Payment of Liquidated Damages With respect to any Liquidated Damages that accrue, Owner shall invoice Contractor for such Liquidated Damages. Contractor shall pay such Liquidated Damages within ten (10) Days after Contractor’s receipt of such invoice. To the extent Contractor does not pay such Liquidated Damages within such ten (10) Day period, Owner may, at its option, do one or more of the following: (i) withhold from Contractor amounts that are otherwise due and payable to Contractor in the amount of such Liquidated Damages and/or (ii) collect on the Letter of Credit in the amount of such Liquidated Damages. For the avoidance of doubt, prior to exercising such right to withhold or collect on the Letter of Credit, Owner shall not be required to provide the notice as set forth in Section 7.8. As used in this Agreement, Liquidated Damages are “paid” if and to the extent Owner exercises option (i) or (ii) above for the collection of Liquidated Damages.
Waiver of Liquidated Damages If the Partnership is unable to cause a Registration Statement to become effective on or before the Target Effective Date, then the Partnership may request a waiver of the Liquidated Damages, which may be granted by the consent of the Holders of at least the Registrable Securities Required Voting Percentage, in their sole discretion, and which such waiver shall apply to all the Holders of Registrable Securities included on such Registration Statement.
Sole Remedy for a Failure to Report Notwithstanding anything to the contrary in this Indenture or the Notes, the Company may elect that the sole remedy for any Event of Default (a “Reporting Event of Default”) pursuant to Section 5.01(4) arising from the Company’s failure to comply with Section 10.06 will, for each of the first 180 days on which a Reporting Event of Default has occurred and is continuing, consist exclusively of the right to receive Special Interest. If the Company has made such an election, then (i) the Notes will be subject to acceleration pursuant to Section 5.02 on account of the relevant Reporting Event of Default from, and including, the 181st day on which a Reporting Event of Default has occurred and is continuing or if the Company fails to pay any accrued and unpaid Special Interest when due; and (ii) Special Interest will cease to accrue on any Notes from, and including, such 181st day. Any Special Interest that accrues on a Note will be payable on the same dates and in the same manner as Installment Payments on such Note and will accrue at a rate per annum equal to 0.25% of the principal amount thereof for the first 90 days on which Special Interest accrues and, thereafter, at a rate per annum equal to 0.50% of the principal amount thereof. To make the election set forth in this Section 5.16, the Company must send to the Holders, the Trustee and the Paying Agent, before the date on which each Reporting Event of Default first occurs, a notice that (i) briefly describes the report(s) that the Company failed to file with the Commission; (ii) states that the Company is electing that the sole remedy for such Reporting Event of Default consist of the accrual of Special Interest; and (iii) briefly describes the periods during which and rate at which Special Interest will accrue and the circumstances under which the Notes will be subject to acceleration on account of such Reporting Event of Default. If Special Interest accrues on any Note, then, no later than five Business Days before each date on which such Special Interest is to be paid, the Company will deliver an Officer’s Certificate to the Trustee and the Paying Agent stating (i) that the Company is obligated to pay Special Interest on such Note on such date of payment; and (ii) the amount of such Special Interest that is payable on such date of payment. The Trustee will have no duty to determine whether any Special Interest is payable or the amount thereof. No election pursuant to this Section 5.16 with respect to a Reporting Event of Default will affect the rights of any Holder with respect to any other Event of Default, including with respect to any other Reporting Event of Default.
Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.
Failure to Make Payment In the event of failure by the Issuer to make any required payment of principal or interest on this Note (and, in the case of payment of interest, such failure to pay shall have continued for 15 calendar days), the Issuer will, upon demand of the Holder, pay to the Holder the amount then due and payable on this Note for principal and interest (without acceleration of the Note in any manner), with interest on the overdue principal and interest at the rate borne by this Note, to the extent permitted by applicable law. If the Issuer fails to pay such amount upon such demand, the Holder may, among other things, institute a judicial proceeding for the collection of the sums so due and unpaid, may prosecute such proceeding to judgment or final decree and may enforce the same against the Issuer and collect the amounts adjudged or decreed to be payable in the manner provided by law out of the property of the Issuer. Upon the occurrence of a failure by the Issuer to make any required payment of principal or interest on the Note, or any other Event of Default until such Event of Default is cured by the Issuer, the Issuer shall not (a) declare or pay any dividends or distributions on, or redeem, purchase, acquire, or make a liquidation payment with respect to, any of the Issuer’s capital stock, (b) make any payment of principal or interest or premium, if any, on or repay, repurchase or redeem any debt securities of the Issuer that rank equal with or junior to the Subordinated Notes, or (c) make any payments under any guarantee that ranks equal with or junior to the Subordinated Notes, other than (i) any dividends or distributions in shares of, or options, warrants or rights to subscribe for or purchase shares of, any class of the Issuer’s common stock; (ii) any declaration of a dividend in connection with the implementation of a shareholders’ rights plan, or the issuance of stock under any such plan in the future, or the redemption or repurchase of any such rights pursuant thereto; (iii) as a result of a reclassification of the Issuer’s capital stock or the exchange or conversion of one class or series of the Issuer’s capital stock for another class or series of the Issuer’s capital stock; (iv) the purchase of fractional interests in shares of the Issuer’s capital stock pursuant to the conversion or exchange provisions of such capital stock or the security being converted or exchanged; or (v) purchases of any class of the Issuer’s common stock related to the issuance of common stock or rights under any benefit plans for the Issuer’s directors, officers or employees or any of the Issuer’s dividend reinvestment plans.
Termination for Failure to Close This Agreement shall automatically be terminated if the Closing Date shall not have occurred by March 15, 2018; provided, that the right to terminate this Agreement pursuant to this Section 7.2 shall not be available to any Party whose breach of any provision of this Agreement results in the failure of the Closing to have occurred by such time.
Company’s Failure to Timely Deliver Securities If the Company shall fail, for any reason or for no reason, on or prior to the Share Delivery Date, if the Transfer Agent is not participating in FAST or such shares of Common Stock may not be issued without legends under the Securities Act, to issue and deliver to the Holder (or its designee) a certificate for the number of Warrant Shares to which the Holder is entitled and register such Warrant Shares on the Company’s share register or, if the Transfer Agent is participating in FAST and such shares of Common Stock may not be issued without legends under the Securities Act, to credit the balance account of the Holder or the Holder’s designee with DTC for such number of Warrant Shares to which the Holder is entitled upon the Holder’s exercise of this Warrant (as the case may be) (a “Delivery Failure”), then, in addition to all other remedies available to the Holder, (X) the Company shall pay in cash to the Holder on each day after the Share Delivery Date and during such Delivery Failure an amount in cash, as liquidated damages and not as a penalty, equal to 2.0% of the product of (A) the sum of the number of shares of Common Stock not issued to the Holder on or prior to the Share Delivery Date and to which the Holder is entitled, and (B) any trading price of the Common Stock selected by the Holder in writing as in effect at any time during the period beginning on the applicable exercise date and ending on the applicable Share Delivery Date, and (Y) the Holder, upon written notice to the Company, may void its Exercise Notice with respect to, and retain or have returned, as the case may be, any portion of this Warrant that has not been exercised pursuant to such Exercise Notice; provided that the voiding of an Exercise Notice shall not affect the Company’s obligations to make any payments which have accrued prior to the date of such notice pursuant to this Section 1(c) or otherwise. In addition to the foregoing, if on or after such Share Delivery Date the Holder purchases (in an open market transaction or otherwise) shares of Common Stock to deliver in satisfaction of a sale by the Holder of all or any portion of the number of shares of Common Stock issuable upon such exercise that the Holder is entitled to receive from the Company (a “Buy-In”), then, in addition to all other remedies available to the Holder, the Company shall, within three (3) Business Days after the Holder’s request and in the Holder’s discretion, either (i) pay cash to the Holder in an amount equal to the Holder’s total purchase price (including brokerage commissions and other out-of-pocket expenses, if any) for the shares of Common Stock so purchased (including, without limitation, by any other Person in respect, or on behalf, of the Holder) (the “Buy-In Price”), at which point the Company’s obligation to so issue and deliver such certificate (and to issue such shares of Common Stock) or credit the balance account of such Holder or such Holder’s designee, as applicable, with DTC for the number of Warrant Shares to which the Holder is entitled upon the Holder’s exercise hereunder (as the case may be) (and to issue such Warrant Shares) shall terminate, or (ii) promptly honor its obligation to so issue and deliver to the Holder a certificate or certificates representing such Warrant Shares or credit the balance account of such Holder or such Holder’s designee, as applicable, with DTC for the number of Warrant Shares to which the Holder is entitled upon the Holder’s exercise hereunder (as the case may be) and pay cash to the Holder in an amount equal to the excess (if any) of the Buy-In Price over the product of (A) such number of Warrant Shares multiplied by (B) the Closing Sale Price of the Common Stock on the Share Delivery Date with respect to the related Exercise Notice (the “Buy-In Payment Amount”). The Holder shall provide the Company written notice indicating the amounts payable to the Holder in respect of the Buy-In and, upon request of the Company, evidence of the amount of such loss. Nothing shall limit the Holder’s right to pursue any other remedies available to it hereunder, at law or in equity, including, without limitation, a decree of specific performance and/or injunctive relief with respect to the Company’s failure to timely deliver certificates representing shares of Common Stock (or to electronically deliver such shares of Common Stock) upon the exercise of this Warrant as required pursuant to the terms hereof.
Compensation for Buy-In on Failure to Timely Deliver Warrant Shares Upon Exercise In addition to any other rights available to the Holder, if the Company fails to cause the Transfer Agent to transmit to the Holder the Warrant Shares in accordance with the provisions of Section 2(d)(i) above pursuant to an exercise on or before the Warrant Share Delivery Date, and if after such date the Holder is required by its broker to purchase (in an open market transaction or otherwise) or the Holder’s brokerage firm otherwise purchases, shares of Common Stock to deliver in satisfaction of a sale by the Holder of the Warrant Shares which the Holder anticipated receiving upon such exercise (a “Buy-In”), then the Company shall (A) pay in cash to the Holder the amount, if any, by which (x) the Holder’s total purchase price (including brokerage commissions, if any) for the shares of Common Stock so purchased exceeds (y) the amount obtained by multiplying (1) the number of Warrant Shares that the Company was required to deliver to the Holder in connection with the exercise at issue times (2) the price at which the sell order giving rise to such purchase obligation was executed, and (B) at the option of the Holder, either reinstate the portion of the Warrant and equivalent number of Warrant Shares for which such exercise was not honored (in which case such exercise shall be deemed rescinded) or deliver to the Holder the number of shares of Common Stock that would have been issued had the Company timely complied with its exercise and delivery obligations hereunder. For example, if the Holder purchases Common Stock having a total purchase price of $11,000 to cover a Buy-In with respect to an attempted exercise of shares of Common Stock with an aggregate sale price giving rise to such purchase obligation of $10,000, under clause (A) of the immediately preceding sentence the Company shall be required to pay the Holder $1,000. The Holder shall provide the Company written notice indicating the amounts payable to the Holder in respect of the Buy-In and, upon request of the Company, evidence of the amount of such loss. Nothing herein shall limit a Xxxxxx’s right to pursue any other remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief with respect to the Company’s failure to timely deliver shares of Common Stock upon exercise of the Warrant as required pursuant to the terms hereof.
Compensation for Buy-In on Failure to Timely Deliver Warrant ADSs Upon Exercise In addition to any other rights available to the Holder, if the Company fails to cause the Depositary to deliver to the Holder the Warrant ADSs in accordance with the provisions of Section 2(d)(i) above pursuant to an exercise on or before the Warrant ADS Delivery Date, and if after such date the Holder is required by its broker to purchase (in an open market transaction or otherwise) or the Holder’s brokerage firm otherwise purchases, ADSs to deliver in satisfaction of a sale by the Holder of the Warrant ADSs which the Holder anticipated receiving upon such exercise (a “Buy-In”), then the Company shall (A) pay in cash to the Holder the amount, if any, by which (x) the Holder’s total purchase price (including brokerage commissions, if any) for the ADSs so purchased exceeds (y) the amount obtained by multiplying (1) the number of Warrant ADSs that the Company was required to deliver to the Holder in connection with the exercise at issue times (2) the price at which the sell order giving rise to such purchase obligation was executed, and (B) at the option of the Holder, either reinstate the portion of the Warrant and equivalent number of Warrant ADSs for which such exercise was not honored (in which case such exercise shall be deemed rescinded) or deliver to the Holder the number of ADSs that would have been issued had the Company timely complied with its exercise and delivery obligations hereunder. For example, if the Holder purchases ADSs having a total purchase price of $11,000 to cover a Buy-In with respect to an attempted exercise of ADSs with an aggregate sale price giving rise to such purchase obligation of $10,000, under clause (A) of the immediately preceding sentence the Company shall be required to pay the Holder $1,000. The Holder shall provide the Company written notice indicating the amounts payable to the Holder in respect of the Buy-In and, upon request of the Company, evidence of the amount of such loss. Nothing herein shall limit a Xxxxxx’s right to pursue any other remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief with respect to the Company’s failure to timely deliver ADSs upon exercise of the Warrant as required pursuant to the terms hereof.
Company’s Failure to Timely Convert If within two (2) Trading Days after the Company's receipt of the facsimile or email copy of a Conversion Notice the Company shall fail to issue and deliver to Holder via “DWAC/FAST” electronic transfer the number of shares of Common Stock to which the Holder is entitled upon such holder's conversion of any Conversion Amount (a "Conversion Failure"), the Original Principal Amount of the Note shall increase by $2,000 per day until the Company issues and delivers a certificate to the Holder or credit the Holder's balance account with DTC for the number of shares of Common Stock to which the Holder is entitled upon such holder's conversion of any Conversion Amount (under Holder’s and Company’s expectation that any damages will tack back to the Issuance Date). Company will not be subject to any penalties once its transfer agent processes the shares to the DWAC system. If the Company fails to deliver shares in accordance with the timeframe stated in this Section, resulting in a Conversion Failure, the Holder, at any time prior to selling all of those shares, may rescind any portion, in whole or in part, of that particular conversion attributable to the unsold shares and have the rescinded conversion amount returned to the Outstanding Balance with the rescinded conversion shares returned to the Company (under Xxxxxx’s and Company’s expectations that any returned conversion amounts will tack back to the original date of the Note).
