Limitation on Out-of-State Litigation - Texas Business and Commerce Code § 272 This is a requirement of the TIPS Contract and is non-negotiable. Texas Business and Commerce Code § 272 prohibits a construction contract, or an agreement collateral to or affecting the construction contract, from containing a provision making the contract or agreement, or any conflict arising under the contract or agreement, subject to another state’s law, litigation in the courts of another state, or arbitration in another state. If included in Texas construction contracts, such provisions are voidable by a party obligated by the contract or agreement to perform the work. By submission of this proposal, Vendor acknowledges this law and if Vendor enters into a construction contract with a Texas TIPS Member under this procurement, Vendor certifies compliance.
PROCLAMATION OF SALE, CONDITIONS OF SALE AND MEMORANDUM OF SALE All contents in the Proclamation of Sale and this Conditions of Sale are to be read together and shall be part of the Memorandum of Sale.
CERTIFICATION PROHIBITING DISCRIMINATION AGAINST FIREARM AND AMMUNITION INDUSTRIES (Texas law as of September 1, 2021) By submitting a proposal to this Solicitation, you certify that you agree, when it is applicable, to the following required by Texas law as of September 1, 2021: If (a) company is not a sole proprietorship; (b) company has at least ten (10) full-time employees; (c) this contract has a value of at least $100,000 that is paid wholly or partly from public funds; (d) the contract is not excepted under Tex. Gov’t Code § 2274.003 of SB 19 (87th leg.); and (e) governmental entity has determined that company is not a sole-source provider or governmental entity has not received any bids from a company that is able to provide this written verification, the following certification shall apply; otherwise, this certification is not required. Pursuant to Tex. Gov’t Code Ch. 2274 of SB 19 (87th session), the company hereby certifies and verifies that the company, or association, corporation, partnership, joint venture, limited partnership, limited liability partnership, or limited liability company, including a wholly owned subsidiary, majority-owned subsidiary parent company, or affiliate of these entities or associations, that exists to make a profit, does not have a practice, policy, guidance, or directive that discriminates against a firearm entity or firearm trade association and will not discriminate during the term of this contract against a firearm entity or firearm trade association. For purposes of this contract, “discriminate against a firearm entity or firearm trade association” shall mean, with respect to the entity or association, to: “(1) refuse to engage in the trade of any goods or services with the entity or association based solely on its status as a firearm entity or firearm trade association; (2) refrain from continuing an existing business relationship with the entity or association based solely on its status as a firearm entity or firearm trade association; or (3) terminate an existing business relationship with the entity or association based solely on its status as a firearm entity or firearm trade association. See Tex. Gov’t Code § 2274.001(3) of SB 19. “Discrimination against a firearm entity or firearm trade association” does not include: “(1) the established policies of a merchant, retail seller, or platform that restrict or prohibit the listing or selling of ammunition, firearms, or firearm accessories; and (2) a company’s refusal to engage in the trade of any goods or services, decision to refrain from continuing an existing business relationship, or decision to terminate an existing business relationship to comply with federal, state, or local law, policy, or regulations or a directive by a regulatory agency, or for any traditional business reason that is specific to the customer or potential customer and not based solely on an entity’s or association’s status as a firearm entity or firearm trade association.” See Tex. Gov’t Code § 2274.001(3) of SB 19.
Certification Regarding Prohibition of Certain Terrorist Organizations (Tex Gov. Code 2270) Vendor certifies that Vendor is not a company identified on the Texas Comptroller’s list of companies known to have contracts with, or provide supplies or services to, a foreign organization designated as a Foreign Terrorist Organization by the U.S. Secretary of State. Does Vendor certify? 3 Yes
Pennsylvania Motor Vehicle Sales Finance Act Licenses The Indenture Trustee shall use its best efforts to maintain the effectiveness of all licenses required under the Pennsylvania Motor Vehicle Sales Finance Act in connection with this Indenture and the transactions contemplated hereby until the lien and security interest of this Indenture shall no longer be in effect in accordance with the terms hereof.
Compliance with Investment Company Act The business and other activities of the Borrower and its Subsidiaries, including the making of the Loans hereunder, the application of the proceeds and repayment thereof by the Borrower and the consummation of the Transactions contemplated by the Loan Documents do not result in a violation or breach in any material respect of the provisions of the Investment Company Act or any rules, regulations or orders issued by the Securities and Exchange Commission thereunder, in each case that are applicable to the Borrower and its Subsidiaries.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 Does Vendor agree? Yes, Vendor agrees Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body. 2
Please see the current Washtenaw Community College catalog for up-to-date program requirements Secondary / Post-Secondary Program Alignment Welding HIGH SCHOOL COURSE SEQUENCE 9th Grade 10th Grade 11th Grade 12th Grade English 9 Algebra I World History/Geography Biology World Language Phys Ed/Health English 10 Geometry U.S. History/Geography Physics or Chemistry World Language Visual/Performing/Applied Arts English 11 Algebra II Civics/Economics Welding English 12 Math Credit Science Credit Welding WASHTENAW COMMUNITY COLLEGE Welding Associate in Applied Science Semester 1 Math Elective(s)* 3 WAF 105 Introduction to Welding Processes 2 WAF 111 Oxy-fuel Welding 4 WAF 112 Shielded Metal Arc Welding 4 Semester Total 13 Semester 2 Speech Elective(s) 3 WAF 106 Blueprint Reading for Welders 3 WAF 123 Advanced Oxy-fuel Welding 4 WAF 124 Advanced Shielded Metal Arc Welding 4 Semester Total 14 Semester 3 Arts/Human. Elective(s) 3 Computer Lit. Elective(s) 3 WAF 215 Advanced Gas Tungsten Arc Welding 4 WAF 288 Gas Metal Arc Welding 4 Semester Total 14 Semester 4 WAF 200 Layout Theory Welding 3 WAF 210 Welding Metallurgy 3 Soc. Sci. Elective(s) 3 WAF 226 Specialized Welding Procedures 4 Semester Total 13 Semester 5 Nat. Sci. Elective(s) 4 WAF 227 Basic Fabrication 3 WAF 229 Shape Cutting Operations 3 Writing Elective(s) 3 Semester Total 13 Program Totals 67
Allocation and use of scarce resources Any procedures for the allocation and use of scarce resources, including frequencies, numbers and rights of way, will be carried out in an objective, timely, transparent and non-discriminatory manner. The current state of allocated frequency bands will be made publicly available, but detailed identification of frequencies allocated for specific government uses is not required.
Term of Agreement; Resignation and Removal of the Administrator (a) This Agreement shall continue in force until the dissolution of the Issuing Entity, upon which event this Agreement shall automatically terminate.
