Excuse for Nonperformance or Delayed Performance Sample Clauses

Excuse for Nonperformance or Delayed Performance. Except with respect to defaults of subcontractors, Contractor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor has notified the DMH Executive Director or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Contractor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Contractor to meet the contract requirements. Upon request of Contractor, the DMH Executive Director or designee shall ascertain the facts and extent of such failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, Contractor’s progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause entitled “Termination for Convenience” in fixed price contracts and “Termination” in cost- reimbursement contracts.
Sample 1Sample 2Sample 3See All (134)
Excuse for Nonperformance or Delayed Performance. Except with respect to defaults of subcontractors, Vendor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Vendor to make progress in the prosecution of the work hereunder which endangers such performance) if Vendor has notified the MTC or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Vendor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Vendor to meet the contract requirements. In such a case, MDOT may, upon the request of the Vendor, revise the delivery schedule accordingly.
Sample 1Sample 2Sample 3See All (104)
Excuse for Nonperformance or Delayed Performance. Except with respect to defaults of subcontractors, Contractor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor has notified the Agency Head or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its
Sample 1Sample 2
Excuse for Nonperformance or Delayed Performance. The Contractor shall not be in default by reason of any failure in performance of this Contract in accordance with its terms (including any failure by the Contractor to make progress in the prosecution of the work hereunder which endangers such performance) if the Contractor has notified the MSPA within fifteen (1 S) days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather.
Sample 1Sample 2
Excuse for Nonperformance or Delayed Performance. Except with respect to defaults of sub-contractors, the Contractor shall not be in default by reason of any failure in performance of this Contract in accordance with its terms if the Contractor has notified the Contracting Officer within fifteen (15) days after the cause of the delay and the failure arises out of causes such as, acts of God, acts of the public enemy, acts of CUC and any other CUC entity in its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes or other labor disputes, freight embargo, or unusually severe weather. If the failure to perform is caused by the failure of a sub-contractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, the Contractor shall not be deemed to be in default, unless the supplies and/or services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit the Contractor to meet the Contract requirements. Upon request of the Contractor, the Contracting Officer shall ascertain the facts and extent of such failure, and if the Contracting Officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, the Contractor's progress and performance would have met the terms of this Contract, the delivery schedule shall be revised accordingly, subject to the rights of CUC under the "TERMINATION FOR CONVENIENCE" clause.
Sample 1

Related to Excuse for Nonperformance or Delayed Performance

  • Excuse from performance of obligations If the Affected Party is rendered wholly or partially unable to perform its obligations under this Agreement because of a Force Majeure Event, it shall be excused from performance of such of its obligations to the extent it is unable to perform on account of such Force Majeure Event; provided that: (a) the suspension of performance shall be of no greater scope and of no longer duration than is reasonably required by the Force Majeure Event; (b) the Affected Party shall make all reasonable efforts to mitigate or limit damage to the other Party arising out of or as a result of the existence or occurrence of such Force Majeure Event and to cure the same with due diligence; and (c) when the Affected Party is able to resume performance of its obligations under this Agreement, it shall give to the other Party notice to that effect and shall promptly resume performance of its obligations hereunder.

  • Excused Performance In case performance of any terms or provisions hereof shall be delayed or prevented because of compliance with any law, decree or order of any governmental agency or authority, whether the same shall be of Local, State or Federal origin, or because of riots, war, public disturbances, strikes, lockouts, differences with workmen, fires, floods, acts of God or any other reason whatsoever which is not within the control of the party whose performance is interfered with and which, by the exercise of reasonable diligence, said party is unable to prevent, the party so suffering may, at its option, suspend, without liability, the performance of its obligations hereunder during the period of such suspension of performance of duties hereunder.

  • Prevention or Delay of Performance by the Company or the Depositary Neither the Depositary nor the Company nor any of their respective directors, employees, agents or affiliates shall incur any liability to any Owner or Holder: (i) if by reason of (A) any provision of any present or future law or regulation or other act of the government of the United States, any State of the United States or any other state or jurisdiction, or of any governmental or regulatory authority or stock exchange; (B) (in the case of the Depositary only) any provision, present or future, of the articles of association or similar document of the Company, or by reason of any provision of any securities issued or distributed by the Company, or any offering or distribution thereof; or (C) any event or circumstance, whether natural or caused by a person or persons, that is beyond the ability of the Depositary or the Company, as the case may be, to prevent or counteract by reasonable care or effort (including, but not limited to, earthquakes, floods, severe storms, fires, explosions, war, terrorism, civil unrest, labor disputes or criminal acts; interruptions or malfunctions of utility services, Internet or other communications lines or systems; unauthorized access to or attacks on computer systems or websites; or other failures or malfunctions of computer hardware or software or other systems or equipment), the Depositary or the Company is, directly or indirectly, prevented from, forbidden to or delayed in, or could be subject to any civil or criminal penalty on account of doing or performing and therefore does not do or perform, any act or thing that, by the terms of this Deposit Agreement or the Deposited Securities, it is provided shall be done or performed; (ii) for any exercise of, or failure to exercise, any discretion provided for in this Deposit Agreement (including any determination by the Depositary to take, or not take, any action that this Deposit Agreement provides the Depositary may take); (iii) for the inability of any Owner or Holder to benefit from any distribution, offering, right or other benefit that is made available to holders of Deposited Securities but is not, under the terms of this Deposit Agreement, made available to Owners or Holders; or (iv) for any special, consequential or punitive damages for any breach of the terms of this Deposit Agreement. Where, by the terms of a distribution to which Section 4.1, 4.2 or 4.3 applies, or an offering to which Section 4.4 applies, or for any other reason, that distribution or offering may not be made available to Owners, and the Depositary may not dispose of that distribution or offering on behalf of Owners and make the net proceeds available to Owners, then the Depositary shall not make that distribution or offering available to Owners, and shall allow any rights, if applicable, to lapse.

  • Continuing Performance (a) The obligations under this Agreement continue until satisfied in full and do not merge with any action performed or document executed by any Party for the purposes of performance of this Agreement. (b) Any representation in this Agreement survives the execution of any document for the purposes of, and continues after, performance of this Agreement. (c) Any indemnity given by any Party under this Agreement: (i) constitutes a liability of that Party separate and independent from any other liability of that Party under this Agreement or any other agreement; and (ii) survives and continues after performance of this Agreement.

  • Performance Delay Time is of the essence in the Vendor’s performance of this Agreement. If at any time it appears to Vendor that it may not meet any of the performance schedules or the scheduled completion date of the services to be performed for any reason, including labor disputes, Vendor shall immediately by verbal means (to be confirmed in writing) notify Customer of the reasons for and the estimated duration of such delay. If requested by Customer, Vendor shall make every effort to avoid or minimize the delay to the maximum extent possible including the expenditure of premium time. Any additional cost caused by these requirements of Customer shall be borne by Vendor, unless the delay in performance arises out of causes beyond the control and without the fault or negligence of Vendor or its subcontractors within the meaning of the Cancellation- Default clause herein. The foregoing requirements are in addition to any of Customer’s other rights and remedies as may be provided by law or this Agreement.

  • Prompt Performance All actions required to be taken (including payments) by any party under this Agreement shall be performed within the time prescribed for performance in this Agreement, or if no period is prescribed, such actions shall be performed promptly.

  • OUTCOME IF GRANTEE CANNOT COMPLETE REQUIRED PERFORMANCE Unless otherwise specified in this Statement of Work, if Grantee cannot complete or otherwise comply with a requirement included in this Statement of Work, HHSC, at its sole discretion, may impose remedies or sanctions outlined under Contract Attachment D, Local Mental Health Authority Special Conditions, Section 7.09 (Remedies and Sanctions). CONTRACT NO. HHS001324500038

  • Work Performance Xxxxxx agrees that all Services performed hereunder shall be performed on a best effort basis by employees, students, faculty, graduate assistants and staff having an appropriate experience and skill level and in compliance with the statement of work.

  • Prevention or Delay in Performance by the Depositary or the Company Neither the Depositary nor the Company nor any of their respective directors, employees, agents or affiliates shall incur any liability to any Owner or Holder (i) if by reason of any provision of any present or future law or regulation of the United States or any other country, or of any governmental or regulatory authority or stock exchange, or by reason of any provision, present or future, of the articles of association or similar document of the Company, or by reason of any provision of any securities issued or distributed by the Company, or any offering or distribution thereof, or by reason of any act of God or war or terrorism or other circumstances beyond its control, the Depositary or the Company shall be prevented, delayed or forbidden from, or be subject to any civil or criminal penalty on account of, doing or performing any act or thing which by the terms of this Deposit Agreement or the Deposited Securities it is provided shall be done or performed, (ii) by reason of any non-performance or delay, caused as aforesaid, in the performance of any act or thing which by the terms of this Deposit Agreement it is provided shall or may be done or performed, (iii) by reason of any exercise of, or failure to exercise, any discretion provided for in this Deposit Agreement, (iv) for the inability of any Owner or holder to benefit from any distribution, offering, right or other benefit which is made available to holders of Deposited Securities but is not, under the terms of this Deposit Agreement, made available to Owners or holders, or (v) for any special, consequential or punitive damages for any breach of the terms of this Deposit Agreement. Where, by the terms of a distribution pursuant to Section 4.01, 4.02 or 4.03, or an offering or distribution pursuant to Section 4.04, or for any other reason, such distribution or offering may not be made available to Owners, and the Depositary may not dispose of such distribution or offering on behalf of such Owners and make the net proceeds available to such Owners, then the Depositary shall not make such distribution or offering, and shall allow any rights, if applicable, to lapse.

  • Monitoring of Contract Performance The Contractor shall comply with the monitoring arrangements set out in the Monitoring Requirements Schedule including, but not limited to, providing such data and information as the Contractor may be required to produce under the Contract.