Non Payment by the Concessioning Authority. (in case of Positive Tipping Fee) or Concessionaire (in case of Negative Tipping Fee) during Concession Period
Non Payment by the Concessioning Authority Sample Clauses
Related to Non Payment by the Concessioning Authority
Compensation for default by the Concessionaire Subject to the provisions of Clause 35.6, in the event of the Concessionaire being in material default or breach of this Agreement, it shall pay to the Authority by way of compensation, all direct costs suffered or incurred by the Authority as a consequence of such material default or breach, within 30 (thirty) days of receipt of the demand supported by necessary particulars thereof; provided that no compensation shall be payable under this Clause 35.1 for any material breach or default in respect of which Damages are expressly specified and payable under this Agreement.
Acceptance by the City It is expressly understood and agreed that all materials provided and/or work done by the Contractor shall be subject to inspection and acceptance by the City at its discretion, and that any progress inspections and approval by the City of any item or work shall not forfeit the right of the City to require the correction of faulty workmanship or material at any time during the course of the work, although previously approved by oversight. Nothing herein contained shall relieve the Contractor of the responsibility for proper construction and maintenance of the work, materials and equipment required under the terms of this Contract until all work has been completed and accepted by the City.
Damages for delay by the Concessionaire In the event that (i) the Concessionaire does not procure fulfilment of any or all of the Conditions Precedent set forth in Clause 4.1.3 within a period of 180 (one hundred and eighty) days from the date of this Agreement, and (ii) the delay has not occurred as a result of failure to fulfil the obligations under Clause 4.1.2 or other breach of this Agreement by the Authority, or due to Force Majeure, the Concessionaire shall pay to the Authority Damages in an amount calculated at the rate of 0.2% (zero point two per cent) of the Performance Security for each day's delay until the fulfilment of such Conditions Precedent, subject to a maximum of 20% (twenty percent) of the Performance Security.
Release by the Contractor The acceptance by the Contractor of final payment shall release NYSERDA from all claims and liability that the Contractor, its representatives and assigns might otherwise have relating to this Agreement.
TERMINATION BY THE CONTRACTOR If the Work is stopped for a period of thirty days under an order of any court or other public authority having jurisdiction, or as a result of an act of government, such as a declaration of a national emergency making materials unavailable, through no act or fault of the Contractor or a Subcontractor or their agents or employees or any other persons performing any of the Work under a contract with the Contractor, or if the Work should be stopped for a period of thirty days by the Contractor because the Architect has not issued a Certificate for Payment as provided in Paragraph 9.7 of these General Conditions or because the State has not made payment thereon as provided in Paragraph 9.7, then the Contractor may, upon seven additional days written notice to the State and the Architect, terminate the Contract and recover from the State payment for all Work executed and for any proven loss sustained upon any materials, equipment, tools, construction equipment and machinery, including reasonable profit and damages.
Contract Use by State Agencies To the extent applicable, the Contract does not prohibit state agencies from using their delegated purchasing authority to procure similar goods and services from other sources.
Contract Distribution The Employer will provide all current and new employees with a link to the new Agreement. Each department or unit will maintain a paper copy of the contract accessible to all employees.
Audits by The District and Correction of Accounts During the term of this Agreement and for a period of six (6) years following the termination of this Agreement, the District may begin an audit of Contractor’s provision of goods and/or services under this Agreement. Contractor agrees to retain and make available for inspection all of its records pertaining to its performance of this Agreement, including billing records and any banking records that may reflect proceeds from any transactions with the District, during the term of this Agreement and for at least six (6) years following the termination of this Agreement. If Contractor receives notice that The District is auditing its performance under this Agreement or litigation results from this Agreement, then Contractor agrees to retain and make available for inspection all of its records pertaining to its performance of this Agreement, including billing records and any banking records that may reflect proceeds from any transactions with the District, for an additional three (3) years following the conclusion of the audit or the entry of a final judgment in any such litigation and the final resolution of any possible appeals of a final judgment in any such litigation. If the District determines as result of its audit, that Contractor has failed to satisfy the invoicing or documentation requirements of this Agreement, has improperly billed the District for goods and/or services that were not actually provided, or has overcharged the District for goods and/or services that were actually provided by Contractor, then Contractor shall repay the District, without interest, for any improper payments or overpayments made by the District to Contractor within thirty (30) days of a written demand by the District. If Contractor fails to repay the District for any improper payments or overpayments within thirty (30) days of the District’s written demand, then Contractor will owe the District interest accrued daily at the rate of 7.0% per annum from the date of the District’s written demand until the improper payment and/or overpayment is repaid in full by Contractor. Conversely, if an audit initiated by the District reveals that the District owes additional compensation to Contractor pursuant to the terms of this Agreement, then the District will pay the additional compensation to Contractor, without interest, within thirty (30) days of the completion of its audit. If the District fails to pay Contractor for any additional compensation owed under this Agreement within thirty (30) days after completion of its audit, then the District will pay Contractor interest on the additional compensation accrued daily at the rate of 7.0% per annum from the date of the completion of the District’s audit.
Subcontract Costs Payments made by the Construction Manager to Subcontractors in accordance with the requirements of the subcontracts.
Third-Party Charges Customer may incur charges from third party service providers that are separate and apart from the amounts charged by Comcast. These may include, without limitation, charges resulting from accessing on-line services, calls to parties who charge for their telephone based services, purchasing or subscribing to other offerings via the Internet or interactive options on Public View Video, Video, or otherwise. Customer agrees that all such charges, including all applicable taxes, are Customer’s sole responsibility. In addition, Customer is solely responsible for protecting the security of credit card information provided to others in connection with such transactions.
