Excuse for Nonperformance or Delayed Performance Except with respect to defaults of subcontractors, Contractor/Vendor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor/Vendor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor/Vendor has notified the Commission or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Contractor/Vendor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Contractor to meet the contract requirements. Upon request of Contractor, the Commission or designee shall ascertain the facts and extent of such failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, Contractor’s progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause entitled (in fixed-price contracts, “Termination for Convenience,” in cost-reimbursement contracts, “Termination”). (As used in this Paragraph of this clause, the term “subcontractor” means subcontractor at any tier).
Nonperformance As used in this Contract, “failure to perform” means failure, for whatever reason, to deliver goods and/or perform work as specified and scheduled in this Contract. If Contractor fails to perform under this Contract, then District, after giving seven days’ written notice and opportunity to cure to Contractor, has the right to complete the work itself, to obtain the contracted goods and/or services from other contractors, or a combination thereof, as necessary to complete the work. Both parties agree that Contractor shall bear any reasonable cost difference, as measured against any unpaid balance due Contractor, for these substitute goods or services.
Performance by Contractor Where Pur- chaser’s employees, agents, contractors, Subcontractors, or their employees or agents perform Purchaser’s Opera- tions in connection with fire responsibilities, Purchaser’s obligations shall be the same as if performance was by Purchaser.
TERMINATION BY MPS - BREACH BY CONTRACTOR If Contractor fails to fulfill its obligations under this Contract in a timely or proper manner, or violates any of its provisions, MPS shall thereupon have the right to terminate it by giving five (5) days written notice before the effective date of termination of the Contract, specifying the alleged violations, and effective date of termination. The Contract shall not be terminated if, upon receipt of the notice, Contractor promptly cures the alleged violation with five (5) days. In the event of termination, MPS will only be liable for services rendered through the date of termination and not for the uncompleted portion, or for any materials or services purchased or paid for by Contractor for use in completing the Contract.
Excuse from Performance The Parties shall be excused from performing their respective obligations hereunder if they are prevented from so performing by reason of floods, earthquakes, other acts of nature, war, civil insurrection, riots, acts of any government (including judicial action), and other similar catastrophic events which are beyond the control of and not the fault of the Party claiming excuse from performance hereunder. Labor unrest, including but not limited to strike, work stoppage or slowdown, sick-out, picketing, or other concerted job action conducted by Contractor's employees or directed at Contractor is not an excuse from performance and Contractor shall be obligated to continue to provide service notwithstanding the occurrence of any or all of such events. The Party claiming excuse from performance shall, within two (2) Business Days after such Party has notice of such cause, give the other Party notice of the facts constituting such cause and asserting its claim to excuse under this Section. If either Party validly exercises its rights under this Section, the Parties hereby waive any claim against each other for any damages sustained thereby. The partial or complete interruption or discontinuance of Contractor's services caused by one or more of the events described in this Section shall not constitute a default by Contractor under this Agreement. Notwithstanding the foregoing, however, if Contractor is excused from performing its obligations hereunder for any of the causes listed in this Section for a period of thirty (30) calendar days or more, the SCWMA shall nevertheless have the right, in its sole discretion, to terminate this Agreement by giving ten (10) calendar days notice to Contractor unless Contractor has demonstrated, by the thirtieth (30th) calendar day, to the satisfaction of the SCWMA that the Contractor will resume services no later than the sixtieth (60th) day following the date service was interrupted or discontinued by Contractor.
Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.
Termination by Either Party This Agreement may be terminated upon 60 days written notice without cause or penalty by either the Company (acting through the Conflicts Committee) or the Advisor. The provisions of Articles 1, 10, 12, 13, 15 and 16 shall survive termination of this Agreement.
Performance Delay Time is of the essence in the Vendor’s performance of this Agreement. If at any time it appears to Vendor that it may not meet any of the performance schedules or the scheduled completion date of the services to be performed for any reason, including labor disputes, Vendor shall immediately by verbal means (to be confirmed in writing) notify Customer of the reasons for and the estimated duration of such delay. If requested by Customer, Vendor shall make every effort to avoid or minimize the delay to the maximum extent possible including the expenditure of premium time. Any additional cost caused by these requirements of Customer shall be borne by Vendor, unless the delay in performance arises out of causes beyond the control and without the fault or negligence of Vendor or its subcontractors within the meaning of the Cancellation- Default clause herein. The foregoing requirements are in addition to any of Customer’s other rights and remedies as may be provided by law or this Agreement.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
Financial Consequences for Nonperformance The State reserves the right to withhold payment or implement other appropriate remedies, such as contract termination or nonrenewal, when the Contractor has failed to perform under or comply with the provisions of this contract. When or if the Contractor fails to perform or comply with provisions of this contract, the Contractor has ten (10) calendar days from receipt of Complaint to Vendor Form (PUR 7017) to comply as instructed within the notice. An amount of $500.00 may be assessed for each day the Contractor is delinquent after the ten (10) day notice period ends, and that amount may be withheld from a Contractor’s invoice. The rights and remedies of the State in this paragraph are not considered penalties and are in addition to any other rights and remedies provided by law.
