Minimum Vendor License Requirements Vendor shall maintain, in current status, all federal, state, and local licenses, bonds and permits required for the operation of the business conducted by Vendor. Vendor shall remain fully informed of and in compliance with all ordinances and regulations pertaining to the lawful provision of goods or services under the TIPS Agreement. TIPS and TIPS Members reserve the right to stop work and/or cancel a TIPS Sale or terminate this or any TIPS Sale Supplemental Agreement involving Vendor if Vendor’s license(s) required to perform under this Agreement or under the specific TIPS Sale have expired, lapsed, are suspended or terminated subject to a 30‐day cure period unless prohibited by applicable statue or regulation.
U.S. Federal Procurement Requirements Without limiting Section 12.1, in light of DXC’s status as a U.S. Federal contractor and subcontractor, all applicable procurement regulations required by federal statute or regulation to be inserted in contracts or subcontracts apply to this Order, including but not limited to FAR 52.219-8 (Utilization of Small Business Concerns), FAR 52.219.-9 (Small Business Subcontracting Plan), FAR 52.219-16 (Liquidated Damages Subcontracting Plan), FAR 52.222-26 (Equal Opportunity), FAR 52.222-35 (Equal Opportunity for Special Disabled Veterans, Veterans of the Vietnam Era, and other Eligible Veterans), FAR 52.222-36 (Affirmative Action for Workers with Disabilities), FAR 52.222-39 ( Notification of Employee Rights Concerning Payment of Union Dues or Fees), FAR 52.222-41 (Service Contract Act of 1965), and FAR 52.247-64 (Preference for Privately Owned U.S. Flag Commercial Vessels).
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
CERTIFICATION REGARDING CERTAIN FOREIGN-OWNED COMPANIES IN CONNECTION WITH CRITICAL INFRASTRUCTURE (Texas law as of September 1, 2021) By submitting a proposal to this Solicitation, you certify that you agree to the following required by Texas law as of September 1, 2021: Proposing Company is prohibited from entering into a contract or other agreement relating to critical infrastructure that would grant to the company direct or remote access to or control of critical infrastructure in this state, excluding access specifically allowed by the Proposing Company for product warranty and support purposes. Company, certifies that neither it nor its parent company nor any affiliate of company or its parent company, is (1) owned by or the majority of stock or other ownership interest of the company is held or controlled by individuals who are citizens of China, Iran, North Korea, Russia, or a designated country; (2) a company or other entity, including governmental entity, that is owned or controlled by citizens of or is directly controlled by the government of China, Iran, North Korea, Russia, or a designated country; or (3) headquartered in China, Iran, North Korea, Russia, or a designated country. For purposes of this contract, “critical infrastructure” means “a communication infrastructure system, cybersecurity system, electric grid, hazardous waste treatment system, or water treatment facility.” See Tex. Gov’t Code § 2274.0101(2) of SB 1226 (87th leg.). The company verifies and certifies that company will not grant direct or remote access to or control of critical infrastructure, except for product warranty and support purposes, to prohibited individuals, companies, or entities, including governmental entities, owned, controlled, or headquartered in China, Iran, North Korea, Russia, or a designated country, as determined by the Governor.
Sector Sub-Sector Industry Classification Level of Government Type of Obligation Description of Measure Source of Measure All sectors : : - : Central : National Treatment Senior Management and Board of Directors : National Treatment and the Senior Management and Board of Directors obligations shall not apply to any measure relating to small and medium sized domestic market enterprise2. Foreign equity is restricted to a maximum of 40% for domestic market enterprises with paid-in equity capital of less than the equivalent of USD 200,000 Note: Members of the Board of Directors or governing body of corporation or associations shall be allowed in proportion to their allowable participation or share in the capital of such enterprises. : -1987 Constitution of the Republic of the Philippines. - Foreign Investments Act of 1991 (R.A. No. 7042, as amended by R.A. No. 8179). -Presidential and Administrative Issuances. ∞ 2 The concept of a small and medium sized domestic market enterprise is an enterprise with paid in equity capital of less than the equivalent of USD 200,000.00.
Certification Regarding Prohibition of Boycotting Israel (Tex Gov. Code 2271) If (a) Vendor is not a sole proprietorship; (b) Vendor has ten (10) or more full-time employees; and (c) this Agreement or any agreement with a TIPS Member under this procurement has value of $100,000 or more, the following certification shall apply; otherwise, this certification is not required. Vendor certifies, where applicable, that neither the Vendor, nor any affiliate, subsidiary, or parent company of Vendor, if any, boycotts Israel, and Vendor agrees that Vendor and Vendor Companies will not boycott Israel during the term of this Agreement. For purposes of this Agreement, the term “boycott” shall mean and include refusing to deal with, terminating business activities with, or otherwise taking any action that is intended to penalize, inflict economic harm on, or limit commercial relations with Israel, or with a person or entity doing business in Israel or in an Israeli-controlled territory but does not include an action made for ordinary business purposes. When applicable, does Vendor certify? Yes
Foreign-Owned Companies in Connection with Critical Infrastructure If Texas Government Code, Section 2274.0102(a)(1) (relating to prohibition on contracts with certain foreign-owned companies in connection with critical infrastructure) is applicable to this Contract, pursuant to Government Code Section 2274.0102, Contractor certifies that neither it nor its parent company, nor any affiliate of Contractor or its parent company, is: (1) majority owned or controlled by citizens or governmental entities of China, Iran, North Korea, Russia, or any other country designated by the Governor under Government Code Section 2274.0103, or (2) headquartered in any of those countries.
Export Control Compliance User acknowledges that Center is an open laboratory for fundamental research that has many foreign persons as its employees and students. User understands and agrees that under no circumstances will User bring export control-listed items, or unpublished software source code or technical information in the form of defense articles or technical data regulated by the International Traffic in Arms Regulations (ITAR), to Center. Use of Center or facilities for activity subject to the ITAR, including the development, assembly or fabrication of defense articles identified on the US Munitions List, is prohibited.
Agricultural Export Subsidies 1. The Parties share the objective of the multilateral elimination of export subsidies for agricultural goods and shall work together toward an agreement in the WTO to eliminate those subsidies and prevent their reintroduction in any form.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
