Contract Renegotiation, Suspension, or Termination Due to Change in Funding If the funds DSHS relied upon to establish this Contract or Program Agreement are withdrawn, reduced or limited, or if additional or modified conditions are placed on such funding, after the effective date of this contract but prior to the normal completion of this Contract or Program Agreement:
Delay Claim Must Be In Writing Any claim to extend the Contract Time and Material Completion and Occupancy Date must be in writing, must set forth in detail the basis for the claim and the number of days of delay claimed, must be correlated with the approved Overall Project Schedule, must be executed by the Contractor and delivered to the Design Professional and the Owner, and must be reviewed and an appropriate time assessed by the Design Professional.
PRICING OF After Hours Coefficient What is your after hours coefficient for the RS Means Price Book for work performed after normal working hours? Remember that this is a ceiling price proposed. You can discount to any TIPS Member customer a lower coefficient than your proposed contract coefficient, but not higher. This is one of three pricing questions that are required for consideration for award on this solicitation. Please consider your answer carefully. An explanation of the TIPS scoring of pricing titled "Pricing Coefficient Instruction" is included in the attachments for your information. The below is an EXAMPLE of how the pricing model works (It is not intended to influence your proposed coefficient, you should propose a coefficient that you determine is reasonable for your business for the life of the contract): The most common after hours coefficient is time and a half of the RS Means Unit Price Book prices. To illustrate this coefficient, if your regular hours coefficient is .95, your after hours coefficient would be 1.45.
JOC - PRICING OF After Hours Coefficient What is your after hours coefficient for the RS Means Price Book for work performed after normal working hours? (FAILURE TO RESPOND PROHIBITS PART 2 JOC EVALUATION) Remember that this is a ceiling price proposed. You can discount to any TIPS Member customer a lower coefficient than your proposed contract coefficient, but not higher. This is one of three pricing questions that are required for consideration for award on this solicitation. Please consider your answer carefully. An explanation of the TIPS scoring of pricing titled "Pricing Coefficient Instruction" is included in the attachments for your information. The below is an EXAMPLE of how the pricing model works (It is not intended to influence your proposed coefficient, you should propose a coefficient that you determine is reasonable for your business for the life of the contract): The most common after hours coefficient is time and a half of the RS Means Unit Price Book prices. To illustrate this coefficient, if your regular hours coefficient is .95, your after hours coefficient would be 1.45.
Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion - Lower Tier Covered Transactions (a) The prospective lower tier participant certifies, by submission of this proposal, that neither it nor its principals is presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participation in this transaction by any federal department or agency.
Recovery of Schedule Delays During Last Sixty Days of Contract Time At any time during the last sixty days of the Contract Time that the Design Professional finds that the Contractor is behind schedule per the Contract Time, as amended, the Design Professional shall notify the Contractor in writing. Within seven days of the date of the Design Professional's notice, the Contractor shall prepare and deliver to the Design Professional and Owner a written plan explaining how the Contractor intends to bring the Project back on schedule. The Contractor's plan must provide sufficient detail to allow the Design Professional and Owner to determine the proposal's feasibility.
Pricing of Services Subcontractor shall provide or perform the Services at the pricing specified in Exhibit ___ to this Subcontract. [ATTACH A XXXX OF MATERIALS, RATE CARD OR OTHER APPROPRIATE COST SHEET COVERING THE SERVICES TO BE PROVIDED.]
Notification of Delay The Design Professional shall immediately notify the City in writing if Design Professional experiences or anticipates experiencing a delay in performing the Professional Services within the time frames set forth in the Task Order. The written notice shall include an explanation of the cause for, and a reasonable estimate of the length of, the delay. If in the opinion of the City, the delay affects a material part of the Task, the City may exercise its rights under Sections 2.5-2.7 of this Agreement.
JOC Pricing of Itemized List of RS Means Non-Prepriced Items No response The Vendor may download the optional Pricing of Itemized List of RS Means Non-Prepriced Items form from the attachment tab, fill in the requested information, and upload the completed spreadsheet. DO NOT UPLOAD encrypted or password protected files. Reference Form (PARTS 1 & 2) 220107 Reference_Form.xls Valid Reference Email addresses are REQUIRED on the spreadsheet. The vendor must download the References spreadsheet from the attachment tab, fill in the requested information and upload the completed spreadsheet. DO NOT UPLOAD encrypted or password protected files.
Rate Redetermination after Catastro- phic Damage In event of Catastrophic Damage and ad- justment, if any, of Included Timber, Contracting Officer shall make an appraisal to determine for each species the catastrophe-caused difference between the appraised unit value of Included Timber remaining immediately prior to the catastrophe and the appraised unit value of existing and potential Included Timber immediately after the ca- tastrophe. Included Timber is any that would not be elimi- nated under B8.32. Potential Included Timber is any that would be added under B8.32. Tentative Rates and Flat Rates in effect at the time of catastrophe shall be adjusted by said differences to be- come the redetermined rates for the purpose of a contract modification under B8.32. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to new Base Rate limitations of 25 cents per hun- dred cubic feet or equivalent. However, existing Base In- dices shall not be changed under this Subsection. Upon agreement under B8.32, redetermined rates and Required Deposits shall be considered established under B3.1 for timber Scaled subsequent to Catastrophic Damage. At time of such appraisal, Specified Road construc- tion cost shall include the estimated cost of any construc- tion work listed in the Schedule of Items performed and abandoned.
