as such indemnified party shall have provided the indemnifying party with a written undertaking to reimburse the indemnifying party for all amounts so advanced if it is ultimately determined that the indemnified party is not entitled to indemnification hereunder (which shall include breaches of fiduciary duty if permitted above).
Third Party Claim Procedures (a) The Indemnified Party seeking indemnification under Section 7.02 agrees to give reasonably prompt notice in writing to Indemnifying Party of the assertion of any claim or the commencement of any suit, action or proceeding by any third party (“Third Party Claim”) in respect of which indemnity may be sought under Section 7.02. Such notice shall set forth in reasonable detail such Third Party Claim and the basis for indemnification (taking into account the information then available to the Indemnified Party). The failure to so notify the Indemnifying Party shall not relieve the Indemnifying Party of its obligations hereunder, except to the extent such failure shall have actually materially and adversely prejudiced the Indemnifying Party.
