Possession by the Allottee After obtaining the occupancy certificate* and handing over physical possession of the [Apartment/Plot] to the Allottees, it shall be the responsibility of the Promoter to hand over the necessary documents and plans, including common areas, to the association of Allottees or the competent authority, as the case may be, as per the local laws. [Provided that, in the absence of any local law, the promoter shall handover the necessary documents and plans, including common areas, to the association of allottees or the competent authority, as the case may be, within thirty days after obtaining the completion certificate].
POSSESSION OF THE PLOT 7.1 Schedule for possession of the said Plot - The Promoter agrees and understands that timely delivery of possession of the Plot to the allottee’s and the common areas to the association of allottee’s or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the Plot along with ready and complete common areas with all specifications, amenities and facilities of the project in place on (Date) unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee’s agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Plot, provided that such Force Majeure conditions are not of a nature, which make it impossible for the contract to be implemented. The Allottee’s agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee’s the entire amount received by the Promoter from the allotment within 45 days from that date. The promoter shall intimate the allottee’s about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee’s, the Allottee’s agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
POSSESSION Tenant has examined the condition of the Premises and by taking possession acknowledges that they have accepted the Premises in good order and in its current condition except as herein otherwise stated. Failure of the Landlord to deliver possession of the Premises at the start of the Lease Term to the Tenant shall terminate this Agreement at the option of the Tenant. Furthermore, under such failure to deliver possession by the Landlord, and if the Tenant cancels this Agreement, the Security Deposit (if any) shall be returned to the Tenant along with any other pre-paid rent, fees, including if the Tenant paid a fee during the application process before the execution of this Agreement.
POSSESSION OF THE PROPERTY The Parties hereby agree that the exclusive possession of the Property shall be delivered by the Seller to the Buyer on .
POSSESSION AND RISK 12.1 Possession of the Property shall only be given by the Seller and taken by the Purchaser on registration of transfer, provided that clauses 4.2 and 4.2 above have been complied with, from which date all risks and benefits of ownership in respect of the Property shall pass to the Purchaser.
POSSESSION OF PROPERTY Possession of the Property free and clear of all uses and encroachments, except the Permitted Exceptions, shall be delivered to Purchaser at closing.
Possession of Alcohol and Illegal Drugs Employees may not use or possess alcohol while on duty, except when authorized by the institution’s policy. The possession or use of illegal drugs is strictly prohibited.
POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
POSSESSION OF PREMISES Tenant shall not be entitled to possession of the premises designated for lease until the security deposit and first month’s rent (or prorated portion thereof), less any applicable promotional discount, is paid in full and the premises designated for lease is vacated by the prior tenant.
RESPONDENT LIABILITY FOR DAMAGE TO GOVERNMENT PROPERTY The Respondent shall be liable for all damages to government-owned, leased, or occupied property and equipment caused by the Respondent and its employees, agents, subcontractors, and suppliers, including any delivery or cartage company, in connection with any performance pursuant to the Contract. The Respondent shall notify the City of Xxxxxx Procurement Manager in writing of any such damage within one (1) calendar day.
