Intent to Limit Charges to Maximum Lawful Rate In no event shall the interest rate or rates payable under this Agreement, plus any other amounts paid in connection herewith, exceed the highest rate permissible under any law that a court of competent jurisdiction shall, in a final determination, deem applicable. Borrower and the Lender Group, in executing and delivering this Agreement, intend legally to agree upon the rate or rates of interest and manner of payment stated within it; provided, however, that, anything contained herein to the contrary notwithstanding, if said rate or rates of interest or manner of payment exceeds the maximum allowable under applicable law, then, ipso facto, as of the date of this Agreement, Borrower is and shall be liable only for the payment of such maximum as allowed by law, and payment received from Borrower in excess of such legal maximum, whenever received, shall be applied to reduce the principal balance of the Obligations to the extent of such excess.
Allowable Costs A. Allowable Costs are restricted to costs that are authorized under Texas Uniform Grant Management Standards (TxGMS) and applicable state and federal rules and laws. This Grant Agreement is subject to all applicable requirements of TxGMS, including the criteria for Allowable Costs. Additional federal requirements apply if this Grant Agreement is funded, in whole or in part, with federal funds.
B. System Agency will reimburse Grantee for actual, allowable, and allocable costs incurred by Grantee in performing the Project, provided the costs are sufficiently documented. Grantee must have incurred a cost prior to claiming reimbursement and within the applicable term to be eligible for reimbursement under this Grant Agreement. At its sole discretion, the System Agency will determine whether costs submitted by Grantee are allowable and eligible for reimbursement. The System Agency may take repayment (recoup) from remaining funds available under this Grant Agreement in amounts necessary to fulfill Grantee’s repayment obligations. Grantee and all payments received by Grantee under this Grant Agreement are subject to applicable cost principles, audit requirements, and administrative requirements including applicable provisions under 2 CFR 200, 48 CFR Part 31, and TxGMS.
C. OMB Circulars will be applied with the modifications prescribed by TxGMS with effect given to whichever provision imposes the more stringent requirement in the event of a conflict.
Construction Cost 3.1. Construction Cost does not include the fees of the ARCHITECT/ENGINEER and consultants, the cost of the land, rights- of-way, or other costs, which is the responsibility of the State as provided in Paragraphs 2.2 through 2.3. or any of the contingencies available for the project unless specifically stated otherwise.
3.2. Labor furnished by the State for the Project, however, with respect only to the construction of such components thereof as have been designed by the ARCHITECT/ENGINEER, shall be included in the Construction Cost at current market rates. Materials and equipment furnished by the State shall be included at current market prices, except that used materials and equipment shall be included as if purchased new for the Project.
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians.
(ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked.
(iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority.
(iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
Tenant Improvement Allowance Items Except as otherwise set forth in this Tenant Work Letter, the Tenant Improvement Allowance shall be disbursed by Landlord only for the following items and costs (collectively, the “Tenant Improvement Allowance Items”):
2.2.1.1 Payment of the fees of the “Architect” and the “Engineers,” as those terms are defined in Section 3.1 of this Tenant Work Letter, the costs of Tenant’s project manager (if any) and payment of the fees incurred by, and the cost of documents and materials supplied by, Landlord and Landlord’s consultants in connection with the preparation and review of the “Construction Drawings,” as that term is defined in Section 3.1 of this Tenant Work Letter;
2.2.1.2 The payment of plan check, permit and license fees relating to construction of the Tenant Improvements;
2.2.1.3 The cost of construction of the Tenant Improvements, including, without limitation, contractors’ fees and general conditions, testing and inspection costs, costs of utilities, trash removal, parking and hoists, and the costs of after-hours freight elevator usage.
2.2.1.4 The cost of any changes in the Base, Shell and Core work when such changes are required by the Construction Drawings (including if such changes are due to the fact that such work is prepared on an unoccupied basis), such cost to include all direct architectural and/or engineering fees and expenses incurred in connection therewith;
2.2.1.5 The cost of any changes to the Construction Drawings or Tenant Improvements required by applicable laws and building codes (collectively, “Code”);
2.2.1.6 Sales and use taxes;
2.2.1.7 The “Coordination Fee,” as that term is defined in Section 4.2.2.2 of this Tenant Work Letter; and
2.2.1.8 All other costs to be expended by Landlord in connection with the construction of the Tenant Improvements.
