Notice of Events of Default The Issuer shall give a Responsible Officer of the Indenture Trustee and each Rating Agency prompt written notice of each Event of Default hereunder and each default on the part of the Servicer or the Seller of its obligations under the Sale and Servicing Agreement.
NOTICE OF THIRD PARTY CLAIMS Pursuant to Public Contract Code Section 9201, District shall provide Contractor timely notification of the receipt of any third-party claim relating to this Contract. District shall be entitled to recover its reasonable costs incurred in providing such notification.
Notice of Litigation Each Seller shall promptly notify the applicable Purchaser upon becoming aware of any Proceedings or threatened Proceedings concerning any Serviced Appointment, in each case, excluding Proceedings in servicer-managed mortgage-level litigation with respect to residential mortgage-backed securities transactions. Notices delivered pursuant to this Section 5.4 will be delivered to the notice recipient designated on Annex B.
Direct Claims Any Action by an Indemnified Party on account of a Loss which does not result from a Third Party Claim (a “Direct Claim”) shall be asserted by the Indemnified Party giving the Indemnifying Party reasonably prompt written notice thereof, but in any event not later than 30 days after the Indemnified Party becomes aware of such Direct Claim. The failure to give such prompt written notice shall not, however, relieve the Indemnifying Party of its indemnification obligations, except and only to the extent that the Indemnifying Party forfeits rights or defenses by reason of such failure. Such notice by the Indemnified Party shall describe the Direct Claim in reasonable detail, shall include copies of all material written evidence thereof and shall indicate the estimated amount, if reasonably practicable, of the Loss that has been or may be sustained by the Indemnified Party. The Indemnifying Party shall have 30 days after its receipt of such notice to respond in writing to such Direct Claim. The Indemnified Party shall allow the Indemnifying Party and its professional advisors to investigate the matter or circumstance alleged to give rise to the Direct Claim, and whether and to what extent any amount is payable in respect of the Direct Claim and the Indemnified Party shall assist the Indemnifying Party’s investigation by giving such information and assistance (including access to the Company’s premises and personnel and the right to examine and copy any accounts, documents or records) as the Indemnifying Party or any of its professional advisors may reasonably request. If the Indemnifying Party does not so respond within such 30 day period, the Indemnifying Party shall be deemed to have rejected such claim, in which case the Indemnified Party shall be free to pursue such remedies as may be available to the Indemnified Party on the terms and subject to the provisions of this Agreement.
Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.
Notice of Legal Matter or Litigation Grantee will send notice to the Substance Use Disorder (SUD) email box, XxxxxxxxxXxxxx.Xxxxxxxxx@xxxx.xxxxx.xx.xx of any litigation or legal matter related to or affecting this Contract within seven (7) calendar days of becoming aware of the litigation or legal matter.
Defendant’s Representations The defendant acknowledges that he has entered into this plea agreement freely and voluntarily after receiving the effective assistance, advice and approval of counsel. The defendant acknowledges that he is satisfied with the assistance of counsel, and that counsel has fully advised him of his rights and obligations in connection with this plea agreement. The defendant further acknowledges that no threats or promises, other than the promises contained in this plea agreement, have been made by the United States, the Court, his attorneys or any other party to induce him to enter his plea of guilty.
Notice of Legal Actions The Contractor must notify the Department of any legal actions filed against it for a violation of any laws, rules, codes, ordinances or licensing requirements within 30 days of the action being filed. The Contractor must notify the Department of any legal actions filed against it for a breach of a contract of similar size and scope to this Contract within 30 days of the action being filed. Failure to notify the Department of a legal action within 30 days of the action will be grounds for termination for cause of the Contract.
FALSE STATEMENTS; BREACH OF REPRESENTATIONS The Parties acknowledge that this Agreement has been negotiated, and is being executed, in reliance upon the information contained in the Application, and any supplements or amendments thereto, without which the Comptroller would not have approved this Agreement and the District would not have executed this Agreement. By signature to this Agreement, the Applicant:
EFFECTIVE DATE AND NOTICE OF NONLIABILITY This Agreement shall not be effective or enforceable until it is approved and signed by the State Controller or its designee (hereinafter called the “Effective Date”), but shall be effective and enforceable thereafter in accordance with its provisions. The State shall not be liable to pay or reimburse Contractor for any performance hereunder or be bound by any provision hereof prior to the Effective Date.
